Press Alt + R to read the document text or Alt + P to download or print.

No preview available

The URL can be used to link to this page

Home My WebLink AboutAG 20-080 - TONY LIND PAVING, LLC RETURN TO: PW ADMIN EXT: 2700 ID#: 4136 CITY OF FEDERAL WAY LAW DEPARTMENT ROUTING FORM 1. ORIGINATING DEPT/DIY: PUBLIC WORKS/Capltal Enlneenn Division mm �mm � ww 2. ORIGINATING STAFF PERSON:Jeff HUynh EXT: 2721mmmmmmmmmmmmmmmmmmm 3. DATE REQ.B):, 3. TYPE OF DOCUMENT(CHECK ONE): p CONTRACTOR SELECTION DOCUMENT(E.G.,RFB,RFP,RFQ) ❑ PUBLIC WORKS CONTRACT © SMALL OR LIMITED PUBLIC WORKS CONTRACT ❑ PROFESSIONAL SERVICE AGREEMENT ❑ MAINTENANCE AGREEMENT ❑ GOODS AND SERVICE AGREEMENT ❑ HUMAN SERVICES/CDBG ❑ REAL ESTATE DOCUMENT ❑ SECURITY DOCUMENT(E.G.BOND RELATED DOCUMENTS) ❑ ORDINANCE ❑ RESOLUTION m CONTRACT AMENDMENT(AG#):20-OHO ❑ INTERLOCAL ❑ OTHER ..- 4. PROJECT NAME.:2020-2021_wNeuc hmborhood Traffic Safety (NTS) Project www s. NAME of CONTRACTOR:Pac West Paving DBA Tony Lind Paving, LLC ADDRESS: 23048 1?2nd Ave aE.Ken.L WA 98042 "I"ImI,i;p"IION . -6 0- 612 �— In .._C -.- SIGNATURE m TCD ,,, -in, ......... ... ...mT TLE Pre....s.., ident 6. EXHIBITS AND ATTACHMENTS:0 SCOPE,WORK OR SERVICES ❑COMPENSATION ❑ INSURANCE REQUIREMENTS/CERTIFICATE ❑ ALL OTHER REFERENCED EXHIBITS ❑ PROOF OF AUTHORITY TO SIGN ❑ REQUIRED LICENSES ❑ PRIOR CONTRACT/AMENDMENTS CFW LICENSE# BL,EXP. 12/311 UBI#m EXP. / / 7. TERM: COMMENCEMENT DATE'.N,TP,Date COMPLETION DATE:, 12/31/2022 8. TOTAL COMPENSATION:$120 OOO.00 $q 000+$60,000) (INCLUDE EXPENSES AND SALES TAX,IF ANY) (IF CALCULATED ON HOURLY LABOR CHARGE-ATTACH SCHEDULES OF EMPLOYEES TITLES AND HOLIDAY RATES) REIMBURSABLE EXPENSE: ❑YES ❑NO IF YES,MAXIMUM DOLLAR AMOUNT: IS SALES TAX OWED: ❑YES ❑NO IF YES,$ PAID BY: ❑CONTRACTOR ❑CITY RETAINAGE: RETAINAGE AMOUNT:„ _,_ o RETAINAGE AGREEMENT(SEE CONTRACT) OR ❑RETAINAGE BOND PROVIDED O PURCHASING: PLEASE CHARGE TO: 101-4300-230-543-10-480 9. DOCUMENT/CONTRACT REVIEW INITIAL /DATE REVIEWED...... INITIAL/DATE APPROVED 6 PROJECT MANAGER JH/ 8/10/202 .... ..... ^.2 ❑ DIVISION MANAGER ❑ DEPUTY DIRECTOR DSW 8/i0f22 ❑ DIRECTOR EJW allaf2022 ❑ RISK MANAGEMENT (IF APPLICABLE) I LAW DEPT KVA 8/1 712 0 2 2 10. COUNCIL APPROVAL(IF APPLICABLE) SCHEDULED COMMITTEE DATE° COMMITTEE APPROVAL DATE: February 7,2022 SCHEDULED COUNCIL DATE: COUNCIL APPROVAL DATE: February15,2022 11. CONTRACT SIGNATURE ROUTING ❑ SENT TO VENDOR/CONTRACTOR DATE SENT: DATE REC,D; ❑ ATTACH: SIGNATURE AUTHORITY, INSURANCE CERTIFICATE,LICENSES,EXHIBITS ❑ CREATE ELECTRONIC REMINDER(NOTIFICATION FOR 1 MONTH PRIOR TO EXPIRATION DATE (INCLUDE DEPT.SUPPORT STAFF IF NECESSARY AND FEEL FREE TO SET NOTIFICATION MORE THAN A MONTH IN ADVANCE IF COUNCIL APPROVAL IS NEEDED.) INITIAL„/,DA,T,ES„IGN,E,D..,,,, m_,-.,, ❑ FINANCE DEPARTMENT IJ A�� a S9h:d'Jr�¢I�uRI °(ME OR DIRI C rOR) J.Y ❑ ASSIGNED AG# AG# _ ❑ SIGNED COPY RETURNED DATE SENT: .. .mm. .... .... COMMENTS: FXFCI,JTF" ORIGfNA.[,5 ........... This change order is to increase the contract for the approved annual budgeted amount Contract to to re-bid next year(every other year bid) 1/2020 CITY OF FEDERAL WAY CONTRACT CHANGE ORDER AGREEMENT 2020-2021 NTS 03 7/25/2022 PROGRAM AG#20-080 _ PROJECT NUMBER AGREEMENT NUMBER CHANGE ORDER NUMBER EFFECTIVE DATE PAC WEST PAVING DBA TONY 2020-2021 NTS PROGRAM LIND PAVING PROJECT TITLE .. CONTRACTOR SUMMARY OF PROPOSED CHANGES: This Change Order covers the work changes summarized below: Change Order#3 provides to increase the current contract amount by$60,000.00 to a total of$120,000.00 and adjust contract unit bid prices by 5.9% based on the Puget Sound Consumer Index(CPI). The time provided for completion in the Contract is ® Unchanged ❑ Increased by_Working Day(s) ❑ Decreased by_Working Day(s) This Document shall become an Amendment to the Contract and all provisions of the Contract not amended herein will apply to this Change Order. Will this change affect expiration or extent of Insurance coverage? ❑ Yes 0 No If"Yes"Will the Policies Be Extended? ❑ Yes ❑ No MODIFICATIONSTO UNIT PRICES:. PREVIOUS REVISED ITEM NO. ITEM CITY UNIT PRICE UNIT PRICE ADD OR DELETE THESE ITEMS ARE APPROXIMATE OR ESTIMATED QUANTITIES INVOLVED IN THIS CHANGE: ITEM NO. ITEM CITY UNIT PRICE ADD OR DELETE E$ r0+... T T INCREAS 000 00 DEPARTMENT RECAP TO DATE: ORIGINAL CONTRACT AMOUNT $ 60000.001 PREVIOUS CHANGE ORDERS $ 000 THIS CHANGE ORDER $ 60-00Q 00 NEW CONTRACT AMOUNT $120,000 00 CHANGE ORDER AGREEMENT 1 Rev. /19 STATEMENT: Payment for the above work will be in accordance with applicable portions of the standard specifications,and with the understanding that all materials, workmanship and measurements shall be in accordance with the provisions of the standard specifications, the contract plans, and the special provisions governing the types of construction. The execution of this Change Order shall constitute full satisfaction and a waiver of any and all claims by the Contractor arising out of, or relating in any way to, the Work identified, to be performed, or deleted pursuant to Change O der except as specifically described in this Change Order. CONTRA R'S SIGNATURE DATE I IVb-9W6R KS DIRECTOR DATE CHANGE ORDER AGREEMENT Rev. /19 Client#: 189338 PACPAVI DATE(MM/DDIYYYY) ACORD. CERTIFICATE OF LIABILITY INSURANCE 8/22/2022 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer any rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Jamie Lee Cabrera NAME: A/C Propel Insurance ADDRESS, 1^ p ��-�°�) 326 P 800 499 0933 866 577 1201 Pacific Avenue; Suite 1000 E�kDR amielee Cabrera ropelinsurance.com COM Middle Market INSURER(S)AFFORDING COVERAGE NAIC# Tacoma,WA 98402-4321 .............. ...... .. INSURER A:Middlesex Insurance Company 23434 INSURED .INSURER B Pac West Paving LLC DBA IN SURER C Tony Lind Paving � ,�...... _ _._ __ .. � . INSURER D: 2515 South Hood Street �' "" — INSURER E Tacoma,WA 98402-1223 INSURER F.................................... ,..,,..__ COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. I fS'R -- 466LSUf3R POLICY_&F r POLICYEJUf .... ...... ...... -- TYPE OF INSURANCE LIMITS INSR WND .., POLICY NUMBER _._[M W Yh/YY) (MMfA7�D/YYyY),....... _ A X COMMERCIAL GENERAL LIABILITY X X A0196080004 6/24/2022 06/2412023 EACH OCCURRENCE $_1,000m000 ._.�CLAIMS-MADE ®OCCUR _PIMVm�aLE$�IaNccurri„ co-rJ� $500L000 ..m.. X PD Ded:1,000 MED ExP(Any one parson) s 1 Or000 ... PERSONAL&ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $.2,000,00 _ 0 NERAL AGGREGATE $3,000 OO � PI�O- �LOC 9 POLICY X ..GEC'&" OTHER: $ A AUTOMOBILE LIABILITY X X A0196080001 6/24/2022 06/24/202 3 COMBINED SINGLE LIMIT 1 000,000 IFa xccbdo) .............................. —.$...._+ „ + ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS X HIRED NON-OWNED PROPERTY DAMAGE - �....AUTOS ONLY X AUTOS ONLY ,_(Pr grerrrt) $ rirl $ JA UMBREXCESS ABAB X OCCUR CLAIMS-MADE X X A0196080005 6/24/2022 06/24/202 mEACH OCCURRENCE $5 000 000 . RETE ..AGGPERATE ... OTH f$SAOOO,OI),ll .... A WORKERS OMP N LIABILITY AND ITY 1 OOOO YIN .......... , ,...� - _._— ........ ,,,,..,.,, m ��,.,__ ..DEDX N.... ( 019608000 6/24/2022 06/241202 ._X sT �.z —�F A.. § ,.t t....... ANY PROPRIETORfPARTNERREX..ECUTIVE WA Stop Gap) E L EACH ACCIDENT $1 OOO OOO iOFFICEWMEMBERE%C;LUDI-D7 N/A 000 (Mandatory fn NH) EA LIMIT If yes,describe under E.L DISEASE-POLICY EMPLOYEE IT $1 0 000,s 00 i DESCRIPTION OF OPERATIONS below 0 DESCRIPTION OF OPERATIONS I LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) RE: Neighborhood Traffic Safety(NTS)Program City of Federal Way, its officers,officials,employees,volunteers and agents Additional Insured Status applies per attached form(s).Waiver of Subrogation applies per attached form(s). Primary non-contributory applies per attached form(s). CERTIFICATE HOLDER CANCELLATION City of Federal Way SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Y y THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 33325 8th Ave S. ACCORDANCE WITH THE POLICY PROVISIONS. Federal Way,WA 98003 AUTHORIZED REPRESENTATIVE ©1988-2015 ACORD CORPORATION.All rights reserved. ACORD 25(2016/03) 1 of 1 The ACORD name and logo are registered marks of ACORD #S5394240/M5278968 SXC01 This page has been left blank intentionally, COMMERCIAL GENERAL LIABILITY CG 20 01 1219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARYO C NT" L O Y ® OTHER INSURANCE CONDITION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART The following is added to the Other Insurance (2)You have agreed in writing in a contract or Condition and supersedes any provision to the agreement that this insurance would be contrary: primary and would not seek contribution Primary And Noncontributory Insurance from any other insurance available to the This insurance is primary to and will not seek additional insured. contribution from any other insurance available to an additional insured under your policy provided that: (1) The additional insured is a Named Insured under such other insurance; and CG 20 01 12 19 ©Insurance Services Office, Inc., 2018 Page 1 of 1 A0196080 06/28/2022 Middlesex Insurance Company 1 00001 0000000000 22179 0 N eb0122b8-lc70 1-a331-8b5O84d45372 POLICY NUMBER: A0196080004 COMMERCIAL GENERAL LIABILITY CG24041219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF' IG TS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART ELECTRONIC DATA LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART POLLUTION LIABILITY COVERAGE PART DESIGNATED SITES POLLUTION LIABILITY LIMITED COVERAGE PART DESIGNATED SITES PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART RAILROAD PROTECTIVE LIABILITY COVERAGE PART UNDERGROUND STORAGE TANK POLICY DESIGNATED TANKS SCHEDULE Name Of Person(s)Or Organization(s): Any person or organization to whom you are required to waive your right to recover by a written contract or agreement executed prior to loss Information required to complete this Schedule, if not shown above,will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV-Conditions: We waive any right of recovery against the person(s) or organization(s) shown in the Schedule above because of payments we make under this Coverage Part. Such waiver by us applies only to the extent that the insured has waived its right of recovery against such person(s)or organization(s)prior to loss. This endorsement applies only to the person(s) or organization(s)shown in the Schedule above. CG 24 04 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 A0196080 06/28/2022 Middlesex Insurance Company 1 00001 0000000000 22179 0 N 41973204-dfd3-4fbd-95ba-8e36ecOf52d8 COMMERCIAL GENERAL LIABILITY CG 7125 06 22 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CONTRACTORS BLANKET ADDITIONAL, INSUREDS, PRIMARY & NON CONTRIBUTORY, WAIV O SUBROGATION This endorsement modifies the coverage provided under the following Coverage Form(s): COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Coverage enhancements are listed below. For details of each coverage, please read the corresponding policy provisions in the body of this endorsement. 1. Additional Insureds -Automatic Status for 13 Additional I ... nsured Types A. Owners, Lessees Or Contractors-Automatic Status When Required In A Written Construction Agreement With You B. Owners, Lessees Or Contractors-Automatic Status When Required In Written Construction Agreement With You (Completed Operations) C. State or Governmental Agency or Subdivision or Political Subdivision - Permits or Authorizations D. Lessor of Leased Equipment E. Owners or Other Interests From Whom Land Has Been Leased F. Manager or Lessor of Premise G. Mortgagee, Assignee, or Receiver H. Controlling Interest I. Co-owner Of Insured Premises J. Executors,Administrators, Trustees Or Beneficiaries K. State Or Governmental Agency Or Subdivision Or Political Subdivision- Permits Or Authorizations Relating To Premises L. Vendors M. Grantor of Franchise 2. Primary and Noncontributory-Other Insurance Condition 3. Waiver Of Transfer Of Rights Of Recovery Against Others To Us (Waiver Of Subrogation)- Automatic With respect to the coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement. 1. Additional Insureds - Automatic Status for 13 A. Owners, Lessees Or Contractors - Additional Insured Types Automatic Status When Required In A Section II - Who Is An Insured is amended to Written Construction Agreement With You include the following as additional insureds when 1) A person or organization with respect to you have agreed to add that person or liability for "bodily injury", "property organization as an Additional Insured on your damage" or "personal and advertising policy in a written contract or written agreement injury"caused, in whole or in part, by: with that person or organization, or because of a a. Your acts or omissions; or permit issued by a state or political subdivision; b. The acts or omissions of those acting provided the injury or damage occurs subsequent on your behalf; to the execution of the contract or agreement or issuance of the permit and while the contract, in the performance of your ongoing agreement or permit remains in effect. operations for the additional insured. CG 71 25 06 22 Includes copyrighted material of Insurance Services Office, Inc., Page 1 of 5 A0196080 with its permission. 06/28/2022 Middlesex Insurance Company 1 00003 0000000000 22179 0 N eb7f9841-3889-46bf-8b8b-c7b11859052 A person's or organization's status as an B. Owners, Lessees Or Contractors - additional insured under this endorsement Automatic Status When Required In Written ends when your operations for that Construction Agreement With You additional insured are completed. (Completed Operations) 2) With respect to the insurance afforded to 1) Any person(s) or organization(s) with these additional insureds, the following respect to liability for "bodily injury" or additional exclusions apply: "property damage" caused, in whole-or in This insurance does not apply to: part, by "your work" performed for that insure anda. "Bodily injury", "property damage" or proldtional ucts-competed operationsdhazard'in e personal and advertising injury arising but only when that portion of the out of the rendering of, or the failure to "products-completed operations hazard"is render, any professional architectural, not excluded by endorsement. engineering or surveying services, including: 2) With respect to the insurance afforded to 1. The preparing, approving, or failing these additional insureds, the following to prepare or approve, maps, shop additional exclusion applies: drawings, opinions, reports, This insurance does not apply to: surveys, field orders, change orders "Bodily injury" or "property damage" or drawings and specifications; or arising out of the rendering of, or the failure 2. Supervisory, inspection, to render, any professional architectural, architectural or engineering engineering or surveying services, activities. including: This exclusion applies even if the claims a. The preparing, approving, or failing to against any insured allege negligence or prepare or approve, maps, shop other wrongdoing in the supervision, drawings, opinions, reports, surveys, hiring, employment, training or field orders, change orders or drawings monitoring of others by that insured, if and specifications; or the "occurrence" which caused the b. Supervisory, inspection, architectural or "bodily injury" or"property damage", or engineering activities. the offense which caused the"personal This exclusion applies even if the claims and advertising injury", involved the against any insured allege negligence or rendering of or the failure to render any other wrongdoing in the supervision, hiring, professional architectural, engineering employment, training or monitoring of or surveying services. others by that insured, if the "occurrence" b. "Bodily injury" or "property damage" which caused the "bodily injury" or occurring after: "property damage" involved the rendering 1. All work, including materials, parts of or the failure to render any professional or equipment furnished in architectural, engineering or surveying connection with such work, on the services. project (other than service, C. State or Governmental Agency or maintenance or repairs) to be Subdivision or Political Subdivision - performed by or on behalf of the Permits or Authorizations additional insured(s) at the location Any state or governmental agency or of the covered operations has been subdivision or political subdivision, subject to completed; or the following provisions: 2. That portion of "your work" out of 1) This insurance applies only with respect to which the injury or damage arises operations performed by you or on your has been put to its intended use by behalf for which the state or governmental any person or organization other agency or subdivision or political than another contractor or subdivision has issued a permit or subcontractor engaged in performing operations for a principal authorization. as a part of the same project. 2) This insurance does not apply to: Page 2 of 5 Includes copyrighted material of Insurance Services Office, Inc., CG 71 25 06 22 A0196080 with its permission. 06/28/2022 Middlesex Insurance Company a. "Bodily injury", "property damage" or F. Manager or Lessor of Premise "personal and advertising injury" arising Any person(s) or organization(s) with respect out of operations performed for the to liability for "bodily injury", "property federal government, state or damage" or "personal and advertising injury" municipality; or caused, in whole or in part, by you or those b. "Bodily injury" or "property damage" acting on your behalf in connection with the included within the ownership, maintenance or use of that part of "products-completed operations the premises leased to you by the additional hazard". insured person(s)or organization(s), subject to D. Lessor of Leased Equipment the following additional exclusions: 1) Any person(s) or organization(s) with This insurance does not apply to: respect to -liability for "bodily injury", 1) Any "occurrence" which takes place after "property damage" or "personal and you cease to be a tenant in that premises. advertising injury" caused, in whole or in 2) Structural alterations, new construction or part, by your maintenance, operation or demolition operations performed by or on use of equipment leased to you by such behalf of the person(s) or organization(s) person(s)or organization(s). shown in the Schedule. 2) With respect to the insurance afforded to G. Mortgagee,Assignee, or Receiver these additional insureds, this insurance does not apply to any "occurrence" which Any person(s) or organization(s) with respect takes place after the equipment lease to their liability as mortgagee, assignee or expires. receiver and arising out of the ownership, E. Owners or Other Interests From Whom maintenance or use of a premises by you. Land Has Been Leased This insurance does not apply to structural alterations, new construction and demolition 1) Any person(s) or organization(s) with operations performed by or for such additional respect to liability for "bodily injury", insured person(s)or organization(s). "property damage" or "personal and advertising injury" caused, in whole or in H. Controlling Interest part, by you or those acting on your behalf 1) Any person(s) or organization(s) with in connection with the ownership, respect to their liability arising out of: maintenance or use of that part of the land a. Their financial control of you; or leased to you by the additional insured person(s)or organization(s). b. Premises they own, maintain or control 2) With respect to the insurance afforded to while you lease or occupy these these additional insureds, the following premises. additional exclusions apply: 2) This insurance does not apply to structural This insurance does not apply to: alterations, new construction and demolition operations performed by or for a. Any "occurrence" which takes place that person or organization. after you cease to lease that land; I. Co-owner Of Insured Premises b. Structural alterations, new construction Any person(s) or organization(s) with respect or demolition operations performed by to their liability as co-owner of a premises or on behalf of the additional insured co-owned by you and covered under this person(s)or organization(s). insurance. J. Executors, Administrators, Trustees Or Beneficiaries Any executor, administrator, trustee or beneficiary of your estate or living trust while acting within the scope of their duties as such. CG 7125 06 22 Includes copyrighted material of Insurance Services Office, Inc., Page 3 of 5 A0196080 with its permission. 06/28/2022 Middlesex Insurance Company 3 00003 0000000000 22179 0 N eb7f9841-3889-46bf-8b8b-c7b11859052 K. State Or Governmental Agency Or 1) "Bodily injury" or "property damage" for Subdivision Or Political Subdivision - which the vendor is obligated to pay Permits Or Authorizations Relating To damages by reason of the assumption of Premises liability in a contract or agreement. This Any state or governmental agency or exclusion does not apply to liability for subdivision or political subdivision, subject to damages that the vendor would have in the the following additional provision: absence of the contract or agreement; This insurance applies only with respect to the 2) Any express warranty unauthorized by you; following hazards for which the state or 3) Any physical or chemical change in the governmental agency or subdivision or product made intentionally by the vendor; political subdivision has issued a permit or 4) Repackaging, except when unpacked authorization in connection with premises you solely for the purpose of inspection, own, rent or control and to which this demonstration, testing, or the substitution insurance applies: of parts under instructions from the 1) The existence, maintenance, repair, manufacturer, and then repackaged in the construction, erection or removal of original container; advertising signs, awnings, canopies, cellar 5) Any failure to make such inspections, entrances, coal holes, driveways, adjustments, tests or servicing as the manholes, marquees, hoist away openings, vendor has agreed to make or normally sidewalk vaults, street banners or undertakes to make in the usual course of decorations and similar exposures; or business, in connection with the 2) The construction, erection or removal of distribution or sale of the products; elevators; or 6) Demonstration, installation, servicing or 3) The ownership, maintenance or use of any repair operations, except such operations elevators covered by this insurance. performed at the vendor's premises in L. Vendors connection with the sale of the product; 1) Any person(s)or organization(s)(referred to 7) Products which, after distribution or sale throughout this endorsement as vendor), by you, have been labeled or relabeled or but only with respect to liability for "bodily used as a container, part or ingredient of injury" or "property damage" arising out of any other thing or substance by or for the "your products" which are distributed or vendor; or sold in the regular course of the vendor's 8) "Bodily injury" or "property damage" business. arising out of the sole negligence of the However: vendor for its own acts or omissions or those of its employees or anyone else a. The insurance afforded to such vendor acting on its behalf. However, this only applies to the extent permitted by exclusion does not apply to: law; and a provided to the vendor is (1) The exceptions contained in b. If coverage P Subparagraphs d.or f.;or required by a contract or agreement, the insurance afforded to such vendor will not be broader than that which you are required by the contract or agreement to provide for such vendor. 2) With respect to the insurance afforded to these vendors, the following additional exclusions apply: a. The insurance afforded the vendor does not apply to: Pa e 4 of 5 Includes copyrighted material of Insurance Services Office, Inc., CG 71 25 06 22 A01 60 0 with its permission. 06/28/2022 Middlesex Insurance Company (2) Such inspections, adjustments, tests or This endorsement shall not increase the servicing as the vendor has agreed to applicable limits of insurance. make or normally undertakes to make in If there is any difference in coverage afforded the usual course of business, in to an additional insured in this endorsement connection with the distribution or sale and that provided under another additional of the products. insured endorsement attached to this policy, b. This insurance does not apply to any the broader coverage will apply to that insured person or organization, from whom additional insured. you have acquired such products, or any 2. Primary And Noncontributory Insurance ingredient, part or container, entering into, accompanying or containing such The following is added to the Other Insurance products. Condition and supersedes any provision to the M. Grantor of Franchise contrary: This insurance is primary to and will not seek Any person(s) or organization(s) with respect contribution from any other insurance available to to their liability as grantor of a franchise to you. an additional insured under your policy provided However: that: 1.The insurance afforded to such additional (1)The additional insured is a Named Insured insureds only applies to the extent permitted under such other insurance; and by law; and (2)You have agreed in writing in a contract or 2. If coverage provided to the additional insured is agreement that this insurance would be required by a contract or agreement, the primary and would not seek contribution from insurance afforded to such additional insured any other insurance available to the additional will not be broader than that which you are insured. required by the contract or agreement to 3. Waiver Of Transfer Of Rights Of Recovery provide for such additional insured. Against Others To Us(Waiver Of Subrogation) - With respect to the insurance afforded to Automatic these additional insureds, the following is The following is added to Paragraph 8. Transfer added to Section III -Limits Of Insurance: Of Rights Of Recovery Against Others To Us of If coverage provided to the additional insured Section IV-Conditions: is required by a contract or agreement, the We waive any right of recovery against any most we will pay on behalf of the additional person or organization, because of any payment insured is the amount of insurance: we make under this Coverage Part, to whom the 1. Required by the contract or agreement; or insured has waived its right of recovery in a 2. Available under the applicable limits of written contract or agreement. Such waiver by us insurance; applies only to the extent that the insured has waived its right of recovery against such person whichever is less. or organization prior to loss. CG 7125 06 22 Includes copyrighted material of Insurance Services Office, Inc., Page 5 of 5 A0196080 with its permission. 06/28/2022 Middlesex Insurance Company 5 00003 0000000000 22179 0 N eb7f9841-3889-46bf-8b8bc7b118594f52 POLICY NUMBER: A0196080004 COMMERCIAL GENERAL LIABILITY CG 2010 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS SCHEDULED PERSON O ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location(s) Of Covered Operations Any person or organization you are required to add as Jobsites as described in written contracts with the P 9 Y q e an named insured additional insured under a written contract or written Description: agreement in effect prior to any loss or damage All Operations with written contract with the named insured Information required to complete this Schedule, if not sh own above will be shown in the Declarations. A. Section II - Who Is An Insured is amended to B. With respect to the insurance afforded to these include as an additional insured the person(s) or additional insureds, the following additional organization(s) shown in the Schedule, but only exclusions apply: with respect to liability for "bodily injury", This insurance does not apply to "bodily injury" or "property damage" or "personal and advertising "property damage" occurring after: injury" caused, in whole or in part, by: 1. All work, including materials, parts or 1. Your acts or omissions; or equipment furnished in connection with such 2. The acts or omissions of those acting on your work, on the project (other than service, behalf; maintenance or repairs)to be performed by or in the performance of your ongoing operations for on behalf of the additional insured(s) at the the additional insured(s) at the location(s) location of the covered operations has been designated above. completed; or However: 2. That portion of "your work" out of which the injury or damage arises has been put to its 1. The insurance afforded to such additional intended use by any person or organization insured only applies to the extent permitted by other than another contractor or law; and subcontractor engaged in performing 2. If coverage provided to the additional insured operations for a principal as a part of the same is required by a contract or agreement, the project. insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. CG 20 10 12 19 ©Insurance Services Office, Inc., 2018 Page 1 of 2 A0196080 06/28/2022 Middlesex Insurance Company 1 00001 0000000000 22179 0 N 62fbaf3f-3267-48c4-8df8-c3326892ccec C. With respect to the insurance afforded to these 2. Available under the applicable limits of additional insureds, the following is added to insurance; Section III-Limits Of Insurance: whichever is less. If coverage provided to the additional insured is This endorsement shall not increase the required by a contract or agreement, the most we applicable limits of insurance. will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or Pa e 2 of 2 ©Insurance Services Office, Inc., 2018 CG 20 10 12 19 A0� 6080 06/28/2022 Middlesex Insurance Company POLICY NUMBER: A0196080004 COMMERCIAL GENERAL LIABILITY CG20371219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED _ OWNERS, LESSEES O CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location And Descri tion Of Com leted O erations m Any person or organization you are required to add as Jobsites and Operations as described in written an contracts with the named insured additional insured under a written contract or written agreement in effect prior to any loss or damage Information required to complete this Schedule, if not shown above,will be shown in the Declarations. A. Section II - Who Is An Insured is amended to B. With respect to the insurance afforded to these include as an additional insured the person(s) or additional insureds, the following is added to organization(s) shown in the Schedule, but only Section III-Limits Of Insurance: with respect to liability for "bodily injury" or If coverage provided to the additional insured is "property damage" caused, in whole or in part, by required by a contract or agreement,the most we "your work" at the location designated and will pay on behalf of the additional insured is the described in the Schedule of this endorsement amount of insurance: performed for that additional insured and included in the "products-completed operations hazard". 1. Required by the contract or agreement; or However: 2. Available under the applicable limits of 1. The insurance afforded to such additional insurance; insured only applies to the extent permitted by whichever is less. law; and This endorsement shall not increase the 2. If coverage provided to the additional insured applicable limits of insurance. is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. CG 20 37 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 A0196080 06/28/2022 Middlesex Insurance Company 1 00001 0000000000 22179 0 N 1776ce3e-fd25-4744-bd19-87cb713a42a6 POLICY NUMBER: A0196080001 COMMERCIAL AUTO CA04441013 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFEROF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured: Pac West Paving LLC Endorsement Effective Date: 06/24/2022 SCHEDULE ....... ..... ............... — ..... ..� Name(s)Of Person(s) Or Organization(s): Any person or organization from whom you are required to waive your right to recover under a written contract or agreement in effect prior to any loss or damage Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The Transfer Of Rights Of Recovery Against Others To Us condition does not apply to the person(s) or organization(s) shown in the Schedule, but only to the extent that subrogation is waived prior to the "accident' or the 'loss" under a contract with that person or organization. CA 04 44 10 13 © Insurance Services Office, Inc., 2011 Page 1 of 1 A0196080 06/28/2022 Middlesex Insurance Company 1 00001 0000000000 22179 0 N c7c0e129-b4fc-4292-M-fdWe862e94 POLICY NUMBER: A0196080001 COMMERCIAL AUTO CA 76 01 0615 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED INSURED - PRIMARY AND NONCONTRIBUTORY - COVERED AUTOS LIABILITY COVERAGE This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM AUTO DEALERS COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by this endorsement. This endorsement identifies person(s)or organization(s)who are"insureds"for Covered Autos Liability Coverage under the Who Is An Insured provision of the Coverage Form. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated. Named Insured: Pac West Paving LLC Endorsement Effective Date: 06/24/2022 SCHEDULE Name Of Person(s)Or Organization(s): Any person or organization you are required to add as an additional insured under a written contract or written agreement in effect prior to any loss or damage Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Each person or organization shown in the B. Primary And Noncontributory Insurance Schedule is an "insured" for Covered Autos This insurance is primary to and will not seek Liability Coverage, but only to the extent that contribution from any other auto insurance issued person or organization qualifies as an insured to the person or organization in the schedule under the Who Is An Insured provision contained under your policy provided that: in: h A.1. of Section II - Covered Autos (1) The person or organization is a Named Insured (1) Paragraph g p under such other insurance; and Liability Coverage in the Business Auto and Motor Carrier Coverage Forms; or (2) Prior to the "accident' you have agreed in D.2. of Section I - Covered Autos writing in a contract or agreement that this (2) Paragraph insurance would be primary and would not Coverages of the Auto Dealers Coverage seek contribution from any other insurance Form. available to the person or organization. CA 76 01 06 15 Includes copyrighted material of Insurance Services Office, Inc., Page 1 of 1 A0196080 with its permission. 06/28/2022 Middlesex Insurance Company 1 00001 0000000000 22179 0 N c7760294-ab67-451d-9230-7258b97a942 RETURN TO: PW ADMIN EXT: 2700 ID#: 4030 CITY OF FEDERAL WAY LAW DEPARTMENT ROUTING FORM 1. ORIGINATING DEPT/DIv: PUBLIC WORKS/Capital Engineering Division 2. ORIGINATING STAFF PERSON: Jeff HUynh EXT: 2721 3. DATE REQ. B1: 3. TYPE OF DOCUMENT(CHECK ONE): p CONTRACTOR SELECTION DOCUMENT(E.G.,RFB,RFP,RFQ) ❑ PUBLIC WORKS CONTRACT 0 SMALL OR LIMITED PUBLIC WORKS CONTRACT ❑ PROFESSIONAL SERVICE AGREEMENT ❑ MAINTENANCE AGREEMENT ❑ GOODS AND SERVICE AGREEMENT ❑ HUMAN SERVICES/CDBG ❑ REAL ESTATE DOCUMENT ❑ SECURITY DOCUMENT(E.G.BOND RELATED DOCUMENTS) ❑ ORDINANCE ❑ RESOLUTION ® CONTRACT AMENDMENT(AG#):24>080 ❑ INTERLOCAL ❑ OTHER 4. PROJECTN:I%IE;: 2020-2021 Neighborhood Traffic Safety (NTS) Project 5. NAME OF CONTRACTOR: Tony Lind Paving ADDRESS: 23048 172nd Ave SE Kent_, WA 98042 TLLLPI ION E:253-630-7612 E-MAIL: TLP Ton lied avin .com FAX: SIGNATURENAME: Tony Lind TITLE: President 6. EXHIBITS AND ATTACHMENTS:® SCOPE,WORK OR SERVICES ❑ COMPENSATION ❑ INSURANCE REQUIREMENTS/CERTIFICATE ❑ ALL OTHER REFERENCED EXHIBITS ❑ PROOF OF AUTHORITY TO SIGN ❑ REQUIRED LICENSES ❑ PRIOR CONTRACT/AMENDMENTS CFW LICENSE# BL EXP. 12/31/ UBI# ,EXP. / / 7. TERM: COMMENCEMENT DATE: NTP Date COMPLETION DATE: 12/31/2022 8. TOTAL COMPENSATION:$60,000.00 - no change (INCLUDE EXPENSES AND SALES TAX,IF ANY) (IF CALCULATED ON HOURLY LABOR CHARGE-ATTACH SCHEDULES OF EMPLOYEES TITLES AND HOLIDAY RATES) REIMBURSABLE EXPENSE: ❑YES ❑NO IF YES,MAXIMUM DOLLAR AMOUNT: IS SALES TAX OWED: ❑YES ❑NO IF YES,$ PAID BY: ❑CONTRACTOR ❑CITY RETAINAGE: RETAINAGE AMOUNT: !3 RETAINAGE AGREEMENT(SEE CONTRACT) OR ❑RETAINAGE BOND PROVIDED to PURCHASING: PLEASE CHARGE TO: 101-4300-230-543-10-480 9. DOCUMENT/CONTRACT REVIEW INITIAL/DATE REVIEWED INITIAL/DATE APPROVED 6 PROJECT MANAGER JH/12/06/21 ❑ DIVISION MANAGER 8 DEPUTY DIRECTOR DSW 12/6/21 6 DIRECTOR EJW 12/6/2021 ❑ RISK MANAGEMENT (IF APPLICABLE) 6 LAW DEPT 12/6/2021 MP 10. COUNCIL APPROVAL(IF APPLICABLE) SCHEDULED COMMITTEE DATE: COMMITTEE APPROVAL DATE: SCHEDULED COUNCIL DATE: COUNCIL APPROVAL DATE: 11. CONTRACT SIGNATURE ROUTING ❑ SENT TO VENDOR/CONTRACTOR DATE SENT: 12/07/21 DATE REC'D:12/20/21 ❑ ATTACH: SIGNATURE AUTHORITY, INSURANCE CERTIFICATE,LICENSES,EXHIBITS ❑ CREATE ELECTRONIC REMINDER/NOTIFICATION FOR 1 MONTH PRIOR TO EXPIRATION DATE (INCLUDE DEPT.SUPPORT STAFF IF NECESSARY AND FEEL FREE TO SET NOTIFICATION MORE THAN A MONTH IN ADVANCE IF COUNCIL APPROVAL IS NEEDED.) INITIAL/DATE SIGNED ❑ FINANCE DEPARTMENT ❑ LAW DEPT 6 SIGNATORY(MAYOR OR DIRECTOR) �lZI Lt ❑ CITY CLERK Z 2d 7a'I lu 0 y I nt. d, ❑ ASSIGNED AG# AG# Q�L� tI ❑ SIGNED COPY RETURNED DATE SENT: Q .0l:q,,f COMMENTS: EXECUTE" 1 "ORIGINALS I/2020 CITY OF FEDERAL WAY CONTRACT CHANGE ORDER AGREEMENT 2020-2021 NTS Program AG#20-080 2 1� 121 021 PROJECT NUMBER AGREEMENT NUMBER CHANGE ORDER NUMBER EFFECTIVE DATE 2020-2021 NTS Program Tony Lind Paving, LLC PROJECT TITLE CONTRACTOR SUMMARY OF PROPOSED CHANGES: This Change Order covers the work changes summarized below: Change Order No.2 provides to amend contract completion date from December 31,2021 to December 31, 2022. The time provided for completion in the Contract is ❑ Unchanged ® Increased by one (1)year. ❑ Decreased by_Working Day(s) This Document shall become an Amendment to the Contract and all provisions of the Contract not amended herein will apply to this Change Order. Will this change affect expiration or extent of Insurance coverage? ❑ Yes ❑ No If"Yes"Will the Policies Be Extended? ® Yes ❑ No MODIFICATIONS TO UNIT PRICES: PREVIOUS REVISED ITEM NO. ITEM QTY UNIT PRICE UNIT PRICE ADD OR DELETE THESE ITEMS ARE APPROXIMATE OR ESTIMATED QUANTITIES INVOLVED IN THIS CHANGE: ITEM NO. ITEM QTY UNIT PRICE ADD OR DELETE TOTAL NET CONTRACT: JINCREASE$ DECREASE$ DEPARTMENT RECAP TO DATE: ORIGINAL CONTRACT AMOUNT $60.000.00 PREVIOUS CHANGE ORDERS $ 0.00 THIS CHANGE ORDER $ 0.00 NEW CONTRACT AMOUNT $60,000.00 STATEMENT: CHANGE ORDER AGREEMENT 1 Rev. 8/19 Payment for the above work will be in accordance with applicable portions of the standard specifications, and with the understanding that all materials, workmanship and measurements shall be in accordance with the provisions of the standard specifications, the contract plans, and the special provisions governing the types of construction. The execution of this Change Order shall constitute full satisfaction and a waiver of any and all claims by the Contractor arising out of, or relating in any way to, the Work identified, to be performed, or deleted pursuant to Change Order except specifically described in this Change Order. CONTRACTOR'S NATUR- DATE PUBLIC WO KS DIRECTOR DATE CHANGE ORDER AGREEMENT 2 Rev. 8/19 Client#: 189338 PACPAVI DATE(MMIDD/YYYY) ACORD,. CERTIFICATE OF LIABILITY INSURANCE 1 12/14/2021 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer any rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Nicole Anderson NAME: _ Propel Insurance ;C No,Esl;:800 499-0933 w Npl_ 866 877-1326 Commercial Insurance ADD R=SS. nicole.anderson@propelinsurance.com 1201 Pacific Ave,Ste 1000 INSURER(S)AFFORDING COVERAGE NAIC# Tacoma,WA 98402 INSURER A:Ohio Security Insurance Company 24082 INSURED — — — INSURER B: Pac West Paving LLC DBA INSURER C Tony Lind Paving - - INSURER D 2515 South Hood Street Tacoma,WA 98402-1223 INSURER E - - INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ADDLISUSR POLICY EFF POLICY EXP LTF TYPE OF INSURANCE INSR WVD POLICY NUMBER (MMIDD/YYYY)L(MM/DD/YYYY) LIMITS A XI COMMERCIAL GENERAL LIABILITY BKS63408711 1612412021 0612412022 EACH OCCURRENCE $1,000,000 DAMAGE TO RENTED - X OCCUR PREMISES Ea occurrence $300,000 X PD Ded:1,000 MED EXP(Any one person) $10.000-- PERSONAL&ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2.000,000 �-1 PRO- POLICY I X JECT I LOC PRODUCTS-COMP/OP AGG $2,000,000 OTHER: $ A AUTOMOBILE LIABILITY BAS63408711 6/24/2021 06/24/202 ^Bra °slNr,�E LIMIT 1 000,000 _ _(��,-��Aenl $ r -- I X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ _ AUTOS ONLY I AUTOS $ HIRED NON-OWNED PROPERTY DAMAGE X AUTOS ONLY X AUTOS ONLY Per accident $ A X UMBRELLA LIAB X OCCUR II US063408711 06/24/2021106/24/2022 EACH OCCURRENCE $5 000 000 EXCESS LIAB rl CLAIMS-MADE 1 AGGREGATE $5 000 000 DFD X I RF7 IF V f)"W 10,000 $ A WORKERS COMPENSATION BKS63408711 6/24/2021 06/24/202 PTnr FOTTH- AND EMPLOYERS'LIABILITY ANY PROPPIETOR r'�RTNER/EXECUTIVE Y/-1 WA STOP GAP E.L-.EACH ACCIDENT $1 000.000 .(FICf-WMEN1P�R:?r:LUDED? � NIA ------...... .... (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) RE: 2020-2021 Neighborhood Traffic Safety(NTS)Program City of Federal Way, its officers,officials,employees,volunteers and agents Additional Insured Status applies per attached form(s).Waiver of Subrogation applies per attached form(s). Primary non-contributory applies per attached form(s). s CERTIFICATE HOLDER CANCELLATION City of Federal Way SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Y y THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 33325 8th Ave S. ACCORDANCE WITH THE POLICY PROVISIONS. Federal Way,WA 98003 AUTHORIZED REPRESENTATIVE ©1988-2015 ACORD CORPORATION.All rights reserved. ACORD 25(2016/03) 1 of 1 The ACORD name and logo are registered marks of ACORD 11QAQ7R4dQ1UAAQr+RQR riI 11/18/21, 10:13 AM Corporations and Charities System BUSINESS INFORMATION Business Name: TONY LIND PAVING LLC UBI Number: 602 813 830 Business Type: WA LIMITED LIABILITY COMPANY Business Status: ACTIVE Principal Office Street Address: 23048172ND AVE SE, KENT,WA, 98042-4713, UNITED STATES Principal Office Mailing Address: 23048172ND AVE SE, KENT,WA, 98042-4713,UNITED STATES Expiration Date: 03/31/2022 Jurisdiction: UNITED STATES,WASHINGTON Formation/Registration Date: 03/16/2008 Period of Duration: PERPETUAL Inactive Date: Nature of Business: CONSTRUCTION REGISTERED AGENT INFORMATION Registered Agent Name: JEFF BOYER Street Address: 23048 172ND AVE SE,KENT,WA, 98042-4713,UNITED STATES Mailing Address: GOVERNORS Title Governors Type Entity Name First Name Last Name GOVERNOR INDIVIDUAL ANTHONY LIND https://ccfs.sos.wa.gov/#/BusinessSearch/Businessinformation 1/1 11/18/21, 10:14 AM Washington State Department of Revenue < Business Lookup License Information: New search Back to results Entity name: TONY LIND PAVING LLC Business TONY LIND PAVING name: Entity type: Limited Liability Company UBI #: 602-813-830 Business ID: 001 Location ID: 0001 Location: Active Location address: 23048 172ND AVE SE KENT WA 98042-4713 Mailing address: 23048 172ND AVE SE KENT WA 98042-4713 Excise tax and reseller permit status: Click here Secretary of State status: Click here Page 1 of 2 Endorsements Filter Endorsements held a License # Count De 's Status Expiratioi First issua hftps://secure.dor.wa.gov/gteunauth/_/#4 114 11118/21, 10:14 AM Washington State Department of Revenue Endorsements held a License# Count Details Status Expiratioi First issua Black Diamond BUS17-00 r:_Ve Mar-31-2 Mar-20-2 General Business - Non-Resident Bremerton General 34147 Active Dec-31-2i Aug-10-2 Business - Non- Resident Burien General 09747 Active Mar-31-2 Jul-18-20 Business - Non- Resident Covington General Active Mar-31-2 Jul-01-20, Business - Non- Resident Enumclaw General CUST000( Active Mar-31-2 Feb-20-2( Business - Non- Resident Federal Way 09-10153 Active Mar-31-2 Apr-30-2( General Business - Non-Resident Issaquah General Active Mar-31-2 Aug-15-2 Business - Non- Resident Lacey General 28978 Active Mar-31-2 Mar-14-2 Business - Non- Resident Maple Valley Active Mar-31-2 Aug-20-2 General Business - Non-Resident https://secure.dor.wa.gov/gteunauth/_/#4 2/4 11/18/21, 10:14 AM Washington State Department of Revenue Endorsements held a License # Count Details Status Expiratioi First issua Mercer Island 100028 Active Mar-31-2 Oct-09-2( General Business - Non-Resident Newcastle General Active Mar-31-2 Feb-28-2( Business - Non- Resident Olympia General 33113 Active Mar-31-2 Mar-14-2 Business - Non- Resident Pacific General 4618 Active Dec-31-21 Oct-27-2( Business - Non- Resident Redmond General RED1S-00 Active Dec-31-21 Feb-18-2( Business - Non- Resident Sammamish Active Mar-31-2 Jun-2S-2C General Business - Non-Resident Governing People May include governing people not registered with Secretary of State Governing people Title LIND, ANTHONY Registered Trade Names Registered trade names Status First issued TONY LIND PAVING Active Mar-26-2008 https:Hsecure.dor.wa.gov/gteunauth/_/#4 3/4 11/18/21, 10:14 AM Washington State Department of Revenue The Business Lookup information is updated nightly. Search date and time: 11/18/2021 10:14:13 AM Contact us How are we doing? Take our survey! Don't see what you expected? Check if your browser is supported hftps://secure.dor.wa.gov/gteunauth/—/#4 4/4 TURN TO: PW ADMIN EXT: 2700 ID#: 3936 CITY OF FEDERAL WAY LAW DEPARTMENT ROUTING FORM 1. ORIGINATING DEPT/DIv: PUBLIC WORKS/Capital Engineering Division 2. ORIGINATING STAFF PERSON:Jeff HUynh EXT: 2721 3. DATE REQ.BY: 3. TYPE OF DOCUMENT(CHECK ONE): ❑ CONTRACTOR SELECTION DOCUMENT(E.G.,RFB,RFP,RFQ) PUBLIC WORKS CONTRACT 0 SMALL OR LIMITED PUBLIC WORKS CONTRACT PROFESSIONAL SERVICE AGREEMENT MAINTENANCE AGREEMENT • GOODS AND SERVICE AGREEMENT HUMAN SERVICES/CDG ❑ REAL ESTATE DOCUMENT SECURITY DOCUMENT(E.G.BOND RELATED DOCUMENTS) ❑ ORDINANCE 0 RESOLUTION ® CONTRACT AMENDMENT(AG#):20-030 ❑ INTERLOCAL • OTHER mm� � io Seek ITS) Project 4. PROJECT NAME: 2 del or oo Traffic_. w , 5. NAME OF CONTRACTOR Tony Lind Paving ADDRESS: 23043 172nd Ave SE Kent, ; 9 042 � TELEPHONE:2 -63 _-712 612...... ........ E-MAIL:TLP@Tonylind avin c rru SIGNATURE hN.''Ap++1 Tony Lind TITLE. President 6. EXHIBITS AND ATTACHMENTS:m SCOPE,WORK OR SERVICES ❑COMPENSATION ❑ INSURANCE REQUIREMENTS/CERTIFICATE ❑ ALL OTHER REFERENCED EXHIBITS 13 PROOF OF AUTHORITY TO SIGN ❑ REQUIRED LICENSES 13 PRIOR CONTRACT/AMENDMENTS CFW LICENSE# BL,EXP.12/31/ UBI# ,EXP. 7. TERM: COMMENCEMENT DATE:-.T.DATE:-N.T.P D ate COMPLETION DATE: 12/31/201 S. TOTAL COMPENSATION:$60 I000.00 (INCLUDE EXPENSES AND SALES TAX,IF ANY) (IF CALCULATED ON HOURLY LABOR CHARGE-ATTACH SCHEDULES OF EMPLOYEES TITLES AND HOLIDAY RATES) REIMBURSABLE EXPENSE: ❑YES ❑NO IF YES,MAXIMUM DOLLAR AMOUNT: $ ..................... IS SALES TAX OWED: ❑YES ❑NO IF YES,$ __ PAID BY: ❑CONTRACTOR ❑CITY RETAINAGE: RETAINAGE AMOUNT: ❑RETAINAGE AGREEMENT(SEE CONTRACT)OR ❑RETAINAGE BOND PROVIDED ® PURCHASING: PLEASE CHARGE TO: 101-4300-230-543-10-480 9. DOCUMENT/CONTRACT REvIEW INITIAL/DATE REVIEWED INITIAL/DATE APPROVED PROJECT MANAGER JH1 W25/21 DIVISION MANAGER DEPUTY DIRECTOR EJW 6/25/2021 DIRECTOR w DSW 6P29129 ❑ RISK MANAGEMENT (IF APPLICABLE) LAW DEPT KVA 6/29/2021 10. COUNCIL APPROVAL(IF APPLICABLE) SCHEDULED COMMITTEE DATE: COMMITTEE APPROVAL DATE: SCHEDULED COUNCIL DATE: COUNCIL APPROVAL DATE: 11. CONTRACT SIGNATURE ROUTING ❑ SENT TO VENDOR/CONTRACTOR DATE SENT: DATE REC'D: .... ❑ ATTACH: SIGNATURE AUTHORITY,INSURANCE CERTIFICATE,LICEN SES,EXHIBITS ❑ CREATE ELECTRONIC REINDER/NOTIFICATION FOR 1 MONTH PRIOR TO EXPIRATION DATE (INCLUDE DEPT.SUPPORT STAFF IF NECESSARY AND FEEL FREE TO SET NOTIFICATION MORE THAN A MONTH IN ADVANCE IF COUNCIL APPROVAL IS NEEDED.) INITIAL./DA i F?S GNI:D � _.._..m. ..........._.....—.m.m..m..m..m..m............... ❑ FINANCE DEPARTMENT �S W DEPT 1I CITY CLERK(MAYOR OR DIRECTOR) - i , ❑ ASSIGNED AG# ❑ SIGNED COPY RETURNED DATE SENT: COMMENTS: EXECUTE" "ORIGINALS 112020 CITY OF FEDERAL WAY CONTRACT CHANGE ORDER AGREEMENT _230 _ AG#20-080 .. 1 PROJECT NUMBER _ AGREEMENT NUMBER CHANGE ORDER NUMBER EFFECTIVE DATE 20202021 NTS Pro Tony Lind Paving, LLC ...T. gram _....__ _ __... .�. PROJECT T-ITLE CONTRACTOR SUMMARY OF PROPOSED CHANGES: This Change Order covers the work changes summarized below: Change Order No. 1 provides for written consent of the assignment of the 2020-2021 NTS Program to Pac West Paving, LLC, formerly known as Tony Lind Paving, LLC, and amendment of the agreement in accordance with the same. All terms of the agreement shall continue in full force and effect and no further assignment shall be made without additional written consent. The time provided for completion in the Contract is ® Unchanged ❑ Increased by_Working Day(s) ❑ Decreased by_Working Day(s) This Document shall become an Amendment to the Contract and all provisions of the Contract not amended herein will apply to this Change Order. Will this change affect expiration or extent of Insurance coverage? ❑ Yes ® No If"Yes"Will the Policies Be Extended? ❑ Yes ❑ No ............ MODIFICATIONS TO UNIT PRICES: PREVIOUS REVISED ITEM NO. ITEM GQTY UNIT PRICE UNIT PRICE ADD OR DELETE THESE ITEMS ARE APPROXIMATE OR ESTIMATED QUANTITIES INVOLVED IN THIS CHANGE: ITEM NO. ITEM QTY UNIT PRICE ADD OR DELETE TOTAL NET CONTRACT: JINCREASE$ DECREASE$ DEPARTMENT RECAP TO DATE: ORIGINAL CONTRACT AMOUNT $00,000.00 PREVIOUS CHANGE ORDERS $ 0.00 THIS CHANGE ORDER $ 0.00 NEW CONTRACT AMOUNT $60,000.00 CHANGE ORDER AGREEMENT 1 Rev. 8/19 STATEMENT: Payment for the above work will be in accordance with applicable portions of the standard specifications,and with the understanding that all materials, workmanship and measurements shall be in accordance with the provisions of the standard specifications, the contract plans, and the special provisions governing the types of construction. The execution of this Change Order shall constitute full satisfaction and a waiver of any and all claims by the Contractor arising out of, or relating in any way to, the Work identified, to be performed, or deleted pursuant to Change Order except as specifically described in this Change Order. CONTRACTOR, SIG TURE DATE V PUBLIC IS DIRECTOR DATE CHANGE ORDER AGREEMENT 2 Rev. 8/19 RETURN TO: PW ADMIN EXT: 2700 ID#: 3683 / 3750 CITY OF FEDERAL WAY LAW DEPARTMENT ROUTING FORM . ORIGINATINGDEPT/DIv: PUBLICWORKS/CAPITAL ENGINEERING DIVISION .. ORIGINATING STAFF PERSON: NAVEEN CHANDRA EXT: 2729 3. DATE REQ.B3 . 5/19/20 �. TYPE OF DOCUMENT(CHECK ONE): O CONTRACTOR SELECTION DOCUMENT(E.G.,RFB,RFP,RFQ) ❑ PUBLIC WORKS CONTRACT O SMALL OR LIMITED PUBLIC WORKS CONTRACT ❑ PROFESSIONAL SERVICE AGREEMENT O MAINTENANCE AGREEMENT O GOODS AND SERVICE AGREEMENT O HUMAN SERVICES/CDBG O REAL ESTATE DOCUMENT ❑ SECURITY DOCUMENT(E.G.BOND RELATED DOCUMENTS) O ORDINANCE O RESOLUTION O CONTRACT AMENDMENT(AG#): O INTERLOCAL ❑ OTHER G. PROJECT NAME: 2020-2021 NEIGHBORHOOD TRAFFIC SAFETY (NTS) PROJECT NAME OF CONTRACTOR: TONY LIND PAVING_, LLC ADDRESS: 23048 172ND AVENUE SE. KENT. WA 98042 TELEPHONE:253-630-7612 E-MAIL: I n lin i n , FAX: _ SIGNATURE NAME' O NY L I N D TITLE: QW WN E R t. EXHIBITS AND ATTACHMENTS:O SCOPE,WORK OR SERVICES O COMPENSATION ❑ INSURANCE REQUIREMENTS/CERTIFICATE ❑ ALL OTHEF REFERENCED EXHIBITS O PROOF OF AUTHORITY TO SIGN O REQUIRED LICENSES O PRIOR CONTRACT/AMENDMENTS CFW LICENSE#09-101535-0(' BL,EXP. 12/31/20 UBI#602 813 830 ,EXP. '. TERM: COMMENCEMENT DATE: NTP Date COMPLETION DATE: 12/31/2021 i. TOTAL COMPENSATION:$60 000.00 (INCLUDE EXPENSES AND SALES TAX,IF ANY) (IF CALCULATED ON HOURLY LABOR CHARGE-ATTACH SCHEDULES OF EMPLOYEES TITLES AND HOLIDAY RATES) REIMBURSABLE EXPENSE: ❑YES 0 NO IF YES,MAXIMUM DOLLAR AMOUNT: S IS SALES TAX OWED: ❑YES OO NO IF YES,$ PAID BY: O CONTRACTOR O CITY RETAINAGE: RETAINAGE AMOUNT: ❑RETAINAGE AGREEMENT(SEE CONTRACT) OR ❑RETAINAGE BOND PROVIDED in PURCHASING: PLEASE CHARGE TO: 101-4300-230-543-10-480 I. DOCUMENT/CONTRACT REVIEW INITIAL/DATE REVIEWED INITIAL/DATE APPROVED 8 PROJECT MANAGER See original routing form NC 05/15/2020 8 DIVISION MANAGER See original routing form SLH 5/18/20 8 DEPUTY DIRECTOR See original routing form DSW 5/20/20 A DIRECTOR See original routing form ILK, ❑ RISK MANAGEMENT (IF APPLICABLE) See original routing form 8 LAW DEPT See original routing form ER 5/27/2020 O. COUNCIL APPROVAL(IF APPLICABLE) SCHEDULED COMMITTEE DATE: COMMITTEE APPROVAL DATE: SCHEDULED COUNCIL DATE: COUNCIL APPROVAL DATE: fill in committee/council dates 1. CONTRACT SIGNATURE ROUTING ❑ SENT TO VENDOR/CONTRACTOR DATE SENT: DATE REC'D: ❑ ATTACH: SIGNATURE AUTHORITY, INSURANCE CERTIFICATE,LICENSES,EXHIBITS ❑ CREATE ELECTRONIC REMINDER/NOTIFICATION FOR I MONTH PRIOR TO EXPIRATION DATE (INCLUDE DEPT.SUPPORT STAFF IF NECESSARY AND FEEL FREE TO SET NOTIFICATION MORE THAN A MONTH IN ADVANCE IF COUNCIL APPROVAL IS NEEDED.) INITIAL/DATE SIGNED ❑ FINANCE DEPARTMENT AW DEPT ll:iol -7 S!(1NATOI0Y(MAYOR OR DIRECTOR) CITY CLERK ❑ ASSIGNED AG# A ❑ SIGNED COPY RETURNED DATE SENT: :OMMENTS: ?XECUTE° "ORIGINALS Tease send as word doc and please do not change dates at bottom in footer.this is how law determines the most recent version of the template is being used. 1/2020 CITY OF FEDERAL WAY LAW DEPARTMENT ROUTING FORM ORIGINATING DEPT/DIV: PUBLIC WORKS/CAPITAL ENGINEERING DIVISION ORIGINATING STAFF PERSON:NAVEEN CHANDRA EXT:2729 3. DATE REQ.BY:ASAP TYPE OF DOCUMENT(CHECK ONE): CONTRACTOR SELECTION DOCUMENT(E.G.,RFB, RFP,OSMALL ❑ PUBLIC WORKS CONTRACT ORLIMITED PUBLIC WORKS CONTRACT ❑ PROFESSIONAL SERVICE AGREEMENT ❑ MAINTENANCE AGREEMENT ❑ GOODS AND SERVICE AGREEMENT ❑ HUMAN SERVICES/CDBG ❑ REAL ESTATE DOCUMENT ❑ SECURITY DOCUMENT(E.G.BOND RELATED DOCUMENTS) ❑ ORDINANCE ❑ RESOLUTION ❑ CONTRACT AMENDMENT(AG#): ❑ INTERLOCAL ❑ OTHER PROJECT NAME:2020-2021 NFI.GHBORI100D TRAFFIC SAFETY(NTS)PROJECT NAME OF CONTRACTOR: "TPSD ADDRESS: TELEPHONE: E-MAIL: F.Ax: SIGNATURE NAME: TITLE: EXHIBITS AND ATTACHMENTS: ❑ SCOPE,WORK OR SERVICES ❑ COMPENSATION ❑ INSURANCE REQUIREMENTS/CERTIFICATE ❑ ALL OTHER REFERENCED EXHIBITS ❑ PROOF OF AUTHORITY TO SIGN ❑ REQUIRED LICENSES ❑ PRIOR CONTRACT/AMENDMENTS CFW LICENSE# BL,EXP. 12/31/_ UBI# ,EXP. / /T TERM: COMMENCEMENT DATE: B.0 COMPLETION DATE: IZI3I� • TOTAL COMPENSATION:$ I�j (INCLUDE EXPENSES AND SALES TAX,IF ANY) (IF CALCULATED ON HOURLY LABOR CHARGE-ATTACH SCHEDULES OF EMPLOYEES TITLES AND HOLIDAY RATES) REIMBURSABLE EXPENSE: ❑YES ❑NO IF YES,MAXIMUM DOLLAR AMOUNT: $ IS SALES TAX OWED: ❑YES ❑NO IF YES,$ PAID BY: ❑CONTRACTOR ❑CITY RETAINAGE: RETAINAGE AMOUNT: ❑RETAINAGE AGREEMENT(SEE CONTRACT) OR o RETAINAGE BOND PROVIDED ❑ PURCHASING: PLEASECHARGETO: DOCUMENT/CONTRACT REVIEW INITIAL/DATE REVIEWED INITIAL/DATE APPROVED K#0 "'ECT MANAGER MANAGER -� 'PI.1TY DIRE(-TOR I DIRECTOR ❑ RISK MANAGEMENT (IF APPLICABLE fel'LAW DEPT � 0. COUNCIL APPROVAL(IF APPLICABLE) SCHEDULED COMMITYFE`D-A]-E: COMMITTEE APPROVAL DAI'E: SCHEDULED COUNCIL DAI'E: COUNCH.APPROVAL DACE: 1. CONTRACT SIGNATURE ROUTING ❑ SENTTO VENDOR/CONTRACTOR DATE SENT: DAI'E REC'D: n ATTACH: SIGNATURE AUTHORITY, INSURANCE CERTIFICATE,LICENSES,EXHIBITS ❑ CREATE ELECTRONIC REMINDER/NOTIFICATION FOR I MONTH PRIORTO EXPIRATION DATE (INCLUDE DEPT.SUPPORT'STAFF IF NECESSARY AND FEEL FRF.E TO SGTNOTIFICATION MORE TIIAN A MONTH IN ADVANCE lF COUNCIL APPROVAI,IS NEFDED.) INITIAL/DATE SIGNED ❑ FINANCE DEPARTMENT u LAW DEPT ❑ SIGNATORY(MAYOR OR DIRECTOR) ❑ CITY CLERK ❑ ASSIGNEDAG# AG# ❑ SIGNED COPY RETURNED DATE SENT: ❑RETURN ONE ORIGINAL 'OMMENTS: .XECUTE ORIGINALS /nnl R SMALL PUBLIC WORKS CONTRACT FOR 2020-2021 Neighborhood Traffic Safety Program This small public works contract ("Contract") is dated effective this day of �200Dand is made by and between the City of Federal Way, a Washington municipal corporation ("City" or "Owner"), and Tony Lind Paving, LLC, a Limited Liability Company ("Contractor"). A. The City desires to retain an independent contractor to furnish all labor and materials necessary to perform work installation of traffic calming devices and other discretionary work listed in Exhibit"A" at Federal Way, Washington("Property"); and B. The Contractor has the requisite skill and necessary experience to perform such work. NOW, THEREFORE,the Parties("Parties") agree to the following terms and conditions: 1. SERVICES BY CONTRACTOR 1.1 Description of Work. Contractor shall perform all work and furnish all tools, materials, supplies, equipment, labor and other items incidental thereto necessary for the construction and completion of the work, more particularly described as the2020-2021 Neighborhood Traffic Safety Program project, in Exhibit "A" attached hereto and incorporated by this reference, ("Work"), and in accordance with and as described in the Contract Documents, which include without limitation, this Contract, Contract Change Order Agreement attached as Exhibit "B," Contractor's Retainage Agreement attached as Exhibit "C," Contractor's Retainage Bond attached as Exhibit "D,"Notice to Labor Unions attached as Exhibit `B," Certificate(s) of Insurance Form attached hereto as Exhibit "F," Performance/Payment Bond attached hereto as Exhibit "G," Title VI Assurances attached hereto as Exhibit "H," Prevailing Wage Rates attached as Exhibit "I," special provisions attached as Exhibit "J," and all other Appendices attached hereto and incorporated by this reference, (collectively the "Contract Documents"), which Work shall be completed to the City's satisfaction, within the time period prescribed by the City and pursuant to the direction of the Mayor or his or her designee. 1.2 Completion Date. The Work shall be commenced within five (5) days of receipt by the Contractor of the City's Notice to Proceed. The Work shall be completed on or before the 31st day of December, 2021. In the event the Work is not completed within the time specified, Contractor agrees to pay to the City liquidated damages in the amount set forth in the formula included in Section 1.3 of this Contract. The Work shall not be deemed completed until the City has accepted the Work. 1.3 Liquidated Damages. Time is of the essence of the Contract. Delays inconvenience the public and cost taxpayers undue sums of money, adding time needed for administration, inspection, and supervision. It is impractical for the City to calculate the actual City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program - 1 -- cost of delays. Accordingly, the Contractor agrees to pay liquidated damages calculated on the following formula for its failure to complete this Contract on time: (1) To pay (according to the following formula) liquidated damages for each working day beyond the number of working days established for completion, and (2) To authorize the City to deduct these liquidated damages from any money due or coming due to the Contractor. LIQUIDATED DAMAGES FORMULA LD=0.15C T where: LD = Liquidated damages per working day(rounded to the nearest dollar). C= Original Contract amount. T= Original time for completion. When the Work is completed to the extent that the City has full and unrestricted use and benefit of the facilities, both from an operational and safety standpoint, the City may determine the Work is complete. Liquidated damages will not be assessed for any days for which an extension of time is granted.No deduction or payment of liquidated damages will, in any degree, release the Contractor from further obligations and liabilities to complete this entire Contract. 1.4 Performance Standard. Contractor shall perform the Work in a manner consistent with accepted practices for other properly licensed contractors, performed to the City's satisfaction,within the time period prescribed by the City. 1.5 Compliance with Laws. Contractor shall perform the Work in accordance with all applicable federal, state and City laws, including but not limited to all City ordinances, resolutions, standards or policies, as now existing or hereafter adopted or amended, and obtain all necessary permits and pay all permit, inspection or other fees, at its sole cost and expense. 1.6 Change Orders. The City may, at any time, without notice to sureties, order changes within the scope of the Work. Contractor agrees to fully perform any such alterations or additions to the Work. All such change orders shall be in the form of the Contract Change Order Agreement attached hereto as Exhibit`B," which shall be signed by both the Contractor and the City, shall specifically state the change of the Work,the completion date for such changed Work, and any increase or decrease in the compensation to be paid to Contractor as a result of such change in the Work. Oral change orders shall not be binding upon the City unless confirmed in writing by the City. If any change hereunder causes an increase or decrease in the Contractor's cost of, or time required for, the performance or any part of the Work under this Contract, an equitable adjustment will be made and the Contract modified in writing accordingly. If the Contractor intends to assert a claim for an equitable adjustment hereunder, it shall, within five (5) days after receipt of a written change order from the City or after giving the City the written notice required above, as the case may be, submit to the City a written statement City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program 2 - setting forth the general nature and monetary extent of such claim; provided the City, in its sole discretion, may extend such five (5) day submittal period upon request by the Contractor. The Contractor shall supply such supporting documents and analysis for the claims as the City may require to determine if the claims and costs have merit. No claim will be allowed for any costs incurred more than five (5) days before the Contractor gives written notice as required.No claim by the Contractor for an equitable adjustment hereunder will be allowed if asserted after final payment under this Contract. 1.7 Work and Materials Omitted. The Contractor shall, when directed in writing by the City, omit work, services and materials to be furnished under the Contract and the value of the omitted work and materials will be deducted from the Total Compensation and the delivery schedule will be reviewed if appropriate. The value of the omitted work, services and materials will be a lump sum or unit price, as mutually agreed upon in writing by the Contractor and the City. If the parties cannot agree on an appropriate deduction, the City reserves the right to issue a unilateral change order adjusting the price and the delivery schedule. 1.8 Utility Location. Contractor is responsible for locating any underground utilities affected by the Work and is deemed to be an excavator for purposes of Chapter 19.122 RCW, as amended. Contractor shall be responsible for compliance with Chapter 19.122 RCW, including utilization of the "one call" locator system before commencing any excavation activities. 1.9 Air Environment. Contractor shall fully cover any and all loads of loose construction materials including without limitation, sand, dirt, gravel, asphalt, excavated materials, construction debris, etc., to protect said materials from air exposure and to minimize emission of airborne particles to the ambient air environment within the City of Federal Way. 2. TERM This Contract shall commence within five (5) days of receipt by the Contractor of the City's Notice to Proceed of this Contract and continue until the completion of the Work, which shall be no later than on or before the 31st day of December, 2021 and the expiration of all warranties contained in the Contract Documents ("Term"). 3. WARRANTY 3.1 Requisite Skill. The Contractor warrants that it has the requisite skill to complete the Work, and is appropriately accredited and licensed by all applicable agencies and governmental entities, including but not limited to being registered to do business in the City of Federal Way by obtaining a City of Federal Way business registration. Contractor represents that it has visited the site and is familiar with all of the plans and specifications in connection with the completion of the Work. 3.2 Defective Work. The Contractor shall, at its sole cost and expense, correct all Work which the City deems to have defects in workmanship and material discovered within one (1) year after the City's final acceptance of the Work. City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program 3 — 4. COMPENSATION 4.1 Tota] Compensation. In consideration of the Contractor performing the Work, the City agrees to pay the Contractor an amount not to exceed Sixty Thousand and 00/100 Dollars ($60,000.00), throughout the term of this contract to be paid upon completion of each instance per schedule outlined in Exhibit "A," which amount shall constitute full and complete payment by the City. 4.2 Contractor Respgnsible for Taxes. The Contractor shall be solely responsible for the payment of any taxes imposed by any lawful jurisdiction as a result of the performance and payment of this Contract. 4.3 Nonpayment. The City shall have the right to withhold payment to the Contractor for any of the Work not completed in a satisfactory manner, in the City's sole discretion, which shall be withheld until such time as Contractor modifies or repairs the Work so that the Work is acceptable to the City. 4.4 Method of Payment. Payment by the City for the Work will only be made after the Work has been completed, a voucher or invoice is submitted in the form specified by the City, and such invoice is approved by the appropriate City representative. Payment shall be made within thirty (30) days of receipt of such invoice or voucher unless otherwise set forth in the Bid Form. The Contractor's acceptance of such payment for the Work shall constitute full compensation for the performance of the Work. Invoices shall be submitted, in duplicate to: City of Federal Way ATTN: Accounts Payable 33325 8th Avenue South Federal Way, WA 98003-6325 Duplicate invoices shall be furnished to: City of Federal Way ATTN:Naveen Chandra, P.E. Public Works Department 33325 8th Avenue South Federal Way, WA 98003-6325 4.5 Retainafe. Pursuant to Chapter 60.28 RCW, five percent (5%) of the Total Compensation shall be retained by the City to assure payment of Contractor's state taxes as well as payment of subcontractors, suppliers and laborers. Upon execution of this Contract, Contractor shall complete, execute and deliver to the City the Contractor's Retainage Option attached hereto as Exhibit"C" or execute the Retainage Bond attached hereto as Exhibit"D."No payments shall be made by the City from the retained percentage fund ("Fund") nor shall the City release any retained percentage escrow account to any person, until the City has received City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program - 4 - from the Department of Revenue a certificate that all taxes, increases, and penalties due from the Contractor and all taxes due and to become due with respect to the Contract have been paid in full or that they are, in the Department's opinion, readily collectible without recourse to the State's lien on the retained percentage. Upon non-payment by the general contractor, any supplier or subcontractor may file a lien against the retainage funds, pursuant to Chapter 60.28 RCW. Subcontractors or suppliers are required to give notice of any lien within forty-five (45) days of the completion of the Work and in the manner provided in RCW 39.08.030. Within sixty (60) days after completion of all Work on this Contract, the City shall release and pay in full the money held in the Fund, unless the City becomes aware of outstanding claims made against this Fund. 5. EQUAL OPPORTUNITY EMPLOYER In all Contractor services,programs or activities, and all Contractor hiring and employment made possible by or resulting from this Contract,there shall be no discrimination by Contractor or by Contractor's employees, agents, subcontractors or representatives against any person because of sex, age (except minimum age and retirement provisions), race, color, creed, national origin,marital status or the presence of any disability, including sensory, mental or physical handicaps, unless based upon a bona fide occupational qualification in relationship to hiring and employment. This requirement shall apply, but not be limited to the following: employment, advertising, layoff or termination,rates of pay or other forms of compensation, and selection for training, including apprenticeship. Contractor shall comply with and shall not violate any of the terms of Chapter 49.60 RCW, Title VI of the Civil Rights Act of 1964,the Americans With Disabilities Act, Section 504 of the Rehabilitation Act of 1973, 49 CFR Part 21, 21.5 and 26, or any other applicable federal, state, or local law or regulation regarding non- discrimination. Contractor shall post a notice to Labor Unions or other employment organizations, attached hereto as Exhibit`B," as required by Section 202 of Executive Order 11246. Any material violation of this provision shall be grounds for termination of this Contract by the City and, in the case of the Contractor's breach,may result in ineligibility for further City agreements. If this project involves federal funds including USDOT funds administered by WSDOT, the contractor agrees to the clauses contained in Exhibit H. 6. INDEPENDENT CONTRACTOR/CONFLICT OF INTEREST 6.1 It is the intention and understanding of the Parties that the Contractor shall be an independent contractor and that the City shall be neither liable nor obligated to pay Contractor sick leave, vacation pay or any other benefit of employment, nor to pay any social security or other tax which may arise as an incident of employment. The Contractor shall pay all income and other taxes due. Industrial or any other insurance that is purchased for the benefit of the City, regardless of whether such may provide a secondary or incidental benefit to the Contractor, shall not be deemed to convert this Agreement to an employment contract. It is recognized that Contractor may or will be performing professional services during the Term for other parties; provided, however, that such performance of other services shall not conflict with or interfere with Contractor's ability to perform the Services. Contractor agrees to resolve any such conflicts of interest in favor of the City. City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program - 5 - 6.2 If the Contractor is a sole proprietorship or if this is a contract with an individual, the contractor agrees to notify the City and complete any required form if the Contractor retired under a State of Washington retirement system and agrees to indemnify any losses the City may sustain through the Contractor's failure to do so. 7. TERMINATION Prior to the expiration of the Term, this Contract may be terminated immediately, with or without cause by the City. 8. INDEMNIFICATION 8.1 Contractor Indemnification. The Contractor agrees to indemnify, defend and hold the City, its elected officials, officers, employees, agents, and volunteers harmless from any and all claims, demands, losses, actions and liabilities (including costs and all attorney fees) to or by any and all persons or entities, including, without limitation, their respective agents, licensees, or representatives, arising from, resulting from, or connected with this Contract to the extent caused by the negligent acts, errors or omissions of the Contractor, its partners, shareholders, agents, employees, or by the Contractor's breach of this Contract. Contractor waives any immunity that may be granted to it under the Washington State Industrial Insurance Act, Title 51 RCW. Contractor's indemnification shall not be limited in any way by any limitation on the amount of damages, compensation or benefits payable to or by any third party under workers' compensation acts, disability benefit acts or any other benefits acts or programs. 8.2 City, Indemnification. The City agrees to indemnify, defend and hold the Contractor, its officers, directors, shareholders, partners, employees, and agents harmless from any and all claims, demands, losses, actions and liabilities (including costs and attorney fees) to or by any and all persons or entities, including without limitation, their respective agents, licensees, or representatives, arising from, resulting from or connected with this Contract to the extent solely caused by the negligent acts, errors, or omissions of the City, its employees or agents. 8.3 Survival. The provisions of this Section shall survive the expiration or termination of this Contract with respect to any event occurring prior to such expiration or termination. 9. INSURANCE 9.1 Minimum Limits. The Contractor agrees to carry as a minimum, the following insurance, in such forms and with such carriers who have a rating, which is satisfactory to the City: (1) Workers' compensation and employer's liability insurance in amounts sufficient pursuant to the laws of the State of Washington; City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program 6 - (2) Commercial general liability insurance with combined single limits of liability not less than $2,000,000 for bodily injury, including personal injury or death, products liability and property damage. (3) Automobile liability insurance with combined single limits of liability not less than $2,000,000 for bodily injury, including personal injury or death and property damage. (4) If any structures are involved in the Contract, the Contractor shall maintain an All Risk Builder's Risk 2 form at all times in an amount no less than the replacement value of the structure until final acceptance of the project by the City. 9.2 Endorsements. Each insurance policy shall contain, or be endorsed to contain, the following provisions: (1) The City, its officers, officials, employees, volunteers and agents shall each be named as additional insured. (2) Coverage may not be terminated or reduced in limits except after thirty (30) days prior written notice by certified mail, return receipt requested,to the City. (3) Coverage shall be primary and non-contributory insurance as respects the City, its officials, employees and volunteers. Any insurance or self-insurance maintained by the City, its officials, employees or volunteers shall be in excess of Contractor's insurance. (4) Coverage shall apply to each insured separately against whom claim is made or suit is brought. (5) Coverage shall be written on an "occurrence" form as opposed to a"claims made" or"claims paid" form. 9.3 Verification. Contractor shall furnish the City with certificates of insurance evidencing the coverage required by this Section, in compliance with the Certificate(s) of Insurance Form attached hereto as Exhibit "F," which certificate must be executed by a person authorized by the insurer to bind coverage on its behalf. The City reserves the right to require complete certified copies of all required insurance policies, at any time. 9.4 Subcontractors. Contractors shall include all subcontractors as additional insured under its policies or shall furnish separate certificates for each subcontractor. All coverage for subcontractors shall be subject to all of the requirements stated herein. 9.5 Deductibles and Self Insured Retentions. Any deductibles or self-insured retentions must be disclosed by Contractor and approved in writing by the City. At the option of the City, Contractor shall either reduce or eliminate such deductibles or self-insured retentions or procure a bond guaranteeing payment for any amounts not covered by the insurance by reason of such deductibles or self-insured retentions. City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program - 7 - 9.6 Asbestos Abatement or Hazardous Materials. If asbestos abatement or hazardous materials work is performed, Contractor shall review coverage with the City's Risk Manager and provide scope and limits of coverage that are appropriate for the scope of Work and are satisfactory to the City. Contractor shall not commence any Work until its coverage has been approved by the Risk Manager. 9.7 Termination. The Contractor's failure to provide the insurance coverage required by this Section shall be deemed to constitute non-acceptance of this Contract by the Contractor and the City may then award this Contract to the next lower bidder. The provisions of this Section shall survive the expiration or termination of this Contract with respect to any event occurring prior to such expiration or termination. 10. PERFORMANCE/PAYMENT BOND Pursuant to RCW 39.08.010, Contractor shall post a Performance/Payment Bond in favor of the City, in the form attached to this Contract as Exhibit "G" and incorporated by this reference, in a dollar amount satisfactory to the City; to guarantee Contractor's performance of the Work to the City's satisfaction; to insure Contractor's performance of all of the provisions of this Contract; and to guarantee Contractor's payment of all laborers, mechanics, subcontractors and material persons. Contractor's obligations under this Contract shall not be limited to the dollar amount of the bond. Alternatively, pursuant to RCW 39.08.010, at the option of Contractor, if the value of this Contract is less than One Hundred Fifty Thousand Dollars ($150,000.00), the City may, in lieu of a bond, retain ten percent (10%) of the Contract amount for a period of thirty (3 0) days after the date of final acceptance, or until receipt of all necessary releases from the Department of Revenue and the Department of Labor and Industries and settlement of any liens filed under Chapter 60.28 RCW, whichever is later. 11. SAFETY Contractor shall take all necessary precautions for the safety of employees on the work site and shall comply with all applicable provisions of federal, state and municipal safety and health laws and codes, including without limitation, all OSHA/WISHA requirements, Safety and Health Standards for Construction Work (Chapter 296-155 WAC), General Safety and Health Standards (Chapter 296-24 WAC), and General Occupational Health Standards (Chapter 296-62 WAC). Contractor shall erect and properly maintain, at all times, all necessary guards, barricades, signals and other safeguards at all unsafe places at or near the Work for the protection of its employees and the public, safe passageways at all road crossings, crosswalks, street intersections, post danger signs warning against known or unusual hazards and do all other things necessary to prevent accident or loss of any kind. Contractor shall protect from damage all water, sewer, gas, steam or other pipes or conduits, and all hydrants and all other property that is likely to become displaced or damaged by the execution of the Work. The Contractor shall, at its own expense, secure and maintain a safe storage place for its materials and equipment and is City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program 8 - solely responsible for the same. 12. PREVAILING WAGES 12.1 Wages of Employees. This Contract is subject to the minimum wage requirements of Chapter 39.12 of the Revised Code of Washington, as now existing or hereafter amended or supplemented. In the payment of hourly wages and fringe benefits to be paid to any of Contractor's laborers, workpersons and/or mechanics, Contractor shall not pay less than the "prevailing rate of wage" for an hour's work in the same trade or occupation in the locality within the State of Washington where such labor is performed, as determined by the Industrial Statistician of the Department of Labor and Industries of the State of Washington, which "prevailing rates of wage" are attached hereto as Exhibit "I" and incorporated herein by this reference. Prevailing wages paid pursuant to this Agreement shall be the prevailing wage rates, which are in effect on the date when the bids,proposals, or quotes were required to be submitted to the City. 12.2 Exeiiil)tions to Prevailing Wage. The prevailing wage requirements of Chapter 39.12 RCW, and as required in this Contract do not apply to: (1) Sole owners and their spouses; (2) Any partner who owns at least 30%of a partnership; and (3) The President, Vice President and Treasurer of a corporation if each one owns at least 30%of the corporation. 12.3 Reporting Requirements. Contractor shall comply with all reporting requirements of the Department of Labor and Industries of the State of Washington.Upon the execution of this Contract, Contractor shall complete and file a Statement of Intent to Pay Prevailing Wages with the Department of Labor and Industries. Upon completion of the Work, Contractor shall complete and file an Affidavit of Wages Paid with the Department of Labor and Industries. Contractor shall deliver copies of both the Statement of Intent to Pay Prevailing Wages and the Affidavit of Wages Paid, certified by the Department of Labor and Industries,to the City. 12.4 Disputes. In the event any dispute arises as to what are the prevailing rates of wages for work of a similar nature and such dispute cannot be resolved by the City and the Contractor, the matter shall be referred for arbitration to the Director of the Department of Labor and Industries of the State of Washington and the decision therein shall be final and conclusive and binding on all parties involved in the dispute. 13. FAILURE TO PAY SUBCONTRACTORS In the event the Contractor shall fail to pay any subcontractors or laborers, or fail to pay for any materials or any insurance premiums, the City may terminate this Contract and/or the City may withhold from the money which may be due the Contractor an amount necessary for the payment of such subcontractors, laborers,materials or insurance premiums. City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program 9 14. OWNERSHIP OF DOCUMENTS All originals and copies of work product, including plans, sketches, layouts, designs, design specifications, records, files computer disks, magnetic media, all finished or unfinished documents or material which may be produced or modified by Contractor while performing the Work shall become the property of the City and shall be delivered to the City at its request. 15. CONFIDENTIALITY Any records, reports, information, data or other documents or materials given to or prepared or assembled by the Contractor under this Contract will be kept as confidential and shall not be made available to any individual or organization by the Contractor without prior written approval of the City. 16. BOOKS AND RECORDS The Contractor agrees to maintain books, records, and documents which sufficiently and properly reflect all direct and indirect costs related to the performance of this Contract and such accounting procedures and practices as may be deemed necessary by the City to assure proper accounting of all funds paid pursuant to this Contract. These records shall be subject at all reasonable times to inspection, review or audit by the City, its authorized representative, the State Auditor, or other governmental officials authorized by law to monitor this Contract. 17. CLEAN UP At any time ordered by the City and immediately after completion of the Work, the Contractor, shall, at its own expense, clean up and remove all refuse and unused materials of any kind resulting from the Work. In the event the Contractor fails to perform the necessary clean up, the City may, but in no event is it obligated to, perform the necessary clean up and the costs thereof shall be immediately paid by the Contractor to the City and/or the City may deduct its costs from any remaining payments due to the Contractor. 18. CONTRACTOR AND SUBCONTRACTOR RESPONSIBILITY: 18.1 Contractor Verification. The Contractor verifies that it has a certificate of registration with the State of Washington; has a current state unified business identifier number; is not disqualified from bidding on any public works contract under RCW 39.06.010 or 39.12.065 (3); has industrial insurance as required by Title 51 RCW, if applicable; has an employment security department number as required in Title 50 RCW, if applicable; has a state excise tax registration number as required in Title 82 RCW, if applicable; possesses a valid electrical contractor license as required by chapter 19.28 RCW, if applicable; and possesses an elevator contractor license as required by chapter 70.87 RCW, if applicable. 18.2 Subcontractor Contracts. The Contractor shall include the language of this section in each of its first tier subcontracts, and shall require each of its subcontractors to include the City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program - 10 - same language of this section in each of their subcontracts, adjusting only as necessary the terms used for the contracting parties. Upon request of the Owner, the Contractor shall promptly provide documentation to the Owner demonstrating that the subcontractor meets the subcontractor responsibility criteria below. The requirements of this section apply to all subcontractors regardless of tier. 18.3 Subcontractor Verification. At the time of subcontract execution, the Contractor shall verify that each of its first tier subcontractors meets the following bidder responsibility criteria: Have a current certificate of registration in compliance with chapter 18.27 RCW, which must have been in effect at the time of subcontract bid submittal; Have a current Washington Unified Business Identifier(UBI) number;Not be disqualified from bidding on any public works contract under RCW 39.06.010 or 39.12.065 (3); Have Industrial Insurance (workers' compensation) coverage for the subcontractor's employees working in Washington, as required in Title 51 RCW, if applicable; A Washington Employment Security Department number, as required in Title 50 RCW, if applicable; A Washington Department of Revenue state excise tax registration number, as required in Title 82 RCW, if applicable; An electrical contractor license, if required by Chapter 19.28 RCW, if applicable; An elevator contractor license, if required by Chapter 70.87 RCW. 19. GENERAL PROVISIONS 19.1 Entire Contract. The Contract Documents contain all of the agreements of the Parties with respect to any matter covered or mentioned in this Contract and no prior agreements or understandings pertaining to any such matters shall be effective for any purpose. 19.2 Modification. No provisions of this Contract, including this provision, may be amended or added to except by agreement in writing signed by the Parties or their respective successors in interest. 19.3 Full Force and Effect. Any provision of this Contract, which is declared invalid, void or illegal, shall in no way affect, impair, or invalidate any other provision hereof and such other provisions shall remain in full force and effect. 19.4 Assignment. The Contractor shall not transfer or assign, in whole or in part, any or all of its obligations and rights hereunder without the prior written consent of the City. In the event the City consents to any such assignment or transfer, such consent shall in no way release the Contractor from any of its obligations or liabilities under this Contract. 19.5 Successors In Interest. Subject to the preceding Subsection, this Contract shall be binding upon and inure to the benefit of the Parties' successors in interest, heirs and assigns. 19.6 Attorney Fees. In the event the City or the Contractor defaults on the performance of any terms in this Contract, and the Contractor or City places the enforcement of the Contract or any part thereof, or the collection of any monies due, or to become due hereunder, or recovery of possession of any belongings, in the hands of an attorney, or file suit upon the same, each Party shall pay all its own attorneys' fees, costs and expenses. The venue for any dispute related to this Contract shall be King County, Washington. City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program - 11 - 19.7 No Waiver. Failure of the City to declare any breach or default immediately upon occurrence thereof, or delay in taking any action in connection with, shall not waive such breach or default. Failure of the City to declare one breach or default does not act as a waiver of the City's right to declare another breach or default. 19.8 Goverciing Law. This Contract shall be made in and shall be governed by and interpreted in accordance with the laws of the State of Washington. 19.9 Autliority. Each individual executing this Contract on behalf of the City and Contractor represents and warrants that such individuals are duly authorized to execute and deliver this Contract on behalf of the Contractor or City. 19.10 Notices. Any notices required to be given by the City to Contractor or by the Contractor to the City shall be delivered to the Parties at the addresses set forth below. Any notices may be delivered personally to the addressee of the notice or may be deposited in the United States mail, postage prepaid, to the address set forth herein. Any notice so posted in the United States mail shall be deemed received three (3) days after the date of mailing. 19.11 Captions. The respective captions of the Sections of this Contract are inserted for convenience of reference only and shall not be deemed to modify or otherwise affect in any respect any of the provisions of this Contract. 19.12 Performance. Time is of the essence of this Contract and each and all of its provisions in which performance is a factor. Adherence to completion dates is essential to the Contractor's performance of this Contract. 19.13 C"oanpliatice with EthicsCode. If a violation of the City's Ethics Resolution No. 91-54, as amended, occurs as a result of the formation and/or performance of this Contract, this Contract may be rendered null and void, at the City's option. 19.14 Conflicting Provisions. In the event of a conflict between the terms and provisions of any of the Contract Documents, the Mayor or his or her designee shall issue an interpretation of the controlling document, which interpretation shall be final and binding. City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program - 12 - DATED the day and year set forth above. CITY OF FEDERAL WAY: ' Ferrell,Mayor 13325 8th Avenue South Federal Way, WA 98003-6325 APPROVED AS TO FORM: ATTEST: NXJS �k� &44�r J. Ryan Call, City Attorney pl anie Courtney, CMC .ity Clerk TONY LIND PAVING C By: Its: Owner f 23048 172nd Avenue SE Kent, WA 98042 STATE OF WASHINGTON ) ) ss. COUNTY OF K1,,0 ) J On this day personally appeared before me Tony Lind, to me known to be the Owner of Tony Lind Paving, LLC that executed the foregoing instrument, and acknowledged the said instrument to be the free and voluntary act and deed of said limited liability company, for the uses and purposes therein mentioned, and on oath stated that he/she was authorized to execute said instrument. GIVEN my hand and official seal this /a day of Vl , 20 p� 4 iS �•'Y dd� 7� (typed/printe arne of notary) Notary Public in and for the State of Washington. My commission expires__ L71 City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program - 13 - EXHIBIT "A" SCOPE OF WORK Perform discretionary work for services listed in Exhibit A, Schedule A of installing traffic calming devices such as painted extruded curb, painted, speed humps, and a traffic circle island at locations and in quantities to be provided by staff at a future date. Also perform discretionary work listed in Exhibit A, Schedule B, which may consist of installation and/or removal of pre- cast, block, or extruded traffic curb, installation of CSTC and HMA, installation and/or removal of speed humps, speed tables, and raised crosswalks, installation and/or removal of pedestrian refuge islands, curb ramps, concrete sidewalk, or concrete curb and gutter, and installation of traffic circle islands. Work orders showing locations and quantity estimates to be provided by staff at future dates. NOTE: All entries shall be written in ink or typed. Unit prices for all items, all extensions, and total amount of bid shall be shown. Enter unit prices in numerical figures only, in dollars and cents to two (2) decimal places (including for whole dollar amounts). All figures must be clearly legible. Bids with illegible figures in the unit price column will be regarded as nonresponsive. Where conflict occurs between the unit price and the total amount specified for any item, the unit price shall prevail, and totals shall be corrected to conform thereto. The Bidder shall complete this entire Bid Form or this bid may be considered non-responsive. The City may correct obvious mathematical errors. The City of Federal Way reserves the right to reject any and all bids, waive any informalities or minor irregularities in the bidding, and determine which bid or bidder meets the criteria set forth in the bid documents. 5CF]FDULE A E:x.m 7lo of T 'Projects As Dose ilMd In 04 Work Item -Typical Unit Unit Price Multiplier Total Project B-3 Extruded Curb.Painted WSDOT Standard Specification Section 8-07(except no rebar) 50 c 50 COFW Development Standard 3-4A COFW SP 8-04 LF 23-00 $1,1 50.00 0-7 Speed Hump,Compii,te(includes toe grind and temporary markings Permanent signing and markings by others.)COFW 4 4 :Development Standard 3-28,COFW SP B-32 EA $2,800.00 $11,200.00 B-16s TratTlc Circle Island,Complete(Includes painted precasi curb, pavement removal,monument case d valve box adjustment 324001 topsoil Each(1)island by Circle Diameter range in feet) COFW Diameter1 1 �Develoomenl Standard 3-59 COFW SP 8.05 Circle EA $8.600.00 $8,600.00 Total of Schedule A $20.950.00 Must tie tne umomfted,is B ince Exhibit A,Schedule A Notes: 1 All items shall include in the price any required layout,mobilization,traffic control,roadside cleanup,or any other incidentals. 2 All permanent pavement markings for traffic calming devices shall be done by others. 3 All permanent signs for traffic calming devices are done by others. 4 Any removal of pavement markings will be done by others. 5 Unit Price is per Each for a Traffic Circle Island,Complete within the circle diameter range,in feet. COMPANY NAME Tony Lind Paving LLC City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program 14 - SCHEDULE 0 [DlcFvVGPss(y Work Orders As Detcn4ed in Scoov u1 W00k N. al t]rarntllY Rargs UnR Unit Prlp Multiplier Ta 0-1 PfwCaMTnftCnr%Pointed W 10C LF $41�_M_ w2,300.00 WSOOT Standard spednnua,Section 11.Or oo 101 SLF 101 $4,646.00 COFW Spew PmWbn 6.07 501. LF9�00 501 19,539.00 8-2 Black Traflle Curb,Pdnad - _ _ _ 50 100 LF $56.00 50 $2,800.00 COFW Development Standard 3-4 101 500 LF M9.00 101 $4,949.00 COFW Spacial Provision 6-07 501. LF 6.00 501 ,046J0n B-3 I E:fn�dad Ctare.Pahad so , �F �O $1,150,00 WSDOT SL Spec.6-07,and SL Pan F-10.42(maps no mbar) ,u, 500 LF 101 $2121.00 COFW Devabprrerd Standard 3-4A.Cottle SP 844 501 • LF 501 $9.51900 er R«oow Pis Cast Sleek,«i iwaa Cwb(newds aavrwl 50 100 LF S0 $500.00 patching N necessary)WSOOT Stardard SpecNeallon section 2- 101 500 LF $9,00101 $909.00 02.3(3).COFW SP 6-07 501• LF - 501 $4.008.00 �.w. ss Crust"awnaano Top Course,kKwde Naw 1 5 TON $1 1 00.00 WSDOT Standard Spadlln0on Section 4-04.9-03 a 1S TON S45,00 6 $270.00 COFW Special Provision 4.04 t5' TON S4 15 $600.00 e-e 1wA calla 1Ir eFiz , s TON 400.OL1- ' $400.00 WSDOT Standard Specification section 5-04 6 15 TON $350.00. 6 $2,100.00 C�FW Special ft ft m 501 1S• TON $300.00 15 --$4 500,00 6.7 ASpeed Hnnp,ConW§o*(Includes tea grind and temporary 1 EA $2_8pC]'C)0 1 $2,800.00 mwkkgs Permanent signii and markings by otlrors.)OOFW Deveioomanl Standard 3-26.COFW SP 6.32 3 EA ..Q .� 2 $5,600.00 - 2.8 513 200 01) 04 Spew Tabs,Car plets(Ind dee be Wind and tamporsry 1 EA $3 ED.Q1 $3,600.00 markings Pennenent agning and markings by othem) 2 3 EA $3,600,00 2 $7,200.00 COFW Devewpram Standard 3.27A,COFW SP 633 4+ EA $3,400.00 4 $13.600.00 11-9 Raised Crosswalk,Catnpeta(kndudes kos grind and Iaapon" 1 EA 3. OQ00. 1 $3,700.00 nwd*Vs Pernanant signing and markings by oders.)COFW 2 3 EA $3,700.00 2 $7,400.00 Developmaru standard 3-27,COFW SP 6-33 4• FA 4 $14 000.00 .0-10 Rernova Speed Hump,Speed Table,or Raised CrosswaNk 1 Ell . M) 1 _$2,000.00 (Include asphalt patching d narxseary) 2 3 EA _$2_000_0(12 $4,000.00 COFW SP 2-02.3(3xr) 4+ EA _$Q00,00 �4..._._._ -$8.000.00 8-11 Pedestrian RAW Island,Corrplea(Irndudes delectable 1 EA S12M0,00 1 $12,900.00 warning so")COFW SP 54M 2 3 EA 2 $25,800.00 COFW DevebMwM Standard 3-56 4* EA 5_12 5�0o.Qa 4 $50.000.00 0.12 Remury Patlnstrian Re4uge Se,wW+ ,Compl t* 1 EA % 1 $C r000 00 �.L� V ( Ian r ) 2 3 EA $5 000.00 2 $12,000.00 COFW SP 2-02.3(3x7) 4- LCL _ 4 $_23,200.00 e-13 Ranowe L Replace Carcina Curb Rue C, pltla 1 EA -&AMa 0Q_'. $4,200.00 COFW DevebpmarStardard 3-0.3-GA,3-0B.3-10.3-10A.3-11, 2 3 0-0 2 $8,400.00 JWSDOT Slid Plan F-40 14(Up ID 25 RFW)COSP 8.04.8-14 4« 00_ML 4 $16,000,00 8-14 Ranee a Replace Canaea Bidasragk.Conplaa .rasa. . � S is s - sr ._S275_O $1,375.00 COFW Devabpmart Standard 3-3 a 3-12 11 S0 SY 11 $2,750.00 COFW Special PmvMm 6.04.11.14 51 + Sy 51 $11,475.00 s-15 Ramon d Rsplaee Comae Curb a ower,Complete 10 30 10 $1,000.00 {include,sawcu",disposal,a~patching)COFW Dag 3-4,3 LF $2,945.00 - 4A a WSOOT Shed Spec 5-04.3(14).COFW SP 8-04 31 tOC LF 5 95.00 31 101 + LF -$90.00 `101 $9090.00 TraRle Ckda Island.Cankplets(Includes pakdad Wa-uat aeb,� L, a t,.nu �4,'tLp EA , $7,200.00 pavement renaval.rnorwane nt rase a valve boat adjustmenit. i r-24^ EA j7p,900.00 1 $7,900.00 IDPacll Each(1)Island by Circle Diameter range In ate)COFW Davelopnars Standard 3-59.COFW SP 8-05 c.1' 32 t EA 1I-se.800.00 Total of ft oOkdo s 377 592.0 Adlnaad coal of Schedule es x 0.10 3 98 542.00.2p 3 Trull(Tcral of Sctwil A+04"Wd Total of Schadule B) 38.395.20 COMPANY NAME Tony Lind Paving,LLC City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program - 15 - Schedule B Notes: 6 Line Item Total for Schedule B are calculated by multiplying the quantity range minimum by the unit price,except for item B-16. 7 Unit Price is per Each for a Traffic Circle Island,Complete within the circle diameter range,in feet. 8 Adjusted(weighted)Total reflects likelihood that only 10%of dlscretlonary work in Schedule B will be requested. Note: The contract resulting from this RFB Is mainly for future discretionary work orders;exact quantities and locations are unknown. The City's recent historical average for this work is approximately$25,000 per year. Discretionary work orders are typically issued multiple times throughout the calendar year. COMPANY NAME Tonv Lind Pavinl?. LLC City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program 16 - EXHIBIT "B" CONTRACT CHANGE ORDER AGREEMENT PROJECT NUMBER CHANGE ORDER NUMBER EFFECTIVE DATE PROJECT TITLE CONTRACTOR SUMMARY OF PROPOSED CHANGES: The time provided for completion in the Contract is ❑ Unchanged ❑ Increased ❑ Decreased by Calendar Days. This Document shall become an Amendment to the Contract and all provisions of the Contract not amended herein will apply to this Change Order. Will this change affect expiration or extent of Insurance coverage? —1 Yes❑ No If"Yes"Will the Policies Be Extended? ❑ Yes❑ No PRICE CHANGE LUMP SUM: INCREASE$ DECREASE$ UNIT PRICE: THE ITEMS ARE APPROXIMATE OR ESTIMATED QUANTITIES INVOLVED IN THIS CHANGE ITEM NO. ITEM QTY. UNIT PRICE ADD OR DELETE TOTAL NET CONTRACT: INCREASE$ DECREASE$ STATEMENT: Payment for the above work will be in accordance with applicable portions of the standard specifications, and with the understanding that all materials, workmanship and measurements shall be in accordance with the provisions of the standard specifications, the contract plans, and the special provisions governing the types of construction. DEPARTMENT RECAP TO DATE: ORIGINAL CONTRACT AMOUNT $ PREVIOUS CHANGE ORDERS $ THIS CHANGE ORDER $ *ADJUSTMENTS $ NEW CONTRACT AMOUNT $ CONTRACTOR'S SIGNATURE DATE City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program 17 — DIREC'TOR'S SIGNATURE DATE ADJUSTMENTS CHANGE ORDER ESTIMATE IS HEREBY ❑INCREASED $ ❑DECREASED $ PAY THIS ADJUSTED AMOUNT: $ DIRECTOR'S SIGNATURE DATE City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program 18 - EXHIBIT "C" CONTRACTOR'S RETAINAGE OPTION IDENTIFICATION AND DESCRIPTION Project Title: 2020-2021 NTS Program RFB No: Contractor: Tony Lind Paving, LLC GENERAL REQUIREMENTS 1. In accordance with applicable State Statutes, a contract retainage not to exceed five percent of the moneys earned by the contractor will be reserved by the City. 2. All investments selected are subject to City approval. 3. The final disposition of the contract retainage will be made in accordance with applicable State Statutes. CONTRACTOR'S INSTRUCTIONS Pursuant to RCW 60.28.011 I hereby notify the City of Federal Way of my instructions for the retainage withheld under the terms of this contract: Option 1: Retained in a fund by the City of Federal Way. No interest will be paid to the contractor. 0 Option 2: Deposited in an interest bearing account in a bank, mutual savings bank, or savings and loan association. Interest paid to the contractor. Contractor shall have the bank (or other) execute a separate "City of Federal Way Retainage Bank Acceptance Agreement" upon contract award. The City will provide the agreement to the Contractor if this option is selected. 0 Option 3: Placed in escrow with a bank or trust company. Contractor shall execute, and have escrow account holder execute a separate "City of Federal Way Construction Retainage Escrow Agreement" upon contract award. The City will provide the agreement to the Contractor if this option is selected. All investments are subject to City approval. The cost of the investment program, and risk thereof, is to be borne entirely by the contractor. 0 Option 4: Contractor shall submit a "Retainage Bond"on City-provided form (Exhibit D of this Agreement). k Contractor�gnature Date City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program - 19 - EXHIBIT "D" RETAINAGE BOND TO CITY OF FEDERAL WAY 2020-2021 NEIGHBORHOOD TRAFFIC SAFETY PROGRAM KNOW ALL PERSONS BY THESE PRESENTS that we, the undersigned, as principal ("Principal', and a Corporation organized and existing under the laws of the State of , as a surety Corporation, and qualified under the laws of the State of Washington to become surety upon bonds of Contractors with Municipal Corporations, as surety ("Surety's, are jointly and severally held and firmly bonded to the City of Federal Way ( City's in the penal sum of: ($ ) for the payment of which sum we bind ourselves and our successors, heirs, administrators or personal representatives, as the case may be. A. This obligation is entered into in pursuant to the statutes of the State of Washington and the ordinances, regulations, standards and policies of the City, as now existing or hereafter amended or adopted. B. Pursuant to proper authorization, the Mayor is authorized to enter into a certain contract with the Principal, providing for the Project, which contract is incorporated herein by this reference C'Contract's, and C. Pursuant to State law, Chapter 60.28 RCW, the City is required to reserve from the monies earned by the Principal pursuant to the contract, a sum not to exceed five percent (5%), said sum to be retained by the City as a trust fund for the protection and payment of any person or persons, mechanic, subcontractor or material men who shall perform any labor upon such contract or the doing of such work, and all persons who shall supply such person or persons or subcontractors with provisions and supplies for the carrying on of such work, and the State with the respect to taxes imposed pursuant to Title 82 RCW which may be due from said Principal. Every person performing labor or furnishing supplies towards completion of said improvement or work shall have a lien on said monies so reserved, provided that such notice of the lien of such claimant shall be given in the manner and within the time provided in RCW 39.08.030 as now existing and in accordance with any amendments that may hereafter be provided thereto; and D. State law further provides that with the consent of the City, the Principal may submit a bond for all or any portion of the amount of funds retained by the public body in a form acceptable to the public body conditioned upon such bond any proceeds therefrom being made subject to all claims and liens and in the same manner and priority as set forth retained percentages pursuant to Chapter 60.28 RCW; and E. The Principal has accepted, or is about to accept,the Contract, and undertake to perform the work therein provided for in the manner and within the time set forth,for the amount of$ ; and F. The City is prepared to release any required retainage money previously paid by the Principal prior to acceptance and successful operation and fulfillment of all other terms of said contract upon being indemnified by these presents, NOW, THEREFORE, if the Principal shall perform all the provisions of the Contract in the manner and within the time period prescribed by the City, or within such extensions of time as may be granted under the Contract, and shall pay all laborers, mechanics, subcontractors and material men or women, and all persons who shall supply the Principal or subcontractors with provisions and supplies for the carrying on of said work, and if the Principal shall pay to the State all taxes imposed pursuant to Title 82 RCW which may be due from such Principal as a result of this contract then and in the event this obligation shall be void; but otherwise it shall be and remain in full force and effect. And the Surety, for value received, hereby further stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract or to the work to be performed thereunder or the specifications accompanying the same shall in any way affect its obligation on this bond, and it does hereby waive notice of any change, extension of time, alterations or additions to the terms of the Contract or to the Work. - 20 - City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program The Surety hereby agrees that modifications and changes may be made in the terms and provisions of the Contract without notice to Surety, and any such modifications or changes increasing the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this Retainage Bond in a like amount, such increase, however, not to exceed twenty-five percent(25%) of the original amount of this bond without consent of the Surety. Within forty-five (45) days of receiving notice that the Principal has defaulted on all or part of the terms of the Contract,the Surety shall make written commitment to the City that it will either: (a) cure the default itself within a reasonable time period, or(b)tender to the City, the amount necessary for the City to remedy the default, including legal fees incurred by the City, or(c) in the event that Surety's evaluation of the dispute is not complete or in the event the Surety disputes the City's claim of default, the Surety shall notify the City of its finding and its intent, if any, to interplead. The Surety shall then fulfill its obligations under this bond, according to the option it has elected. Should Surety elect option (a)to cure the default, the penal sum of the Bond shall be reduced in an amount equal to the costs actually incurred by the Surety in curing the default. If the Surety elects option (b), then upon completion of the necessary work, the City shall notify the Surety of its actual costs. The City shall return, without interest, any overpayment made by the Surety and the Surety shall pay to the City any actual costs which exceed the City estimate, limited to the bond amount. Should the Surety elect option (c), the Parties shall first complete participation in mediation, described in the below paragraph, prior to any interplead action. In the event a dispute should arise between the Parties to this Bond with respect to the City's declaration of default by the Principal, the Parties agree to participate in at least four hours of mediation to resolve said dispute. The Parties shall proportionately share in the cost of the mediation. The mediation shall be administered by Judicial Dispute Resolution, LLC, 1425 Fourth Avenue, Suite 300, Seattle, Washington 98101. The Surety shall not interplead prior to completion of the mediation. The parties have executed this instrument under their separate seals this day of 20the name and corporate seal of each corporate party hereto affixed, and these presents duly signed by its undersigned representatives pursuant to authority of its governing body. CORPORATE SEAL: PRINCIPAL By _ _.. _,... Title: Address: CORPORATE SEAL: SURETY By: Attorney-in-Fact (Attach Power of Attorney) Title: Address: - 21 - City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program CERTIFICATES AS TO CORPORATE SEAL I hereby certify that I am the (Assistant) Secretary of the Corporation named as Principal in the within bond; that ., who signed the said bond on behalf of the Principal, was of said Corporation; that I know his or her signature thereto is genuine, and that said bond was duly signed, sealed, and attested for and in behalf of said Corporation by authority of its governing body. Secretary or Assistant Secretary I hereby certify that I am the (Assistant) Secretary of the Corporation named as Surety in the within bond; that 1 who signed the said bond on behalf of the Surety, was of the said Corporation; that I know his or her signature thereto is genuine, and that said bond was duly signed, sealed, and attested for and in behalf of said Corporation by authority of its governing body. Secretary or Assistant Secretary APPROVED AS TO FORM: I Ryan Call, City Attorney — 22 — City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program EXHIBIT "E" NOTICE TO LABOR UNIONS OR OTHER EMPLOYMENT ORGANIZATIONS NONDISCRIMINATION IN EMPLOYMENT TO: (Name of Union or Organization) The undersigned currently holds contract(s) with involving funds or credit of the City of Federal Way, Washington, or (a) subcontract(s) with a prime contractor holding such contract(s). You are advised that, under the provisions of the above contract(s) or subcontract(s) and in accordance with Section 202 of Executive Order 11246 dated September 24, 1965, the undersigned is obliged not to discriminate against any employee or applicant of employment because of race, color, creed or national origin. This obligation not to discriminate in employment includes,but is not limited to, the following: EMPLOYMENT, UPGRADING, TRANSFER OR DEMOTION RECRUITMENT AND ADVERTISING RATES OF PAY OR OTHER FORMS OF COMPENSATION SELECTION FOR TRAINING INCLUDING APPRENTICESHIP, LAYOFF OR TERMINATION This notice is furnished to you pursuant to the provisions of the above contract(s) or subcontractor(s) and Executive Order 11246.. Copies of this Notice will be posted by the undersigned in conspicuous places available to employees or applicants for employment. Complaints may be submitted to: Naveen Chandra P.E. City of Federal Way 33325 8`h Avenue South Federal Way, WA 98003 (Contractor or subcontractor) Date - 23 - City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program EXHIBIT "F" CERTIFICATE OF INSURANCE 24 City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program Client#: 183199 TONYLIND ACORDTM CERTIFI XTE OF LIABILITY INSUr .NCE DATE(MM/DD/YYYY) 6/03/2020 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer any rights to the certificate holder in lieu of such endorsement(s). PRODUCER i AME, Nicole Anderson Propel Insurance PHONEFAX (A/C.No.E-01'800 499-0933 AC_No,. 866 577-1326 Tacoma Commercial Insurance E-MAIL $ , nicole.anderson@propelinsurance.com 1201 Pacific Ave,Suite 1000 INSURER(S)AFFORDING COVERAGE NAIL& Tacoma,WA 98402 INSURER A:Union Insurance Company 25844 INSURED Tony Lind Paving, LLC INSURER B:The Ohio Casualty Insurance Company 24074 INSURER C 23048 172nd Avenue SE Kent,WA 98042 INSURER D: INSURER E: INSURER F COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSRJ TYPE OF INSURANCE ADDL UBR POLICY EFF POLICY EXP LTR POLICY NUMBER MM 00:YYYY) imr&DDryyyyl LIMITS A X COMMERCIAL GENERAL LIABILITY X X CPA603236123 01/01/2020 01/01/2021 EACH OCCURRENCE S1,000,000 CLAIMS-MADE u OCCUR DpMnAGFT9FRENT rrer-a s300.000 PD Ded:i 000 MED EXP(Any oneperson) $10,000 PERSONAL&ADV INJURY $1.000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000 000 POLICY LJ JECOT U LOC PRODUCTS-COMP/OP AGG s2.000.000 OTHER: AUTOMOBILE LIABILITY 11 •1 1-�=1NGLE LIN11T A _ X X CPA603236123 01/01/2020 01/01/2021 'E;;'',.::', ::,.. e1 000.000 X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY(Per accident) $ HIRED NON-OWNED PF40PE-1Tf f_1+t f.1 A!; X AUTOS ONLY �X_ AUTOS ONLY LF" N+ $ A X UMBRELLA LIAR X OCCUR X X CPA60323612301/01/2020 01/01/2021 EACH OCCURRENCE $5,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE V5,000,000 De() I X 1-FTENTION 0 $ A WORKERS COMPENSATION CPA603236123 1/01/2020 01/01/2021 PERt ITF OFTI H- AND EMPLOYERS'LIABILITY YIN 4N;"r_.O-Ric-riF•�,t,aT';ER•E:?_L.LTi%iE� �� WA STOP GAP E.L EACH ACCIDENT 0.000,000 SFr GERWEMBER EXCLIED" t N i N/A (Mandatory in NH) E L.DISEASE-EA EMPLOYEE $1.000,000 If yes,describe under DESCRIPTION OF OPFRATIONS below E L.DISEASE-POLICY LIMIT $1.000,000 B Leased/Rented BM059122791 1/01/2020 01/01/2021 $375,000 Limit Equipment $1,000 Deductible DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) RE:2020-2021 Neighborhood Traffic Safety(NTS) Program City of Federal Way, its officers,officials,employees,volunteers and agents Additional Insured Status applies per attached form(s).Waiver of Subrogation applies per attached form(s). Primary non-contributory applies per attached form(s). CERTIFICATE HOLDER CANCELLATION Cit of Federal Way SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City y THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 33325 8th Ave S ACCORDANCE WITH THE POLICY PROVISIONS. Federal Way,WA 98003 AUTHORIZED REPRESENTATIVE ©1988-2015 ACORD CORPORATION.All rights reserved. ACORD 25(2016/03) 1 of 1 The ACORD name and logo are registered marks of ACORD #S4155268/M3942703 CRS01 EXHIBIT "G" CITY OF FEDERAL WAY PERFORMANCE/PAYMENT BOND Bond No. NWA1450 KNOW ALL PEOPLE BY THESE PRESENTS: We,the undersigned Tony Lind Paving LLC ("Principal")and Merchants National Bonding, Inc. _ the undersigned corporation organized and existing under the laws of the State of Iowa and legally doing business in the State of Washington as a surety("Surety"),are held and firmly bonded unto the City of Federal Way,a Washington municipal corporation("City")in the penal sum of Forty Thousand and no/100THS Dollars and no/100($40.000.00 ) for the payment of which we firmly bind ourselves and our legal representatives,heirs,successors and assigns,jointly and severally. This obligation is entered into pursuant to the statutes of the State of Washington and the ordinances, regulations, standards and policies of the City,as now existing or hereafter amended or adopted. The Principal has entered into an Agreement with the City dated 4-10 20A0 for 2020-2021 Neighborhood Traffic Safety Project. NOW, THEREFORE, if the Principal shall perform all the provisions of the Agreement in the manner and within the time period prescribed by the City, or within such extensions of time as may be granted under the Agreement, and shall pay all laborers, mechanics, subcontractors and material men or women, and all persons who shall supply the Principal or subcontractors with provisions and supplies for the carrying on of said work, and shall hold the City, their officials, agents, employees and volunteers harmless from any loss or damage occasioned to any person or property by reason of any carelessness or negligence on the part of the Principal, or any subcontractor in the performance of said work, and shall indemnify and hold the City harmless from any damage or expense by reason of failure of performance as specified in the Agreement within a period of one(1)year after its final acceptance thereof by the City, then and in the event this obligation shall be void;but otherwise,it shall be and remain in full force and effect. And the Surety,for value received,hereby further stipulates and agrees that no change,extension of time,alteration or addition to the terms of the Agreement or to the work to be performed thereunder or the specifications accompanying the same shall in any way affect its obligation on this bond, and it does hereby waive notice of any change, extension of time, alterations or additions to the terms of the Agreement or to the Work. The Surety hereby agrees that modifications and changes may be made in terms and provisions of the Agreement without notice to Surety,and any such modifications or changes increasing the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this Performance Bond in a like amount, such increase,however,not to exceed twenty- five percent(25%)of the original amount of this bond without the consent of the Surety. Within forty-five(45)days of receiving notice that the Principal has defaulted on all or part of the terms of the Agreement,the Surety shall make a written commitment to the City that it will either: (a) cure the default itself within a reasonable time period, or(b)tender to the city, the amount necessary for the City to remedy the default, including legal fees incurred by the City, or(c) in the event that Surety's evaluation of the dispute is not complete or in the event the Surety disputes the City's claim of default,the Surety shall notify the City of its finding and its intent,if any,to interplead.The Surety shall then fulfill its obligations under this bond, according to the option it has elected. Should Surety elect option (a)to cure the default, the penal sum of the Bond shall be reduced in an amount equal to the costs actually incurred by the Surety in curing the default. If the Surety elects option (b), then upon completion of the necessary work, the City shall notify the Surety of its actual costs. The City shall return,without interest, any overpayment made by the Surety and the Surety shall pay to the City any actual costs which exceed the City estimate, limited to the bond amount. Should the Surety elect option (c), the Parties shall first complete participation in mediation,described in the below paragraph,prior to any interplead action. - 25 - City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program In the event a dispute should arise between the Parties to this Bond with respect to the City's declaration of default by the Principal, the Parties agree to participate in at least four hours of mediation to resolve said dispute. The Parties shall proportionately share in the cost of the mediation. The mediation shall be administered by Judicial Dispute Resolution,LLC, 1425 Fourth Avenue, Suite 300, Seattle, Washington 98101. The Surety shall not interplead prior to completion of the mediation. DATED this 9th day of June —M20 . CORPORATE<< PRINCIPAL: PRINCIPAL Tony Lind Paving LLC NO By: S4!�Sy RYs ' By. Ton Lindl `� �, Its: Owner Pug = 23048 172°d Ave SE X85216 fi;,�� Kent,WA 98042 (253)630-7612 Z-E OF NN STATE OF WASHINGTON ) )ss. COUNTY OF King ) On this day personally appeared before me Tony Lind to me known to be the Owner of Tony Lind Paving,LLC that executed the foregoing instrument, and acknowledged the said instrument to be the free and voluntary act and deed of said limited liability company, for the uses and purposes therein mentioned, and on oath stated that he/she was authorized to execute said instrument. GIVEN my hand and official seal this IC)ck�,day of �alu 20" Notary's signature �� ' ,� Notary's printed name i1 Notary Public in and for the State a asliin-ton. My commission expires C'�j CORPORATE SEAL OF SURETY: t*,•yi�,�r1�e�++�.r„h STY Merchants National Bonding, Inc. 1`"'''' .r e. Attorney-in-Fact Y (Attach Power of Attorney) Heather L.Allen �► (Name of Person Executing Bond) '• ~' a.+ ► 5400 Carillon Point '"•rf =�`'•,.....•• (Address) 'W*F#11101i V%6 _ Kirkland,WA 98033 (425)576-4078 (Phone) APPROVED AS TO FORM: ag-c, J.Ryan Vall,City Attorney - 26 - City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program ERCHAN�rs��', BONDING COMPANY.. POWER OF ATTORNEY Know All Persons By These Presents,that MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING, INC., both being corporations of the State of Iowa(herein collectively called the"Companies")do hereby make,constitute and appoint,individually, Aliceon A Keltner;Annelies M Richie;Brandon K Bush;Brent E Heilesen;Carley Espiritu;Christopher Kinyon;Cynthia L Jay;Eric A Zimmerman; Erica E Mosley;Heather L Allen;Holli Albers;James B Binder;Jamie L Marques;Karen C Swanson;Kyle Joseph Howat;Tamara A Ringeisen their true and lawful Attorney(s)-in-Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. This Power-of-Attorney is granted and is signed and sealed by facsimile under and by authority of the following By-Laws adopted by the Board of Directors of Merchants Bonding Company (Mutual) on April 23, 2011 and amended August 14, 2015 and adopted by the Board of Directors of Merchants National Bonding,Inc.,on October 16,2015. "The President, Secretary, Treasurer, or any Assistant Treasurer or any Assistant Secretary or any Vice President shall have power and authority to appoint Attorneys-in-Fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and undertakings,recognizances,contracts of indemnity and other writings obligatory in the nature thereof." "The signature of any authorized officer and the seal of the Company may be affixed by facsimile or electronic transmission to any Power of Attorney or Certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligations of the Company,and such signature and seal when so used shall have the same force and effect as though manually fixed." In connection with obligations in favor of the Florida Department of Transportation only,it is agreed that the power and aut hority hereby given to the Attorney-in-Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations in favor of the Kentucky Department of Highways only,it is agreed that the power and authority hereby given to the Attorney-in-Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner- Department of Highways of the Commonwealth of Kentucky at least thirty(30)days prior to the modification or revocation. In Witness Whereof,the Companies have caused this instrument to be signed and sealed this 11th day of February 2020 .��110NgL•••, .`o��G Co . " .- pojy S �O; `d�' �QQ� . MERCHANTS BONDING COMPANY(MUTUAL) 4 %� ^� 4_,yam MERCHANTS NATIONAL BONDING.INC. .T � 2003 :� y 1933 c, I3y STATE OF IOWA �U" ""° COUNTY OF DALLAS ss. On this 11th day of February 2020 before me appeared Larry Taylor, to me personally known, who being by me duly sworn did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.; and that the seals affixed to the foregoing instrument are the Corporate Seals of the Companies;and that the said instrument was signed and sealed in behalf of the Companies by authority of their respective Boards of Directors. 11131�tAt s POLLY MASON o s Commission Number 750576 My Commission Expires ,gyp January 07, 2023 Notary Public (Expiration of notary's commission does not invalidate this instrument) I,William Warner,Jr.,Secretary of MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING,INC.,do hereby certify that the above and foregoing is a true and correct copy of the POWER-OF-ATTORNEY executed by said Companies,which is still in full force and effect and has not been amended or revoked. In Witness Whereof, I have hereunto set my hand and affixed the seal of the Companies on this i day of ...... T co 2003 ' ¢ 1933 Secretary rya. : POA 0018 (1/20) """�" EXHIBIT "H" TITLE VI ASSURANCES During the performance of this contract, the contractor/consultant, for itself, its assignees and successors in interest (hereinafter referred to as the "contractor's agrees as follows: 1. Compliance with Regulations The contractor shall comply with the Regulations relative to non-discrimination in federally assisted programs of United States Department of Transportation (USDOT), Title 49, Code of Federal Regulations, part 21, as they may be amended from time to time, (hereinafter referred to as the Regulations), which are herein incorporated by reference and made a part of this contract. 2. Non-discrimination The contractor, with regard to the work performed by it during the contract, shall not discriminate on the grounds of race, color, sex, or national origin in the selection and retention of sub- contractors, including procurement of materials and leases of equipment. The contractor shall not participate either directly or indirectly in the discrimination prohibited by Section 21.5 of the Regulations, including employment practices when the contract covers a program set forth in Appendix B of the Regulations. 3. Solicitations for Sub-contracts, Including Procurement of Materials and Equipment In all solicitations either by competitive bidding or negotiations made by the contractor for work to be performed under a sub-contract, including procurement of materials or leases of equipment, each potential sub-contractor or supplier shall be notified by the contractor of the contractor's obligations under this contract and the Regulations relative to non-discrimination on the grounds of race, color, sex, or national origin. 4. Information and Reports The contractor shall provide all information and reports required by the Regulations or directives issued pursuant thereto, and shall permit access to its books, records, accounts, other sources of information, and its facilities as may be determined by the contracting agency or the appropriate federal agency to be pertinent to ascertain compliance with such Regulations, orders and instructions. Where any information required of a contractor is in the exclusive possession of another who fails or refuses to furnish this information, the contractor shall so certify to WSDOT or the USDOT as appropriate, and shall set forth what efforts it has made to obtain the information. S. Sanctions for Non-compliance In the event of the contractor's non-compliance with the non-discrimination provisions of this contract, the contracting agency shall impose such contract sanctions as it or the USDOT may determine to be appropriate, including, but not limited to: Withholding of payments to the contractor under the - 27 - City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program contract until the contractor complies, and/or; Cancellation, termination, or suspension of the contract, in whole or in part 6. Incorporation of Provisions The contractor shall include the provisions of paragraphs (1) through (5) in every sub-contract, including procurement of materials and leases of equipment, unless exempt by the Regulations, or directives issued pursuant thereto. The contractor shall take such action with respect to any sub- contractor or procurement as the contracting agency or USDOT may direct as a means of enforcing such provisions including sanctions for non-compliance. Provided, however, that in the event a contractor becomes involved in, or is threatened with, litigation with a sub-contractor or supplier as a result of such direction, the contractor may request WSDOT enter into such litigation to protect the interests of the state and, in addition, the contractor may request the USDOT enter into such litigation to protect the interests of the United States. - 28 - City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program EXHIBIT "I" PREVAILING RATE OF WAGE (SEE ATTACHED). - 29 - City of Federal Way 2020 2020-2021 Neighborhood Traffic Safety Program Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Overtime Codes Overtime calculations are based on the hourly rate actually paid to the worker.On public works projects,the hourly rate must be not less than the prevailing rate of wage minus the hourly rate of the cost of fringe benefits actually provided for the worker. 1. ALL HOURS WORKED IN EXCESS OF EIGHT(8)HOURS PER DAY OR FORTY(40) HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. B. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. C. The first two (2)hours after eight(8)regular hours Monday through Friday and the first ten(10)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other overtime hours and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. D. The first two(2)hours before or after a five-eight(8)hour workweek day or a four-ten(10)hour workweek day and the first eight(8)hours worked the next day after either workweek shall be paid at one and one-half times the hourly rate of wage. All additional hours worked and all worked on Sundays and holidays shall be paid at double the hourly rate of wage. E. The first two(2)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. F. The first two(2) hours after eight(8) regular hours Monday through Friday and the first ten (10)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other overtime hours worked,except Labor Day, shall be paid at double the hourly rate of wage.All hours worked on Labor Day shall be paid at three times the hourly rate of wage. G. The first ten(10)hours worked on Saturdays and the first ten(10)hours worked on a fifth calendar weekday in a four- ten hour schedule,shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of ten (10)hours per day Monday through Saturday and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. H. All hours worked on Saturdays(except makeup days if work is lost due to inclement weather conditions or equipment breakdown) shall be paid at one and one-half times the hourly rate of wage. All hours worked Monday through Saturday over twelve(12)hours and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. L All hours worked on Sundays and holidays shall also be paid at double the hourly rate of wage. J. The first two(2) hours after eight(8)regular hours Monday through Friday and the first ten(10)hours on Saturday shall be paid atone and one-half times the hourly rate of wage. All hours worked over ten(10)hours Monday through Saturday,Sundays and holidays shall be paid at double the hourly rate of wage. K. All hours worked on Saturdays and Sundays shall be paid at one and one-half times the hourly rate of wage.All hours worked on holidays shall be paid at double the hourly rate of wage. M. All hours worked on Saturdays(except makeup days if work is lost due to inclement weather conditions)shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. N. All hours worked on Saturdays(except makeup days)shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. 1 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Overtime Codes Continued 1. O. The first ten(10)hours worked on Saturday shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays,holidays and after twelve(12)hours,Monday through Friday and after ten(10)hours on Saturday shall be paid at double the hourly rate of wage. P. All hours worked on Saturdays(except makeup days if circumstances warrant)and Sundays shall be paid at one and one-half times the hourly rate of wage.All hours worked on holidays shall be paid at double the hourly rate of wage. Q. The first two (2) hours after eight (8) regular hours Monday through Friday and up to ten (10) hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of ten(10) hours per day Monday through Saturday and all hours worked on Sundays and holidays(except Christmas day)shall be paid at double the hourly rate of wage.All hours worked on Christmas day shall be paid at two and one-half times the hourly rate of wage. R. All hours worked on Sundays and holidays shall be paid at two times the hourly rate of wage. S. The first two(2)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked on holidays and all other overtime hours worked,except Labor Day, shall be paid at double the hourly rate of wage. All hours worked on Labor Day shall be paid at three times the hourly rate of wage. U All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays and holidays (except Labor Day)shall be paid at two times the hourly rate of wage. All hours worked on Labor Day shall be paid at three times the hourly rate of wage. V. All hours worked on Sundays and holidays (except Thanksgiving Day and Christmas day) shall be paid at one and one-half times the hourly rate of wage. All hours worked on Thanksgiving Day and Christmas day shall be paid at double the hourly rate of wage. W. All hours worked on Saturdays and Sundays (except make-up days due to conditions beyond the control of the employer))shall be paid at one and one-half times the hourly rate of wage.All hours worked on holidays shall be paid at double the hourly rate of wage. X. The fust four(4)hours after eight(8)regular hours Monday through Friday and the first twelve(12)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked over twelve (12)hours Monday through Saturday, Sundays and holidays shall be paid at double the hourly rate of wage. When holiday falls on Saturday or Sunday, the day before Saturday, Friday, and the day after Sunday, Monday, shall be considered the holiday and all work performed shall be paid at double the hourly rate of wage. Y. All hours worked outside the hours of 5:00 am and 5:00 pm (or such other hours as may be agreed upon by any employer and the employee)and all hours worked in excess of eight(8)hours per day(10 hours per day for a 4 x 10 workweek)and on Saturdays and holidays(except labor day)shall be paid at one and one-half times the hourly rate of wage.(except for employees who are absent from work without prior approval on a scheduled workday during the workweek shall be paid at the straight-time rate until they have worked 8 hours in a day(10 in a 4 x 10 workweek)or 40 hours during that workweek.) All hours worked Monday through Saturday over twelve(12)hours and all hours worked on Sundays and Labor Day shall be paid at double the hourly rate of wage. Z. All hours worked on Saturdays and Sundays shall be paid at one and one-half times the hourly rate of wage.All hours worked on holidays shall be paid the straight time rate of pay in addition to holiday pay. 2 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Overtime Codes Continued 2. ALL HOURS WORKED IN EXCESS OF EIGHT(8)HOURS PER DAY OR FORTY(40)HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. B. All hours worked on holidays shall be paid at one and one-half times the hourly rate of wage. C. All hours worked on Sundays shall be paid at one and one-half times the hourly rate of wage. All hours worked on holidays shall be paid at two times the hourly rate of wage. F. The first eight(8)hours worked on holidays shall be paid at the straight hourly rate of wage in addition to the holiday pay. All hours worked in excess of eight(8)hours on holidays shall be paid at double the hourly rate of wage. G. All hours worked on Sunday shall be paid at two times the hourly rate of wage.All hours worked on paid holidays shall be paid at two and one-half times the hourly rate of wage including holiday pay. H. All hours worked on Sunday shall be paid at two times the hourly rate of wage. All hours worked on holidays shall be paid at one and one-half times the hourly rate of wage. O. All hours worked on Sundays and holidays shall be paid at one and one-half times the hourly rate of wage. R. All hours worked on Sundays and holidays and all hours worked over sixty(60)in one week shall be paid at double the hourly rate of wage. U. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage_All hours worked over 12 hours in a day or on Sundays and holidays shall be paid at double the hourly rate of wage. W. The first two(2)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. On a four-day,ten- hour weekly schedule,either Monday thru Thursday or Tuesday thru Friday schedule,all hours worked after ten shall be paid at double the hourly rate of wage. The first eight(8)hours worked on the fifth day shall be paid at one and one-half times the hourly rate of wage. All other hours worked on the fifth, sixth, and seventh days and on holidays shall be paid at double the hourly rate of wage. 3. ALL HOURS WORKED IN EXCESS OF EIGHT(8)HOURS PER DAY OR FORTY(40) HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. A. Work performed in excess of eight(8)hours of straight time per day,or ten (10)hours of straight time per day when four ten (10) hour shifts are established, or forty (40) hours of straight time per week, Monday through Friday, or outside the normal shift, and all work on Saturdays shall be paid at time and one-half the straight time rate. Hours worked over twelve hours(12) in a single shift and all work performed after 6:00 pm Saturday to 6:00 am Monday and holidays shall be paid at double the straight time rate of pay.Any shift starting between the hours of 6:00 pm and midnight shall receive an additional one dollar($1.00)per hour for all hours worked that shift. The employer shall have the sole discretion to assign overtime work to employees.Primary consideration for overtime work shall be given to employees regularly assigned to the work to be performed on overtime situations. After an employee has worked eight(8)hours at an applicable overtime rate, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight(8)hours or more. C. Work performed in excess of eight(8)hours of straight time per day,or ten(10) hours of straight time per day when four ten (10) hour shifts are established, or forty(40) hours of straight time per week, Monday through Friday, or outside the normal shift, and all work on Saturdays shall be paid at one and one-half times the hourly rate of wage. All work performed after 6:00 pm Saturday to 5:00 am Monday and Holidays shall be paid at double the hourly rate of wage. After an employee has worked eight(8)hours at an applicable overtime rate,all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight(8)hours or more. 3 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Overtime Codes Continued 3. E. All hours worked Sundays and holidays shall be paid at double the hourly rate of wage.Each week,once 40 hours of straight time work is achieved,then any hours worked over 10 hours per day Monday through Saturday shall be paid at double the hourly wage rate. F. All hours worked on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sunday shall be paid at two times the hourly rate of wage.All hours worked on paid holidays shall be paid at two and one-half times the hourly rate of wage including holiday pay. H. All work performed on Sundays between March 16th and October 14th and all Holidays shall be compensated for at two (2) times the regular rate of pay. Work performed on Sundays between October 15th and March 15th shall be compensated at one and one half(1-1/2)times the regular rate of pay. J. All hours worked between the hours of 10:00 pm and 5:00 am, Monday through Friday, and all hours worked on Saturdays shall be paid at a one and one-half times the hourly rate of wage.All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. K. Work performed in excess of eight(8)hours of straight time per day,or ten(10)hours of straight time per day when four ten (10)hour shifts are established, or forty(40)hours of straight time per week, Monday through Friday, or outside the normal 5 am to 6pm shift, and all work on Saturdays shall be paid at one and one-half times the hourly rate of wage. All work performed after 6:00 pm Saturday to 5:00 am Monday and Holidays,and all hours worked in excess of twelve(12)hours in a single shift shall be paid at double the hourly rate of wage. After an employee has worked eight (8) hours at an applicable overtime rate, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight(8)hours or more.When an employee returns to work without at least eight(8)hours time off since their previous shift,all such time shall be a continuation of shift and paid at the applicable overtime rate until he/she shall have the eight(8)hours rest period. 4. ALL HOURS WORKED IN EXCESS OF EIGHT(8)HOURS PER DAY OR FORTY(40)HOURS PER WEEK SHALL BE PAID AT ONE AND ONE-HALF TIMES THE HOURLY RATE OF WAGE. A. All hours worked in excess of eight(8)hours per day or forty(40)hours per week shall be paid at double the hourly rate of wage.All hours worked on Saturdays,Sundays and holidays shall be paid at double the hourly rate of wage. B. All hours worked over twelve(12)hours per day and all hours worked on holidays shall be paid at double the hourly rate of wage. C. On Monday through Friday,the first four(4)hours of overtime after eight(8)hours of straight time work shall be paid at one and one half(1-1/2)times the straight time rate of pay,unless a four(4)day ten(10)hour workweek has been established. On a four (4) day ten (10) hour workweek scheduled Monday through Thursday, or Tuesday through Friday,the first two(2)hours of overtime after ten(10)hours of straight time work shall be paid at one and one half(1-1/2)times the straight time rate of pay. On Saturday,the first twelve(12)hours of work shall be paid at one and one half(1-1/2)times the straight time rate of pay,except that if the job is down on Monday through Friday due to weather conditions or other conditions outside the control of the employer,the first ten(10)hours on Saturday may be worked at the straight time rate of pay.All hours worked over twelve(12)hours in a day and all hours worked on Sunday and Holidays shall be paid at two(2)times the straight time rate of pay. 4 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Overtime Codes Continued 4, D. All hours worked in excess of eight(8)hours per day or forty(40)hours per week shall be paid at double the hourly rate of wage. All hours worked on Saturday,Sundays and holidays shall be paid at double the hourly rate of pay.Rates include all members of the assigned crew. EXCEPTION: On all multipole structures and steel transmission lines, switching stations,regulating, capacitor stations, generating plants, industrial plants,associated installations and substations, except those substations whose primary function is to feed a distribution system,will be paid overtime under the following rates: The first two(2)hours after eight(8)regular hours Monday through Friday of overtime on a regular workday,shall be paid at one and one-half times the hourly rate of wage.All hours in excess of ten(10)hours will be at two(2)times the hourly rate of wage. The first eight(8)hours worked on Saturday will be paid at one and one-half(1-1/2)times the hourly rate of wage.All hours worked in excess of eight(8)hours on Saturday,and all hours worked on Sundays and holidays will be at the double the hourly rate of wage. All overtime eligible hours performed on the above described work that is energized,shall be paid at the double the hourly rate of wage. E. The first two(2)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. On a four-day, ten-hour weekly schedule, either Monday thru Thursday or Tuesday thru Friday schedule, all hours worked after ten shall be paid at double the hourly rate of wage.The Monday or Friday not utilized in the normal four- day,ten hour work week,and Saturday shall be paid at one and one half(1'/z)times the regular shift rate for the first eight(8) hours. All other hours worked Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. F. All hours worked between the hours of 6:00 pm and 6:00 am, Monday through Saturday, shall be paid at a premium rate of 20% over the hourly rate of wage. All hours worked on Sundays shall be paid at one and one-half times the hourly rate of wage.All hours worked on holidays shall be paid at double the hourly rate of wage. G. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked Monday through Saturday over twelve (12) hours and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. H. The first two(2)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All other overtime hours worked,except Labor Day, and all hours on Sunday shall be paid at double the hourly rate of wage.All hours worked on Labor Day shall be paid at three times the hourly rate of wage. I. The First eight(8)hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of eight (8)per day on Saturdays shall be paid at double the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. J. The first eight(8)hours worked on a Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked in excess of eight(8)hours on a Saturday shall be paid at double the hourly rate of wage. All hours worked over twelve(12) in a day, and all hours worked on Sundays and Holidays shall be paid at double the hourly rate of wage. K. All hours worked on a Saturday shall be paid at one and one-half times the hourly rate of wage,so long as Saturday is the sixth consecutive day worked. All hours worked over twelve(12)in a day Monday through Saturday,and all hours worked on Sundays and Holidays shall be paid at double the hourly rate of wage. 5 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Overtime Codes Continued 4. L. The first twelve(12)hours worked on a Saturday shall be paid at one and one-half times the hourly rate of wage.All hours worked on a Saturday in excess of twelve(12)hours shall be paid at double the hourly rate of pay. All hours worked over twelve(12)in a day Monday through Friday,and all hours worked on Sundays shall be paid at double the hourly rate of wage.All hours worked on a holiday shall be paid at one and one-half times the hourly rate of wage, except that all hours worked on Labor Day shall be paid at double the hourly rate of pay. M. All hours worked on Sunday and Holidays shall be paid at double the hourly rate. Any employee reporting to work less than nine (9)hours from their previous quitting time shall be paid for such time at time and one-half times the hourly rate. N. All hours worked on Saturdays shall be paid atone and one-half times the hourly rate of wage. All hours worked on Sundays and holidays,and all work performed between the hours of midnight(12:00 AM)and eight AM(8:00 AM) every day shall be paid at double the hourly rate of wage. O. All hours worked between midnight Friday to midnight Sunday shall be paid at one and one-half the hourly rate of wage. After an employee has worked in excess of eight(8)continuous hours in any one or more calendar days, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of six (6) hours or more. All hours worked on Holidays shall be paid at double the hourly rate of wage. P. All hours worked on Holidays shall be paid at one and one-half times the hourly rate of wage. Q. The first four(4)hours after eight(8)regular hours Monday through Friday and the first eight(8)hours on Saturday shall be paid at one and one-half times the hourly rate of wage. All hours worked over twelve (12)hours Monday through Saturday shall be paid at double the hourly rate. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. R. All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage,so long as Saturday is the sixth consecutive day worked. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. S. All hours worked on Saturdays and Holidays shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays shall be paid at double the hourly rate of wage. T. The first two(2)hours of overtime for hours worked Monday-Friday shall be paid at one and one-half times the hourly rate of wage.All hours worked in excess of ten(10)hours per day shall be paid at double the hourly rate of wage.All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage.For work on Saturday which is scheduled prior to the end of shift on Friday,the first six(6)hours work shall be paid at one and one-half times the hourly rate of wage,and all hours over(6)shall be paid double the hourly rate of wage.For work on Saturday which was assigned following the close of shift on Friday,all work shall be paid at double the hourly rate of wage. U, The fust four(4)hours after eight(8)regular hours Monday through Friday and the first twelve(12)hours on Saturday shall be paid at one and one-half times the hourly rate of wage.(Except on makeup days if work is lost due to inclement weather,then the first eight(8) hours on Saturday may be paid the regular rate.)All hours worked over twelve(12) hours Monday through Saturday, and all hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. 6 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Overtime Codes Continued 4. V. Work performed in excess of ten(10)hours of straight time per day when four ten(10)hour shifts are established or outside the normal shift(5 am to 6pm),and all work on Saturdays,except for make-up days shall be paid at time and one-half(1 1/z)the straight time rate. In the event the job is down due to weather conditions,then Saturday may,be worked as a voluntary make-up day at the straight time rate. However, Saturday shall not be utilized as a make-up day when a holiday falls on Friday. All work performed on Sundays and holidays and work in excess of twelve(12)hours per day shall be paid at double(2x) the straight time rate of pay. After an employee has worked eight (8) hours at an applicable overtime rate, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight(8)hours. When an employee returns to work without a break of eight(8)hours since their previous shift,all such time shall be a continuation of shift and paid at the applicable overtime rate until such time as the employee has had a break of eight (8)hours. W. All hours worked on Saturdays(except makeup days if work is lost due to inclement weather conditions)shall be paid at one and one-half times the hourly rate of wage. All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. When an employee returns to work without at least eight(8) hours time off since their previous shift, all such time shall be a continuation of shift and paid at the applicable overtime rate until such time as the employee has had a break of eight(8)hours. X_ All hours worked on Saturdays shall be paid at one and one-half times the hourly rate of wage.All hours worked on Sundays and holidays shall be paid at double the hourly rate of wage. Work performed outside the normal shift of 6 am to 6pm shall be paid at one and one-half the straight time rate,(except for special shifts or three shift operations). All work performed on Sundays and holidays shall be paid at double the hourly rate of wage.Shifts may be established when considered necessary by the Employer. The Employer may establish shifts consisting of eight(8)or ten(10)hours of work(subject to WAC 296-127-022), that shall constitute a normal forty (40) hour work week. The Employer can change from a 5-eight to a 4-ten hour schedule or back to the other. All hours of work on these shifts shall be paid for at the straight time hourly rate.Work performed in excess of eight hours(or ten hours per day(subject to WAC 296-127-022)shall be paid at one and one- half the straight time rate. When due to conditions beyond the control of the Employer, or when contract specifications require that work can only be performed outside the regular day shift,then by mutual agreement a special shift may be worked at the straight time rate,eight(8) hours work for eight(8)hours pay. The starting time shall be arranged to fit such conditions of work. When an employee returns to work without at a break of eight(8)hours since their previous shift,all such time shall be a continuation of shift and paid at the applicable overtime rate until such time as the employee has had a break of eight(8)hours. 7 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Overtime Codes Continued 4. Y. Work performed in excess of eight(8)hours of straight time per day, or ten(10)hours of straight time per day when four ten (10) hour shifts are established, or forty (40) hours of straight time per week, Monday through Friday, or outside the normal shift,and all work on Saturdays shall be paid at time and one-half the straight time rate. All work performed after 6:00 pm Saturday to 6:00 am Monday and holidays shall be paid at double the straight time rate of pay. Any shift starting between the hours of 6:00 pm and midnight shall receive an additional one dollar($1.00) per hour for all hours worked that shift. After an employee has worked eight (8) hours at an applicable overtime rate, all additional hours shall be at the applicable overtime rate until such time as the employee has had a break of eight(8)hours or more. Holidav Codes 5, A. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day,and Christmas Day(7). B. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day,the day before Christmas,and Christmas Day(8). C. Holidays: New Year's Day,Presidents'Day,Memorial Day, Independence Day,Labor Day,Thanksgiving Day,the Friday after Thanksgiving Day,And Christmas Day(8). D. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day,And Christmas Day(8). H. Holidays: New Year's Day,Memorial Day,Independence Day,Thanksgiving Day,the Day after Thanksgiving Day, And Christmas(6). 1. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day,Thanksgiving Day, and Christmas Day (6). J. Holidays: New Year's Day, Memorial Day, Independence Day,Thanksgiving Day, Friday after Thanksgiving Day, Christmas Eve Day,And Christmas Day(7). K. Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday After Thanksgiving Day,The Day Before Christmas,And Christmas Day(9). L. Holidays:New Year's Day,Martin Luther King Jr.Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day,Friday after Thanksgiving Day,And Christmas Day(8). N. Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day,The Friday After Thanksgiving Day,And Christmas Day(9). P. Holidays: New Year's Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day, Friday And Saturday After Thanksgiving Day, The Day Before Christmas, And Christmas Day (9). If A Holiday Falls On Sunday,The Following Monday Shall Be Considered As A Holiday. Q. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, and Christmas Day(6). 8 Benefit Code Key—Effective 8/31/2019 thru 3/3/2U20 flolida.v Codes Continued 5. R. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Day After Thanksgiving Day,One-Half Day Before Christmas Day,And Christmas Day. (7 1/2). S. Paid Holidays:New Year's Day,Presidents'Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day, And Christmas Day(7). T. Paid Holidays: New Year's Day, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day,The Friday After Thanksgiving Day,Christmas Day,And The Day Before Or After Christmas(9). Z. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Veterans Day, Thanksgiving Day, the Friday after Thanksgiving Day,And Christmas Day(8). 6. A. Paid Holidays:New Year's Day,Presidents'Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day, the Friday after Thanksgiving Day,And Christmas Day(8). E. Paid Holidays: New Year's Day, Day Before Or After New Year's Day, Presidents Day, Memorial Day, Independence Day, Labor Day,Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Day, and a Half- Day On Christmas Eve Day.(9 1/2). G. Paid Holidays: New Year's Day,Martin Luther King Jr. Day, Presidents' Day, Memorial Day, Independence Day, Labor Day,Veterans'Day,Thanksgiving Day,the Friday after Thanksgiving Day,Christmas Day,and Christmas Eve Day(11). H. Paid Holidays:New Year's Day,New Year's Eve Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day,Friday After Thanksgiving Day,Christmas Day,The Day After Christmas,And A Floating Holiday(10). I. Paid Holidays: New Year's Day,Memorial Day, Independence Day,Labor Day,Thanksgiving Day, Friday After Thanksgiving Day,And Christmas Day(7). T. Paid holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day,The Friday After Thanksgiving Day,The Last Working Day Before Christmas Day,And Christmas Day(9). Z. Holidays: New Year's Day,Memorial Day, Independence Day,Labor Day,Thanksgiving Day, Friday after Thanksgiving Day, And Christmas Day (7). if a holiday falls on Saturday, the preceding Friday shall be considered as the holiday. If a holiday falls on Sunday, the following Monday shall be considered as the holiday. 7. A. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day,And Christmas Day(8).Any Holiday Which Falls On A Sunday Shall Be Observed As A Holiday On The Following Monday. If any of the listed holidays falls on a Saturday,the preceding Friday shall be a regular work day. B. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day,And Christmas Day(8).Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. C. Holidays:New Year's Day,Martin Luther King Jr.Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas Day (8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. 9 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Holiday Codes Continued 7. D. Paid Holidays: New Year's Day,Memorial Day,Independence Day,Labor Day,Veteran's Day,Thanksgiving Day, the Friday after Thanksgiving Day, And Christmas Day (8). Unpaid Holidays: President's Day. Any paid holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any paid holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. E. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,And Christmas Day(7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. F. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,the last working day before Christmas day and Christmas day(8).Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. G. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day,Thanksgiving Day, and Christmas Day (6).Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. H. Holidays:New Year's Day,Martin Luther King Jr.Day,Independence Day,Memorial Day,Labor Day,Thanksgiving Day,the Friday after Thanksgiving Day,the Last Working Day before Christmas Day and Christmas Day(9).Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday.Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. I. Holidays:New Year's Day,President's Day,Independence Day,Memorial Day,Labor Day,Thanksgiving Day,The Friday After Thanksgiving Day,The Day Before Christmas Day And Christmas Day(9).Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. J. Holidays:New Year's Day,Independence Day,Memorial Day,Labor Day,Thanksgiving Day and Christmas Day(6). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. K. Holidays: New Year's Day, Memorial Day, Independence Day, Thanksgiving Day, the Friday and Saturday after Thanksgiving Day,And Christmas Day(8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. L. Holidays: New Year's Day, Memorial Day, Labor Day, Independence Day, Thanksgiving Day,the Last Work Day before Christmas Day, And Christmas Day(7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. M. Paid Holidays: New Year's Day, The Day after or before New Year's Day, President's Day, Memorial Day, Independence Day,Labor Day,Thanksgiving Day,the Friday after Thanksgiving Day,Christmas Day,And the Day after or before Christmas Day (10). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday.Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. N. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,And Christmas Day(7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday.When Christmas falls on a Saturday,the preceding Friday shall be observed as a holiday. P. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day, And Christmas Day(7). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. 10 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Holiday Codes Continued 7. Q. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,the Last Working Day before Christmas Day and Christmas Day(8).Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday.If any of the listed holidays falls on a Saturday,the preceding Friday shall be a regular work day. R. Paid Holidays: New Year's Day, the day after or before New Year's Day, President's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day,the Friday after Thanksgiving Day,Christmas Day,and the day after or before Christmas Day(10).If any of the listed holidays fall on Saturday,the preceding Friday shall be observed as the holiday. If any of the listed holidays falls on a Sunday,the day observed by the Nation shall be considered a holiday and compensated accordingly. S. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Friday after Thanksgiving Day,Christmas Day,the Day after Christmas,and A Floating Holiday(9). If any of the listed holidays falls on a Sunday,the day observed by the Nation shall be considered a holiday and compensated accordingly. T. Paid Holidays: New Year's Day, the Day after or before New Year's Day, President's Day, Memorial Day, Independence Day, Labor Day,Thanksgiving Day,the Friday after Thanksgiving Day,Christmas Day,and The Day after or before Christmas Day. (10). If any of the listed holidays falls on a Sunday,the day observed by the Nation shall be considered a holiday and compensated accordingly. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. V. Holidays:New Year's Day,President's Birthday,Memorial Day,Independence Day,labor Day,Thanksgiving Day, the Friday after Thanksgiving Day,Christmas Day,the day before or after Christmas,and the day before or after New Year's Day. If any of the above listed holidays falls on a Sunday,the day observed by the Nation shall be considered a holiday and compensated accordingly. W. Holidays: New Year's Day, Day After New Year's, Memorial Day, Independence Day, Labor Day, Thanksgiving Day,the Friday after Thanksgiving Day,Christmas Eve Day,Christmas Day,the day after Christmas,the day before New Year's Day,and a Floating Holiday. X_ Holidays:New Year's Day,Day before or after New Year's Day,Presidents'Day,Memorial Day,Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day, Christmas Day, and the day before or after Christmas day. If a holiday falls on a Saturday or on a Friday that is the normal day off,then the holiday will be taken on the last normal workday.If the holiday falls on a Monday that is the normal day off or on a Sunday,then the holiday will be taken on the next normal workday. Y, Holidays: New Year's Day, Presidents' Day, Memorial Day, Independence Day, Labor Day,Thanksgiving Day,the Friday after Thanksgiving Day,and Christmas Day.(8)If the holiday falls on a Sunday,then the day observed by the federal government shall be considered a holiday and compensated accordingly. Z. Holidays:New Year's Day.President's Day,Independence Day,Memorial Day,Labor Day,"thanksgiving Day,The Friday After Thanksgiving Day,And Christmas Day(8). Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. Any holiday which falls on a Saturday shall be observed as a holiday on the preceding Friday. 15. A. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,the day before Christmas Day and Christmas Day. (8)Any holiday which falls on a Sunday shall be observed as a holiday on the following Monday. B. Holidays: New Year's Day, Martin Luther King Jr. Day, President's Day,Memorial Day, Independence Day,Labor Day,Veteran's Day,Thanksgiving Day,and Christmas Day. (9) C. Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, the Friday after Thanksgiving Day,the day before Christmas Day and Christmas Day.(8) 11 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Holidav Costes Continued 15. D. Holidays:New Year's Day,Presidents'Day,Memorial Day,Independence Day,Labor Day,Thanksgiving Day,Friday after Thanksgiving Day,Christmas Day,and the day after Christmas. E. Holidays:the day before New Years's Day,New Year's Day,Martin Luther King,Jr.Day,Presidents'Day,Memorial Day,Independence Day,Labor Day,Veteran's Day,Thanksgiving Day,Friday after Thanksgiving Day,the day before Christmas,and Christmas Day. (12) Note Codes 8. D. Workers working with supplied air on hazmat projects receive an additional$1.00 per hour. L. Workers on hazmat projects receive additional hourly premiums as follows -Level A: $0.75, Level B: $0.50, And Level C:$0.25. M. Workers on hazmat projects receive additional hourly premiums as follows: Levels A & B: $1.00, Levels C & D- $0.50. N. Workers on hazmat projects receive additional hourly premiums as follows-Level A:$1.00,Level B:$0.75,Level C:$0.50,And Level D:$0.25. P. Workers on hazmat projects receive additional hourly premiums as follows-Class A Suit: $2.00,Class B Suit:$1.50, Class C Suit:$1.00,And Class D Suit$0.50. Q. The highest pressure registered on the gauge for an accumulated time of more than fifteen(15) minutes during the shift shall be used in determining the scale paid. S. Effective August 31,2012—A Traffic Control Supervisor shall be present on the project whenever flagging or spotting or other traffic control labor is being utilized.Flaggers and Spotters shall be posted where shown on approved Traffic Control Plans or where directed by the Engineer.All flaggers and spotters shall possess a current flagging card issued by the State of Washington, Oregon,Montana,or Idaho. This classification is only effective on or after August 31, 2012. T. Effective August 31,2012—A Traffic Control Laborer performs the setup,maintenance and removal of all temporary traffic control devices and construction signs necessary to control vehicular, bicycle, and pedestrian traffic during constniction operations. Flaggers and Spotters shall be posted where shown on approved Traffic Control Plans or where directed by the Engineer. All flaggers and spotters shall possess a current flagging card issued by the State of Washington,Oregon, Montana,or Idaho.This classification is only effective on or after August 31,2012. U. Workers on hazmat projects receive additional hourly premiums as follows—Class A Suit:$2.00,Class B Suit:$1.50, And Class C Suit:$1.00.Workers performing underground work receive an additional$0.40 per hour for any and all work performed underground, including operating, servicing and repairing of equipment. The premium for underground work shall be paid for the entire shift worked. Workers who work suspended by a rope or cable receive an additional$0.50 per hour.The premium for work suspended shall be paid for the entire shift worked. Workers who do"pioneer"work(break open a cut,build road,etc.)more than one hundred fifty (150)feet above grade elevation receive an additional$0.50 per hour. 12 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Note Codes Continued 8. V. In addition to the hourly wage and fringe benefits,the following depth and enclosure premiums shall be paid.The premiums are to be calculated for the maximum depth and distance into an enclosure that a diver reaches in a day. The premiums are to be paid one time for the day and are not used in calculating overtime pay. Depth premiums apply to depths of fifty feet or more.Over 50'to 100'-$2.00 per foot for each foot over 50 feet.Over 101'to 150'-$3.00 per foot for each foot over 101 feet.Over 151'to 220'-$4.00 per foot for each foot over 220 feet. Over 221'-$5.00 per foot for each foot over 221 feet. Enclosure premiums apply when divers enter enclosures (such as pipes or tunnels) where there is no vertical ascent and is measured by the distance travelled from the entrance.25'to 300' -$1.00 per foot from entrance.300' to 600' -$1.50 per foot beginning at 300'.Over 600' -$2.00 per foot beginning at 600'. W. Meter Installers work on single phase 120/240V self-contained residential meters.The Lineman/Groundmen rates would apply to meters not fitting this description. X. Workers on hazmat projects receive additional hourly premiums as follows-Class A Suit:$2.00,Class B Suit: $1.50,Class C Suit:$1.00,and Class D Suit: $0.50.Special Shift Premium: Basic hourly rate plus$2.00 per hour. When due to conditions beyond the control of the Employer or when an owner(not acting as the contractor),a government agency or the contract specifications requires that work can only be performed outside the normal 5 am to 6pm shift,then the special shift premium will be applied to the basic hourly rate.When an employee works on a special shift,they shall be paid a special shift premium for each hour worked unless they are in OT or Double-time status.(For example,the special shift premium does not waive the overtime requirements for work performed on Saturday or Sunday.) Y. Tide Work:When employees are called out between the hours of 6:00 p.m_and 6:00 a-m.to work on tide work (work located in the tide plane)all time worked shall be at one and one-half times the hourly rate of pay_ Swinging Stage/Boatswains Chair: Employees working on a swinging state or boatswains chair or under conditions that require them to be tied off to allow their hands to be free shall receive seventy-five cents($0.75)per hour above the classification rate_ Z. Workers working with supplied air on hazmat projects receive an additional$1.00 per hour. Special Shift Premium: Basic hourly rate plus$2.00 per hour.When due to conditions beyond the control of the Employer or when an owner(not acting as a contractor), a government agency or the contract specifications require that more than(4)hours of a special shift can only be performed outside the normal 6 am to 6pm shift,then the special shift premium will be applied to the basic straight time for the entire shift. When an employee works on a special shift,they will be paid a special shift premium for each hour worked unless they are in overtime or double- time status. (For example,the special shift premium does not waive the overtime requirements for work performed on Saturday or Sunday.) 13 Benefit Code Key—Effective 8/31/2019 thru 3/3/2020 Note Codes Continued 9. A. Workers working with supplied air on hazmat projects receive an additional$1.00 per hour. Special Shift Premium: Basic hourly rate plus $2.00 per hour. When due to conditions beyond the control of the Employer or when an owner(not acting as the contractor),a government agency or the contract specifications require that more than four(4)hours of a special shift can only be performed outside the normal 6 am to 6pm shift,then the special shift premium will be applied to the basic straight time for the entire shift. When an employee works on a special shift, they shall be paid a special shift premium for each hour worked unless they are in overtime or double- time status.(For example,the special shift premium does not waive the overtime requirements for work performed on Saturday or Sunday.) Certified Crane Operator Premium: Crane operators requiring certifications shall be paid$0.50 per hour above their classification rate. Boom Pay Premium: All cranes including tower shall be paid as follows based on boom length: (A)—130' to 199'—$0.50 per hour over their classification rate. (B)—200' to 299'—$0.80 per hour over their classification rate. (C)—300'and over—$1.00 per hour over their classification rate. B. The highest pressure registered on the gauge for an accumulated time of more than fifteen(15)minutes during the shift shall be used in determining the scale paid. Tide Work:When employees are called out between the hours of 6:00 p.m.and 6:00 a.m.to work on tide work(work located in the tide plane) all time worked shall be at one and one-half times the hourly rate of pay. Swinging Stage/Boatswains Chair:Employees working on a swinging stage or boatswains chair or under conditions that require them to be tied off to allow their hands to be free shall receive seventy-five cents ($0.75) per hour above the classification rate. C. Tide Work:When employees are called out between the hours of 6:00 p.m.and 6:00 a.m.to work on tide work(work located in the tide plane) all time worked shall be at one and one-half times the hourly rate of pay. Swinging Stage/Boatswains Chair:Employees working on a swinging stage or boatswains chair or under conditions that require them to be tied off to allow their hands to be free shall receive seventy-five cents ($0.75) per hour above the classification rate. Effective August 31,2012—A Traffic Control Supervisor shall be present on the project whenever flagging or spotting or other traffic control labor is being utilized.A Traffic Control Laborer performs the setup,maintenance and removal of all temporary traffic control devices and construction signs necessary to control vehicular,bicycle,and pedestrian traffic during construction operations.Flaggers and Spotters shall be posted where shown on approved Traffic Control Plans or where directed by the Engineer.All flaggers and spotters shall possess a current flagging card issued by the State of Washington,Oregon,Montana,or Idaho.'These classifications are only effective on or after August 31,2012. D. Industrial Painter wages are required for painting within industrial facilities such as treatment plants,pipelines, towers,dams,badges,power generation facilities and manufacturing facilities such as chemical plants,etc.,or anywhere abrasive blasting is necessary to prepare surfaces,or hazardous materials encapsulation is required. E. Heavy Construction includes construction,repair,alteration or additions to the production,fabrication or manufacturing portions of industrial or manufacturing plants,hydroelectric or nuclear power plants and atomic reactor construction. Workers on hazmat projects receive additional hourly premiums as follows-Level A: $1.00, Level B:$0.75,Level C: $0.50,And Level D:$0.25. 14 State of Washington Department of Labor & Industries Prevailing Wage Section -Telephone 360-902-5335 PO Box 44540, Olympia, WA 98504.4540 Washington State Prevailing Wage The PREVAILING WAGES listed here include both the hourly wage rate and the hourly rate of fringe benefits. On public works projects, worker's wage and benefit rates must add to not less than this total.A brief description of overtime calculation requirements are provided on the Benefit Code Key. Journey Level Prevailing Wage Rates for the Effective Date: 02/10/2020 County Trade Job Classification Waite Holiday (Overtime Note King Asbestos Abatement Workers Journey Level $50.86 5D 1 H View King Boilermakers Journey Level $69.04 5N 1C View King Brick Mason Journey Level $58.82 5A 1M View King Brick Mason Pointer-Caulker-Cleaner $58.82 5A 1M View King Buitding Ser vice Emptovees Janitor $25.58 5S 2F View King Building Ser/ice Ernp_2vees Traveling Waxer/Shampooer $26.03 5S 2F View King BluitdinQ Service Emptoyees Window Cleaner (Non- $29.33 5S 2F View Scaffold) King Building Service Ern [gyees Window Cleaner (Scaffold) $30.33 5S 2F View King Cabinet Makers On Shopl Journey Level $22.74 1 View King Carpenr_ers Acoustical Worker $62.44 7A 4C View Kingc�n-tars Carpenter $62.44 7A 4C View King Carcenters Carpenters on Stationary $62.57 7A 4C View Tools King Carpenters Creosoted Material $62.54 7A 4C View King Carr esters Floor Finisher $62.44 7A 4C View King (-arr)er,ters Floor Layer $62.44 7A 4C View King Carpenters Scaffold Erector $62.44 7A 4C View King Cement Masons Application of all $62.97 7A 4U View Composition Mastic King Cement Masons Application of all Epoxy $62.47 7A 4U View Material King Cement Masons Application of all Plastic $62.97 7A 4U View Material King Cement MAsons Application of Sealing $62.47 7A 4U View Compound King Cement Masons Application of Underlayment $62.97 7A 4U View King Cement Masons 1130ding General $62.47 7A 4U View King Cement Masons Composition or Kalman $62.97 7A 4U View Floors King Cement Masons Concrete Paving $62.47 7A 4U View King Cement Masons Curb Et Gutter Machine $62.97 7A 4U View King Cement Masons Curb Et Gutter, Sidewalks $62.47 7A 41J View King Cement Masons Curing Concrete $62.47 7A 4U View https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 King Cernert ,Masons Finish Colored Concrete $62.S. 7A 4U View King Cement Masons Floor Grinding $62.97 7A 4U View King Cement Masons Floor Grinding/Polisher $62.47 7A 4U View King Cement Masons Green Concrete Saw, self- $62.97 7A 4U View powered King Cement Masons Grouting of all Plates $62.47 7A 4U View King Cement Masons Grouting of all Tilt-up Panels $62.47 7A 4U View King Cement Masons Gunite Nozzleman $62.97 7A 4U View King Cement Masons Hand Powered Grinder $62.97 7A 4U View King Cement Masons Journey Level $62.47 7A 4U View King Cement Masons Patching Concrete $62.47 7A 4U View King Cement Masons Pneumatic Power Tools $62.97 7A 4U View King Cement Masons Power Chipping Et Brushing $62.97 7A 4U View King Cement Masons Sand Blasting Architectural $62.97 7A 4U View Finish King Cement Masons Screed Et Rodding Machine $62.97 7A 4U View King Cement Masons Spackling or Skim Coat $62.47 7A 4U View Concrete King Cement Masons Troweling Machine Operator $62.97 7A 4U View King Cement Masons Troweling Machine Operator $62.97 7A 4U View on Colored Slabs King Cement Masons jTunnet Workers $62.97 7A 4U View King Divers Et Tenders Bell/Vehicle or Submersible $116.20 7A 4C View Operator (Not Under Pressure) King Divers Et Tenders Dive Supervisor/Master $79.23 7A 4C View King Divers Et Tenders Diver $116.20 7A 4C 8V View King Divers Et Tenders Diver On Standby $74.23 7A 4C View King Divers Et Tenders Diver Tender $67.31 7A 4C View King Divers Et Tenders Manifold Operator $67.31 7A 4C View King Divers Et Tenders Manifold Operator Mixed Gas $72.31 7A 4C View King Divers Et Tenders Remote Operated Vehicle $67.31 7A 4C View Operator/Technician King Divers Et Tenders Remote Operated Vehicle $62.69 7A 4C View Tender King Dredge Workers Assistant Engineer $56.44 5D 3F I View King Dredge Workers Assistant Mate (Deckhand) $56.00 5D 3F View King Dredge Workers Boatmen $56.44 5D 3F View King Dredge Workers Engineer Welder $57.51 5D 3F View King Dredge Workers L everman, Hydraulic $58.67 5D 3F View King Dredge Workers Mates $56.44 5D 3F View King Dredge Workers Oiler $56.001 5D 3F View King Drywall Applicator Journey Level $62.44 5D 1H View King Drywall Tapers Journey Level $62.94 5P 1E View King Electrical Fixture Journey Level $30.59 5L 1E View Maintenance Workers King Electricians - Inside Cable Splicer $83.17 7C 4E View https://fortress.wa.gov/lni/wagelookup/pr-vWagelookup.aspx 1/27/2020 King Electricians - Inside Cable Splicer (tunnel) $89.3 7C 4E View King Electricians - Inside lCertified Welder $80.36 7C 4E View King Electricians - Inside lCertified Welder (tunnel) $86.25 7C 4E View King Electricians - Inside Construction Stock Person $41.48 7C 4E View King Electricians - Inside Journey Level $77.55 7C 4E View King Electricians - Inside Journey Level (tunnel) $83.17 7C 4E View King Electricians - Motor Shoe Journey Level $45.08 5A 1B View King Electricians - Powerline Cable Splicer $79.60 5A 4D View Construction King Electricians - Powerline Certified Line Welder $72.98 5A 4D View Construction King Electricians - Powerline Groundperson $47.94 5A 4D View Construction King Electricians - Powerline Heavy Line Equipment $72.98 5A 4D View Construction Operator King Electricians - Powerline Journey Level Lineperson $72.98 5A 4D View Construction King Electricians - Powerline Line Equipment Operator $62.06 5A 4D View Construction King Electricians - Powerline Meter Installer $47.94 5A 4D 8W View Construction King Electricians - Powerline Pole Sprayer $72.98 5A 4D View Construction King Electricians - Powerline Powderperson $54.55 5A 4D View Construction King Electronic Technicians Journey Level $51.07 7E 1E View King Elevator Constructors Mechanic $94.22 7D 4A View King Elevator Constructors Mechanic In Charge $101.73 7D 4A View King Fabricated Precast Concrete All Classifications - In- $18.25 5B 1 R View Products Factory Work Only King Fence Erectors Fence Erector $43.11 7A 4V 8Y View King Fence Erectors iFence Laborer $43.111 7A 4V 8Y View King Flaggers Journey Level $43.111 7A I 4V 8Y View King Glaziers Journey Level $66.511 7L 1Y View King Heat Et Frost Insulators And Journeyman $76.61 5J 4H View Asbestos Workers King Heating EQUipment Journey Level $85.88 7F 1E View Mechanics King Hod Carriers Et Mason Journey Level $52.44 7A 4V 8Y View Tenders King Industrial Power Vacuum Journey Level $13.50 1 View Cleaner King Inland Boatmen Boat Operator $61.41 5B 1K View King Inland Boatmen Cook $56.48 5B 1K View King Inland Boatmen Deckhand $57.48 5B 1K View King Inland Boatmen Deckhand Engineer $58.81 5B 1K View King Inland Boatmen Launch Operator $58.89 5B 1K View King Inland Boatmen Mate $57.31 5B 1K View https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 King lns ection/Cleaning/Seg. I Cleaner Operator, Foamer $31.45 1 View Of Sewer Et 'Nater Svsrems 5y Operator Remote Control King Inspection ICleaning!SeaUn Grout Truck Operator $13.50 1 View Of Sewer 8: Water Systems By Remote Control King Inspection/Cleaning ISeat in_q Head Operator $24.91 1 View Of Sewer Et Water Systems By Remote Control King Inspection/CLeanin /Sealin Technician $19.33 1 View Of Sewer Et Water Systems By Remote Control King Inspection/Cteaning'Seating Tv Truck Operator $20.45 1 View Of Sewer a Water SySte_i'ps BY Remote Control King Insulation Appiicaturs Journey Level $62.44 7A 4C View King Ironworkers Journeyman $72.18 7N 10 View King Laborers Air, Gas Or Electric Vibrating $50.86 7A 4V 8Y View Screed King Laborers Airtrac Drill Operator $52.44 7A 4V 8Y View King Laborers Ballast Regular Machine $50.86 7A 4V 8Y View King Laborers Batch Weighman $43.11 7A 4V 8Y View King Laborers Brick Pavers $50.86 7A 4V 8Y View King Laborers Brush Cutter $50.86 7A 4V 8Y View King Laborers Brush Hog Feeder $50.86 7A 4V 8Y View King Laborers Burner $50.86 7A 4V 8Y View King Laborers Caisson Worker $52.44 7A 4V 8Y View King Laborers Carpenter Tender $50.86 7A 4V 8Y View King Laborers Cement Dumper-paving $51.80 7A 4V 8Y View King Laborers Cement Finisher Tender $50.86 7A 4V 8Y View King Laborers Change House Or Dry Shack $50.86 7A 4V 8Y View King Laborers Chipping Gun (30 Lbs. And $51.80 7A 4V 8Y View Over) King Laborers Chipping Gun (Under 30 Lbs.) $50.86 7A 4V8Y View King Laborers Choker Setter $50.86 7A 4V 8Y View King Laborers Chuck Tender $50.86 7A 4V 8Y View King Laborers _ Clary Power Spreader $51.80 7A 4V 8Y View King Laborers Clean-up Laborer $50.86 7A 4V 8Y View King Laborers Concrete Dumper/Chute $51.80 7A 4V 8Y View Operator King Laborers lConcrete Form Stripper $50.86 7A 4V 8Y View King Laborers Concrete Placement Crew $51.80 7A 4V8Y View King Laborers Concrete Saw Operator/Core $51.80 7A 4V 8Y View Driller King Laborers Crusher Feeder $43.11 7A 4V 8Y View King Laborers Curing Laborer $50.86 7A 4V 8Y View King Laborers Demolition: Wrecking Et $50.86 7A 4V 8Y View Moving (Incl. Charred Material) https://fortress.wa.gov/tni/wagelookup/prvWagelookup.aspx 1/27/2020 King Laborers Ditch Digger $50.8 7A 4V 8Y I View King Laborers Diver $52-441 7A 4V I 8Y View King Laborers Drill Operator (Hydraulic, $51.80 7A 4V 8Y View Diamond) King Laborers Dry Stack Walls $50.86 7A 4V 8Y View King Laborers Dump Person $50.86 7A 4V 8Y View King Laborers Epoxy Technician $50.86 7A 4V 8Y View King Laborers Erosion Control Worker $50.86 7A 4V 8Y View King Laborers Faller Et Bucker Chain Saw $51.80 7A 4V 8Y View King Laborers Fine Graders $50.86 7A 4V 8Y View King Laborers Firewatch $43.11 7A 4V 8Y View King Laborers Form Setter $50.86 7A 4V 8Y View King Laborers Gabian Basket Builders $50.86 7A 4V 8Y View King Laborers General Laborer $50.86 7A 4V 8Y View King Laborers Grade Checker Et Transit $52.44 7A 4V 8Y View Person King Laborers Grinders $50.86 7A 4V 8Y View King Laborers Grout Machine Tender $50.86 7A 4V 8Y View King Laborers Groutmen (Pressure) $51.80 7A 4V 8Y View Including Post Tension Beams King Laborers Guardrail Erector $50.86 7A 4V 8Y View King Laborers Hazardous Waste Worker $52.44 7A 4V 8Y View (Level A) King Laborers Hazardous Waste Worker $51.80 7A 4V 8Y View (Level B) King Laborers Hazardous Waste Worker $50.86 7A 4V 8Y View (Level C) King Laborers High Scaler $52.44 7A 4V 8Y View King Laborers Jackhammer $51.80 7A 4V 8Y View King Laborers Laserbeam Operator $51.80 7A 4V 8Y View King Laborers Maintenance Person $50.86 7A 4V 8Y View King Laborers Manhole Builder-Mudman $51.80 7A 4V 8Y View King Laborers Material Yard Person $50.86 7A 4V 8Y View King Laborers Motorman-Dinky Locomotive $51.80 7A 4V 8Y View King Laborers Nozzleman (Concrete Pump, $51.80 7A 4V 8Y View Green Cutter When Using Combination Of High Pressure Air lit Water On Concrete Et Rock, Sandblast, Gunite, Shotcrete, Water Blaster, Vacuum Blaster) King Laborers Pavement Breaker $51.80 7A 4V 8Y View King Laborers Pilot Car $43.11 7A 4V 8Y View King Laborers Pipe Layer Lead $52.44 7A 4V 8Y View King Laborers Pipe Layer/Tailor $51.80 7A 4V 8Y View King Laborers Pipe Pot Tender $51.80 7A 4V 8Y View King Laborers Pipe Reliner $51.80 7A 4V 8Y View King Laborers Pipe Wrapper $51.80 7A 4V 8Y View https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 King Laborers Pot Tender $50.8k 7A 4V 8Y View King Laborers Powderman $52.44 7A 4V 8YView King Laborers Powderman's Helper $50.86 7A 4V 8Y View King Laborers Power Jacks $51.80 7A 4V 8Y View King Laborers Railroad Spike Puller Power $51.80 7A 4V 8Y View King Laborers Raker- Asphalt $52.44 7A 4V 8Y View King Laborers Re-timberman $52.44 7A 4V 8Y View King Laborers Remote Equipment Operator $51.80 7A 4V 8Y View King Laborers Rigger/Signal Person $51.80 7A 4V 8Y View King Laborers Rip Rap Person $50.86 7A 4V 8Y View Bing Laborers Rivet Buster $51.80 7A 4V 8Y View King Laborers Rodder $51.80 7A 4V 8Y View King Laborers Scaffold Erector $50.861 7A 4V 8Y View King Laborers Scale Person $50.86 7A 4V 8Y View King Laborers Sloper (Over 20") $51.80 7A 4V 8Y View King Laborers Sloper Sprayer $50.86 7A 4V 8Y View King Laborers Spreader (Concrete) $51.80 7A 4V 8Y View King Laborers Stake Hopper $50.86 7A 4V 8Y View King Laborers Stock Her $50.86 7A4V 8Y View King Laborers Swinging Stage/Boatswain $43.11 7A 4V 8Y View Chair King Laborers Tamper & Similar Electric, $51.80 7A 4V 8Y View Air Ft Gas Operated Tools King Laborers Tamper (Multiple ft Self- $51.80 7A 4V 8Y View propelled) King Laborers Timber Person - Sewer $51.80 7A 4V 8Y View (tagger, Shorer & Cribber) King Laborers Toolroom Person (at Jobsite) $50.86 7A 4V 8Y View King, Laborers Topper $50.86 7A 4V 8Y View King Laborers Track Laborer $50.86 7A 4V 8Y View King Laborers Track Liner (Power) $51.80 7A 4V 8Y View King. Laborers Traffic Control Laborer $46.10 7A 4V 9C View King Laborers Traffic Control Supervisor $46.10 7A 4V 9C View King Laborers Truck Spotter $50.86 7A 4V 8Y View King Laborers Tugger Operator $51.80 7A 4V 8Y View King Laborers Tunnel Work-Compressed Air $120.61 7A 4V 9B View Worker 0-30 psi King Laborers Tunnel Work-Compressed Air $125.64 7A 4V 9B View Worker 30.01-44.00 psi King Laborers Tunnel Work-Compressed Air $129.32 7A 4V 9B View Worker 44.01-54.00 psi King Laborers Tunnel Work-Compressed Air $135.02 7A 4V 9B View Worker 54.01-60.00 psi King Laborers Tunnel Work-Compressed Air $137.14 7A 4V 9B View Worker 60.01-64.00 psi King Laborers Tunnel Work-Compressed Air $142.24 7A 4V 9B View Worker 64.01-68.00 psi https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 King Laborers Tunnel Work-Compressed Air $144. 7A 4V 9B View Worker 68.01-70.00 psi King Laborers Tunnel Work-Compressed Air $146.14 7A 4V 9B View Worker 70.01-72.00 psi King Laborers Tunnel Work-Compressed Air $148.14 7A 4V 9B View Worker 72.01-74.00 psi King Laborers Tunnel Work-Guage and Lock $52.54 7A 4V 8Y View Tender King Laborers Tunnel Work-Miner $52.54 7A 4V 8Y View King Laborers Vibrator $51.80 7A 4V 8Y View King Laborers Vinyl Seamer $50.86 7A 4V 8Y View King Laborers Watchman $39.18 7A 4V 8Y View King Laborers Welder $51.80 7A 4V 8Y View King Laborers Well Point Laborer $51.80 7A4V 8Y View King Laborers Window Washer/Cleaner $39.18 7A 4V 8Y View King Laborers - Underground General Laborer Et Topman $50.86 7A 4V 8Y View Sewer Et Water King Laborers - Underground Pipe Layer $51.80 7A 4V 8Y View Sewer & Water King Landscape Construction Landscape $39.18 7A 4V 8Y View Construction/Landscaping Or Planting Laborers King Landscape Construction Landscape Operator $68.02 7A 3K 8X View King Landscape Maintenance Groundskeeper $17.87 1 View King Lathers Journey Level $62.44 5D 1H View King Marble Setters Journey Level $58.82 5A 1M View King Metal Fabrication (In Shap) Fitter $15.86 1 View King Metal Fabrication 1n Sho Z Laborer $13.50 1 View King Meta[ Fabrication In Shop ) Machine Operator $13.50 1 View King Metal Fabrication (In Shap) Painter $13.50 1 View King Metal Fabrication (In Shopl Welder $15.48 1 View King Millwright Journey Level $63.94 7A 4C View King Modular Buildings Cabinet Assembly $13.501 1 View King Modular Buildin s Electrician $13.50 1 View King Modular Buildings Equipment Maintenance $13.50 1 View King ,Modular Buildings Plumber $13.50 1 View King ,Modular Buildings Production Worker $13.50 1 View King Modular Buildings Tool Maintenance $13.50 1 View King Modular Buildings Utility Person $13.50 1 View King Modular Buildings Welder $13.50 1 View King Painters Journey Level $43.40 6Z 2B View King Pile Driver Crew Tender $67.31 7A 4C View King Pile Driver lCrew Tender/Technician $67.31 7A 4C View King Pile Driver Hyperbaric Worker - $77.93 7A 4C View Compressed Air Worker 0-30.00 PSI King Pile Driver $82.93 7A 4C View https.-/Ifortress.wa.gov/lnilwagelookup/prvWagelookup.aspx 1/27/2020 Hyperbaric Worker - Compressed Air Worker 30.01 44.00 PSI King Pile Driver Hyperbaric Worker - $86.93 7A 4C View Compressed Air Worker 44.01 - 54.00 PSI King Pile Driver Hyperbaric Worker - $91.93 7A 4C View Compressed Air Worker 54.01 60.00 PSI King Pile Driver Hyperbaric Worker - $94.43 7A 4C View Compressed Air Worker 60.01 - 64.00 PSI King Pile Driver Hyperbaric Worker - $99.43 7A 4C View Compressed Air Worker 64.01 - 68.00 PSI King Pile Driver Hyperbaric Worker - $101.43 7A 4C View Compressed Air Worker 68.01 - 70.00 PSI King Pile Driver Hyperbaric Worker- $103.43 7A 4C View Compressed Air Worker 70.01 - 72.00 PSI King Pile Driver Hyperbaric Worker - $105.43 7A 4C View Compressed Air Worker 72.01 - 74.00 PSI King Pile Driver Journey Level $62.69 7A 4C View King Plasterers Journey Level $59.42 ZQ 1R View King Pta; ground Et Park Journey Level $13.50 1 View Equipment Installers King Pturnbers Et PipefLitters Journey Level $87.69 6Z 1G View King Power Equipment Operators Asphalt Plant Operators $69.16 7A 3K 8X View King Power Equipment Operators Assistant Engineer $65.05 7A 3K 8X View King Power Equipment Operators Barrier Machine (zipper) $68.55 7A 3K 8X View King Power Equipment Operators Batch Plant Operator: $68.55 7A 3K 8X View concrete King Power Equipment Operators Bobcat $65.05 7A 3K 8X View King Power Equipment Operators Brokk - Remote Demolition $65.05 7A 3K 8X View Equipment King rower E uiprncnt Operators Brooms $65.05 7A 3K 8X View King Power Equipment Operators Bump Cutter $68.55 7A 3K 8X View King Power Equipment Operators Cableways $69.16 7A 3K 8X View King Power Equipment O erators Chipper $68.55 7A 3K 8X View King Power Equipment Operators Compressor $65.05 7A 3K 8X View King Power Equipment 0 erators Concrete Finish Machine - $65.05 7A 3K 8X View Laser Screed King Power Equipment Operators Concrete Pump -Mounted Or $68.02 7A 3K 8X View Trailer High Pressure Line Pump, Pump High Pressure King Power E ui ment Operators Concrete Pump: Truck Mount $69.16 7A 3K 8X View With Boom Attachment Over 42 M King Power Equipment Operators j $68.55 7A j 3K 8X 1 View https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx l/27/2020 Concrete Pump: Truck Mount With Boom Attachment Up To 42m King Power Equipment Operators Conveyors $68.02 7A 3K 8X View 'King Power Equipment Operators Cranes friction: 200 tons and $71.26 7A 3K 8X View over King Power Equipment_Operators Cranes: 100 tons through 199 $69.85 7A 3K 8X View tons, or 150' of boom (including jib with attachments) King Power EQUiDment Operators Cranes: 20 Tons Through 44 $68.55 7A 3K 8X View Tons With Attachments King Power Equipment Opet ators Cranes: 200 tons- 299 tons, $70.57 7A 3K 8X View or 250' of boom including jib with attachments King Power Equipment Operators Cranes: 300 tons and over or $71.26 7A 3K 8X View 300' of boom including jib with attachments King Power Equipment Operators Cranes: 45 Tons Through 99 $69.16 7A 3K 8X View Tons, Under 150' Of Boom (including Jib With Attachments) King Power Eq4pment O erators Cranes: A-frame - 10 Tons $65.05 7A 3K 8X View And Under King Power Equipment Operators Cranes: Friction cranes $70.57 7A 3K 8X View through 199 tons King Power Equipment Operators Cranes: through 19 tons with $68.02 7A 3K 8X View attachments, A-frame over 10 tons King Power E ui ment Operators Crusher $68.55 7A 3K 8X View King Power Equipment Operators Deck Engineer/Deck Winches $68.55 7A 3K 8X View (power) King Power Equipment Operators Derricks, On Building Work $69.16 7A 3K 8X View King Power Equipment_Operators Dozers D-9 Et Under $68.02 7A 3K 8X View King Power Equipment Operators Drill Oilers: Auger Type, $68.02 7A 3K 8X View Truck Or Crane Mount King Power Equipment Operators Drilling Machine $69.85 7A 3K 8X View King Power Equipment Operators Elevator And Man-lift: $65.05 7A 3K 8X View Permanent And Shaft Type King Power Equipment O erators Finishing Machine, Bidwell $68.55 7A 3K 8X View And Gamaco Et Similar Equipment King Power Equipment_Operators Forklift: 3000 Lbs And Over $68.02 7A 3K 8X View With Attachments King Power Equipment Operators Forklifts: Under 3000 Lbs. $65.05 7A 3K 8X View With Attachments King Power Equipment Operators Grade Engineer: Using Blue $68.55 7A 3K 8X View Prints, Cut Sheets, Etc King Power Equipment Operators Gradechecker/Stakeman $65.05 7A 3K8X View King Power Equipment Operators Guardrail Punch $68.55 7A 3K 8X View King Power Equipment Operators $69.16 7A 3K 8X View https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 Hard Tail End Dump Articulating Off- Road Equipment 45 Yards. Et Over King Power Equipment Oner,ators Hard Tail End Dump $68.55 7A 3K 8X View Articulating Off-road Equipment Under 45 Yards King Power Equipment Operatgrs Horizontal/Directional Drill $68.02 7A 3K 8X View Locator King Power Equipment Operators Horizontal/Directional Drill $68.55 7A 3K 8X View Operator King Power Equipment Operators Hydralifts/Boom Trucks Over $68.02 7A 3K 8X View 10 Tons King Power Equipment Operators Hydralifts/Boom Trucks, 10 $65.05 7A 3K 8X View Tons And Under King Power Equipment Operators Loader, Overhead 8 Yards. Et $69.85 7A 3K 8X View Over King Power Equipment Operators Loader, Overhead, 6 Yards. $69.16 7A 3K 8X View But Not Including 8 Yards King Power Equipment Operators Loaders, Overhead Under 6 $68.55 7A 3K 8X View Yards King Power Equipment Operators Loaders, Plant Feed $68.55 7A 3K 8X View King Power Equipment Q erators Loaders: Elevating Type Belt $68.02 7A 3K 8X I View King Power Equipment Operators Locomotives, All $68.55 7A 3K 8X View King Power Equipment Qperators Material Transfer Device $68.55 7A 3K 8X View King Power Equipment Operators Mechanics, All (leadmen - $69.85 7A 3K 8X View $0.50 Per Hour Over Mechanic) King Power Equipment Operators Motor Patrol Graders $69.16 7A 3K 8X View King Power Equipment Operators Mucking Machine, Mole, $69.16 7A 3K 8X View Tunnel Drill, Boring, Road Header And/or Shield King Power Equipment operators Oil Distributors, Blower $65.05 7A 3K 8X View Distribution Et Mulch Seeding Operator King Power Equipment Operators Outside Hoists (Elevators And $68.02 7A 3K 8X View Manlifts), Air Tuggers, Strato King Power E ui meat Operators Overhead, Bridge Type $68.55 7A 3K 8X View Crane: 20 Tons Through 44 Tons King Power Equipment Operators Overhead, Bridge Type: 100 $69.85 7A 3K 8X View Tons And Over King Rawer Equipment Operators Overhead, Bridge Type: 45 $69.16 7A 3K 8X View Tons Through 99 Tons King Power Equipment Operators Pavement Breaker $65.05 7A 3K 8X View King P� uipment Operators Pile Driver (other Than Crane $68.55 7A 3K 8X View Mount) King Power Eguiprrenr Operators Plant Oiler - Asphalt, Crusher $68.02 7A 3K 8X View King Power Equipment Operators Posthole Digger, Mechanical $65.05 7A 3K 8X View King Power Equipment Operators Power Plant $65.05 7A 3K 8X View King Power Equipment Operator IPumps - water $65.05 7A 3K 8X View https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 King Power Equipi'nent Oper -s Quad 9, Hd 41, D10 And Over $69.' 7A I 3K $X View King Power Equipment 0 erators Quick Tower - No Cab, Under $65.05 7A 3K 8X View 100 Feet In Height Based To Boom King Power Equipment Oyerators Remote Control Operator On $69.16 7A 3K 8X View Rubber Tired Earth Moving Equipment King Power Equipment Operators Rigger and Bellman $65.05 7A 3K 8X View King Power Equipment Operators Rigger/Signal Person, $68.02 7A 3K 8X View Bellman (Certified) King Power Equipment Operators Rollagon $69.16 7A I 3K 8X View King Power Equipment Operators Roller, Other Than Plant Mix $65.05 7A 3K 8X View King Power Equipment Operators Roller, Plant Mix Or Multi-lift $68.02 7A 3K 8X View Materials King Power Equipment Operators Roto-mill, Roto-grinder $68.55 7A 3K 8X View King Power Equipment Operators Saws - Concrete $68.02 7A 3K 8X View King Power Equipment Operators Scraper, Self Propelled $68.55 7A 3K 8X View Under 45 Yards King Power E ui ment Operators Scrapers - Concrete £t Carry $68.02 7A 3K 8X View All King Power Equipment O erators Scrapers, Self-propelled: 45 $69.16 7A 3K 8X View Yards And Over King Power E ui merit Operators Service Engineers - $68.02 7A 3K 8X View Equipment King Power Equipment Operators Shotcrete/G unite Equipment $65.05 7A 3K 8X View King Power Equipment Operators Shovel, Excavator, Backhoe, $68.02 7A 3K 8X View Tractors Under 15 Metric Tons King Power Equipmen[ Operators Shovel, Excavator, Backhoe: $69.16 7A 3K 8X View Over 30 Metric Tons To 50 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoes, $68.55 7A 3K 8X View Tractors: 15 To 30 Metric Tons King Power Equipment 0 erators Shovel, Excavator, Backhoes: $69.85 7A 3K 8X View Over 50 Metric Tons To 90 Metric Tons King Power Equipment Operators Shovel, Excavator, Backhoes: $70.57 7A 3K 8X View Over 90 Metric Tons King Power Equipment Operators Slipform Pavers $69.16 7A 3K 8X View King Power Equipment Operators Spreader, Topsider Et $69.16 7A 3K 8X View Screedman King Power Equipment O erators Subgrader Trimmer $68.55 7A 3K 8X View King Power Equipment Operators Tower Bucket Elevators $68.021 7A 3K 8X View King Power Equipment Operators Tower Crane Up To 175' In $69.85 7A 3K 8X View Height Base To Boom King mower Equipment Operators Tower Crane: over 175' $70.57 7A 3K 8X View through 250' in height, base to boom King Power Equipment O erators Tower Cranes: over 250' in $71.26 7A 3K 8X View height from base to boom https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 King Power Equipment= Olj2�r-a, _ Transporters, All Track Or $69.16 7A 3K 8X View Truck Type King slower Equipment Oceral_af's Trenching Machines $68.02 7A 3K 8X View King Power Equipment Operators Truck Crane Oiler/driver- $68.55 7A 3K 8X View 100 Tons And Over King Power Equipment Operators Truck Crane Oiler/Driver $68.02 7A 3K 8X View Under 100 Tons King Power Equipments Operators Truck Mount Portable $68.55 7A 3K 8X View Conveyor King Power Equipment Ooet-at. yrs Welder $69.16 7A 3K 8X View King Power Equipment Operators Wheel Tractors, Farman $65.05 7A 3K 8X View Type King -ower E uiprnen� ,Drerators Yo Yo Pay Dozer $68.55 7A 3K 8X View King Power Equipment Oper�at_gr-s- Asphalt Plant Operators $69.16 7A 3K 8X I View Underground Sewer �, WaCer — King Power Equipment ;3r)eraior-s- Assistant Engineer $65.051 7A 3K 8X View Underground Sewer Et Water- King Power Equipment Caesars- Barrier Machine (zipper) $68.55 7A 3K 8X View Underground Sewer Et Water- King Power Equipment Operators- Batch Plant Operator, $68.55 7A 3K 8X View Underground Sewer a 'Nater Concrete King Power Equipment Operatars� Bobcat $65.05 7A 3K 8X View Underground Sewer E Water King Prower Equipment Operators- Brokk- Remote Demolition $65.05 7A 3K 8X View Underground Sewer ft Water Equipment King Power Eauipmont Operators- Brooms $65.05 7A 3K 8X View Underground Sewer & Water King Power Equipment Operators- Bump Cutter $68.55 7A 3K 8X View Underground ewer a 'Water King Power Equipment Operators Cableways $69.161 7A 3K 8X View Underground Sewer Et Water King Poorer Equipment Operators- Chipper $68.55 7A 3K 8X View UrldeFground Sewer Er Water — I — King Power Equipment Operators- Compressor $65.05 7A 3K 8X View Urnder?round Sevver Et )Nater King Power Equipment Opera ors- Concrete Finish Machine - $65.05 7A 3K 8X View Underground Sewer F-- Water Laser Screed King Power Equipment O erators- Concrete Pump - Mounted Or $68.02 7A 3K _ 8X View Underground Sewer a 'Mater- Trailer High Pressure Line Pump, Pump High Pressure King Power Equipment Operators- Concrete Pump: Truck Mount $69.16 7A 3K 8X View Underground Sewer I&I Water With Boom Attachment Over 42 M King Power Egjil menr: uperamrs- Concrete Pump: Truck Mount $68.55 7A 3K 8X View UnderRMUnd Sewer Et Y/ater With Boom Attachment Up To 42m King Power Equipment Operators- Conveyors $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Cperatirs- Cranes friction: 200 tons and $71.26 7A 3K 8X View Underground Sewer ft Water over King $69.851 7A 3K 8X View https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 Power Equipment Opp ors- Cranes: 100 tons through 199 Underground. Sewer a ..ater tons, or 150' of boom (including jib with attachments) King 'ower E a.uipment Operators- Cranes: 20 Tons Through 44 $68.55 7A 3K 8X View En er-round Sewer & 'Nater Tons With Attachments King Power Equipment Operators- Cranes: 200 tons- 299 tons, $70.57 7A 3K r8X View Underground Sewer Et water or 250' of boom including jib with attachments King Power Equipn,,er'tt Operators= Cranes: 300 tons and over or $71.26 7A 3K View Underground Sewer Et Water 300' of boom including jib with attachments King Power Egr,ipmerit Operators Cranes: 45 Tons Through 99 $69.16 7A 3K 8X View Underground Sewer Et_Wattir. Tons, Under 159 Of Boom (including Jib With Attachments) King Powcs- E-ui rnen Operators, Cranes: A-frame - 10 Tons $65.05 7A 3K 8X View Underground Sewe. Et Vlater And Under King mower- Equipment Qperators Cranes: Friction cranes $70.57 7A 3K 8X View Under round Sewer Er Water through 199 tons King Power Equipment Operators- Cranes: through 19 tons with $68.02 7A 3K 8X View Underground Sewer Et Water attachments, A-frame over 10 tons King Power Equipment Operators- Crusher $68.55 7A 3K 8X View Underground Sewer Ft 0/ater King Power Equipment Operators- Deck Engineer/Deck Winches $68.55 7A 3K 8X View Underground Scwf r _4 `ddatcr (power) King Power Equiorr,ent Opera tor,- Derricks, On Building Work $69.16 7A 3K 8X View Underground Server et Water King Power Equi aient Operators- Dozers D-9 Et Under $68.02 7A 3K 8X View Underground Se,,ver EL Water King Power E-uipxnent Operators- Drill Oilers: Auger Type, $68.02 7A 3K 8X View Underground Sewer Et Wager. Truck Or Crane Mount u. King Power Equipment OLeratars- Drilling Machine $69.85 7A 3K 8X View Underground Sewer Et Water King Power Ec uipment 'Operators- Elevator And Man-lift: $65.05 7A 3K 8X View Underground Sewer Et Water Permanent And Shaft Type King Power Eeluipment Operators- Finishing Machine, Bidwell $68.55 7A 3K 8X View Undero,r?din f Sewer Et Water- And Gamaco Et Similar Equipment King Power Equipment Operators- Forklift: 3000 Lbs And Over $68.02 7A 3K 8X View Underground Sewer Et `Nater With Attachments King Power Equipment Operators- Forklifts: Under 3000 Lbs. $65.05 7A 3K 8X View Underground Sewer Et Water With Attachments King Power Equipment Operators- Grade Engineer: Using Blue $68.55 7A 3K 8X I View Underground Se�nlrr E 'later Prints, Cut Sheets, Etc King Power Equipment Operators Gradechecker/Stakeman $65.05 7A 3K 8X View Underground S�s/er_ � UVat�er King Power,Equipment Opera.vors- Guardrail Punch $68.55 7A 3K 8X View Under round Sewer Et Water King Power Equip enL 0�7eratrxs- $69.16 7A 3K 8X View Under round_Sewer It Wac�-r https://fortress.wa.gov/lni/wagelookup/prvWagetookup.aspx 1/27/2020 Hard Tail End Dump Articulating Off- Road Equipment 45 Yards. Et Over King Power' Equipment Operators- Hard Tail End Dump $68.55 7A 3K 8X View Under 3r ound Sew.es & WdLer, Articulating Off-road Equipment Under 45 Yards King Power Erluiprnent 7peraLors- Horizontal/Directional Drill $68.02 7A 3K 8X View Underground Sewer- ft Water Locator King Power Equipment Onerwors- Horizontal/Directional Drill $68.55 7A 3K 8X View Under_round Sewer & water Operator King Power Equipment Operators- Hydralifts/Boom Trucks Over $68.02 7A 3K 8X 1 View Undergroun! Sewer a Water 10 Tons King Power Equipment Operators- Hydralifts/Boom Trucks, 10 $65.05 7A 3K 8X View Underground Sewer & Water Tons And Under King Power Equipment Operators Loader, Overhead 8 Yards. Et $69.85 7A 3K 8X View Underground Sewer Et Water Over King Plower Equipment Operators_ Loader, Overhead, 6 Yards. $69.16 7A 3K 8X View Serres-Underground a 'Nater But Not Including 8 Yards King Power Equipmene Operators- Loaders, Overhead Under 6 $68.55 7A 3K 8X View Underground Sewer Ft 'Nater Yards King Power E ui ment O er_itor;- Loaders, Plant Feed $68.55 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Loaders: Elevating Type Belt $68.02 7A 3K 8X View Underground Sewer_a` -jter King 'rawer Egpuigment Operators- Locomotives, All $68.55 7A 3K 8X View r.1ndergr4L;nd ]ewer 8: )Naar King Power E ui rnef,t Operators- Material Transfer Device $68.55 7A 3K 8X View Underground Sever Ft `Na!_:�r King Power Equipment Operators- Mechanics, All (leadmen - $69.85 7A 3K 8X View . Underizraind Sewer EL Water $0.50 Per Hour Over Mechanic) King Power Equipment O erators- Motor Patrol Graders $69.16 7A 3K 8X View Underground Sewer Et +dates- King Power Equipment Operatirs Mucking Machine, Mole, $69.16 7A 3K 8X View Underground Sewer Et Water Tunnel Drill, Boring, Road Header And/or Shield King Power-EciL3ipment Operators= Oil Distributors, Blower $65.05 7A 3K 8X View Underground Sewer Et `Nater Distribution Et Mulch Seeding Operator King Power Equipment Operators Outside Hoists (Elevators And $68.02 7A 3K 8X View Underground Sewer Et Water Manlifts), Air Tuggers, Strato King Power Equi mint Operators_ Overhead, Bridge Type $68.55 7A 3K 8X View Underground Sewer Et Water Crane: 20 Tons Through 44 Tons King Power Equipment Operators. Overhead, Bridge Type: 100 $69.85 7A 3K 8X View Underground Sewer 8: Water Tons And Over King Power Equipment Operators- Overhead, Bridge Type: 45 $69.16 7A 3K 8X View Underground Se-,r/er Et Water Tons Through 99 Tons King Power EQUi sneit Operators, Pavement Breaker $65.05 7A 3K 8X View Under round Sewer Et Wader King Power Equipment Ope,ators- Pile Driver (other Than Crane $68.55 7A 3K 8X View Underground Sewer rs °Placer Mount) https://fortress.wa.gov/lni/wagelookup/pr-vWagelookup.aspx 1/27/2020 King Power Equipment Ope rs- Plank Oiler- Asphalt, Crusher $68.' 7A 3K 8X View lUnder.,jr)und Sewer Et 'Natar King Power Equipment Opera;ors- Posthole Digger, Mechanical $65.05 7A 3K 8X View Underground Sewer' Et Water King Power E;juipment Operators- Power Plant $65.05 7A 3K 8X View Underground Sewer ft Water King Power- Equiprrrent O 2e-ator;- Pumps - Water $65.05 7A 3K 8X View Underground Sewer a Water- — King Power Equipment Opfrators- Quad 9, Hd 41, D10And Over $69.16 7A 3K 8X View Underground Sewer a: Water King Power Equipment Operators- Quick Tower- No Cab, Under $65.05 7A 3K 8X View Underground Se,,ver EL Wader` 100 Feet In Height Based To Boom King Power Equipment Operators- Remote Control Operator On $69.16 7A 3K 8X View Underground Sewer Et Water Rubber Tired Earth Moving Equipment ,King Power Equipment_Operators- Rigger and Bellman $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Rigger/Signal Person, $68.02 7A 3K 8X View Underground Sewer Et Water Bellman (Certified) King Power Equipment Operators- Rollagon $69.16 7A 3K 8X View Underground Sewer It Water King Power Equipment Operators- Roller, Other Than Plant Mix $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators Roller, Plant Mix Or Multi-lift $68.02 7A 3K 8X View Underground Sewer 8:Water Materials King Power E^ui rner t Operators- Roto-mill, Roto-grinder $68.55 7A 3K 8X View Underground Sewer Et Water — King Power Equipment O erators• Saws - Concrete $68.02 7A 3K 8X View Underground Sewer & Water King Power Equipment Operators- Scraper, Self Propelled $68.55 7A 3K 8X View Underground Sewer Et Water Under 45 Yards King Power Equipment Operators- Scrapers - Concrete Et Carry $68.02 7A 3K 8X View Underground Sewer Et Water All King Power Equipment Operators- Scrapers, Self-propelled: 45 $69.16 7A 3K 8X View Underground Sewer Et Water Yards And Over King Power E ui ment Operators- Service Engineers - $68.02 7A 3K 8X View Underground Sewer- Ft Water Equipment King Power Equipment Operators- Shotcrete/Gunite Equipment $65.05 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Shovel, Excavator, Backhoe, $68.02 7A 3K 8X View Underground Sewer & Water- Tractors Under 15 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoe: $69.16 7A 3K 8X View Underground Sewer & Water Over 30 Metric Tons To 50 Metric Tons King Power Equipment Operators- Shovel, Excavator, Backhoes, $68.55 7A 3K 8X View Underground Sewer Et Water Tractors: 15 To 30 Metric Tons King Power Equipment Operatcrs- Shovel, Excavator, Backhoes: $69.85 7A 3K 8X View Underground Sewer Et Water Over 50 Metric Tons To 90 Metric Tons iittps://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 King bower Eguiom_ent Opera__ys- Shovel, Excavator, Backhoes: $70.5 7A 3K 8X View Underground Sewer Et Water Over 90 Metric Tons King Power Equipment O erators- Slipform Pavers $69.16 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators Spreader, Topsider Et $69.16 7A 3K 8X View Underground Sewer £t Water Screedman King Power Equipment Operators_ Subgrader Trimmer $68.55 7A 3K 8X I View Underground Sewer Et Water King Power Equipment Operators- Tower Bucket Elevators $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment. Operators- Tower Crane Up To 175' In $69.85 7A 3K 8X View Underground Sewer Et dater Height Base To Boom King Power Equipment Operators- Tower Crane: over 175' $70.57 7A 3K 8X View Underground Sewer Et Water through 250' in height, base to boom King Power Equipment Operators- Tower Cranes: over 250' in $71.26 7A 3K 8X View Underground Sewer Et Water height from base to boom King Power Equipment_Operators- Transporters, All Track Or $69.16 7A 3K 8X View Underground Sewer Et Water Truck Type King Power Equipment Operators- Trenching Machines $68.02 7A 3K 8X View Underground Sewer Et Water King Power Equipment Operators- Truck Crane Oiler/driver - $68.55 7A 3K 8X View Underground Sewer & Water 100 Tons And Over King Power E ui merit 0 erators- Truck Crane Oiler/Driver $68.02 7A 3K 8X View Underground Sewer Et Water Under 100 Tons King Power Equipment 4 erators- Truck Mount Portable $68.55 7A 3K 8X View Underground Sewer & Water Conveyor King Power Equipment Operators Welder $69.16 7A 3K 8X View Underground Sewer Et Water King Power EQuipment Operators- Wheel Tractors,.Farman $65.05 7A 3K 8X View Underground Sewer & Water Type ^ ,King Power Equipment Operators- Yo Yo Pay Dozer $68.55 7A 3K 8X View Underground Sewer Et Water King Power Line Clearance Tree Journey Level In Charge $50.96 5A 4A View Trimmers King Power Line Clearance Tree Spray Person $48.35 5A 4A View Trimmers King Puwer Liiie Clearance Tree Tree Equipment Operator $50.96 5A 4A View Trimmers King Power Line Clearance Tree Tree Trimmer $45.54 5A 4A View Trimmers II King Power Line Clearance Tree Tree Trimmer Groundperson $34.51 5A 4A View Trimmers King Refrigeration Et Air Journey Level $82.51 6Z 1G View Ccnditionin Mechanics King Residential Brick Mason Journey Level $58.82 5A 1M View King Residential Carpenters Journey Level $32.06 1 View King Residential Cement Masons Journey Level $29.25 1 View King Residential Drywall Journey Level $46.43 7A 4C View Apgticators King IResidentiaL Drywall Tapers lJourney Level $47.171 1E View https:Hfortress.wa.gov/tni/wagelookup/prvWagelookup.aspx 1/27/2020 King Residential Electrician: Journey Level $36.( 1 View King Residential Glaziers Journey Level $44.151 7L 1H View King Residential Insulation Journey Level $29.87 1 View Applicators King Residential Laborers Journey Level $26.18 1 View King Residential Marble Setters Journey Level $27.38 1 View King Residential Painters Journey Level $27.80 1 View King Residential Plumbers Et Journey Level $39.43 1 View Pi efitters King Residential Refrigeration Et Journey Level $54.12 5A 1G View Air Conditioning Mechanics King Residential Sheet Metal Journey Level (Field or Shop) $51.89 7F 1R View Workers King Residential Soft Floor Layers Journey Level $51.071 5A 3J View King Residential Sprinkier Fitters Journey Level $48.18 5C 2R View (Fire Protection) King Residential Stone Masons Journey Level $58.82 5A 1M View King Residential Terrazzo Workers Journey Level $54.061 5A I 1M View King Residential Terrazzo/Tile Journey Level $24.39 1 View Finishers King Residential Tile Setters Journey Level $21.04 1 View King Roofers Journey Level $53.27 5A 3H View King Roofers Using Irritable Bituminous $56.27 5A 3H View Materials King Sheet Meta(Workers Journey Level (Field or Shop) $85.881 7F 1E View King Shipbuilding Et Ship Repair New Construction $36.36 7V 1 View Boilermaker King Shigbuitding Et S Re airNew Construction Carpenter $36.36 7V 1 View King Shipbuilding, Et Ship R_ epair New Construction Crane $36.36 7V 1 View Operator King Shipbuilding Ft Ship Repair New Construction Electrician $36.36 7V 1 View King Shipbuilding, Et Ship epair- New Construction Heat Et $76.61 5J 4H View Frost Insulator King Shilpbuilding Et Ship Repair New Construction Laborer, $36.36 7V 1 View King Shipbuilding, Et Ship Repair New Construction Machinist $36.36 7V 1 View King Shipbuilding Et Ship Repair- New Construction Operating $36.36 7V 1 View Engineer King LShipbuilding ShipbuildingEt Ship Repair New Construction Painter $36.36 7V 1 View King Shipbuilding Et Shin Repair New Construction Pipefitter $36.36 7V 1 View King. ShipbuildingShipbuiLding Et Ship Repair New Construction Rigger $36.36 7V 1 View King Shipbuilding Et Ship Repair New Construction Sheet $36.36 7V 1 View Metal King Shipbuilding Et Ship Repair New Construction Shipfitter $36.36 7V 1 View King Shilabuilding Et Sh"rp Repair New Construction $36.36 7V 1 View Warehouse/Teamster King Shipbuilding Et Ship Re ai€ New Construction Welder / $36.36 7V 1 View Burner King Shipbuilding Et Ship Repair Ship Repair Boilermaker $46.15 7X 4J View https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 King SNpbuitdin¢ Et Ship Ref- Ship Repair Carpenter $44.5 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Crane Operator $45.06 7Y 4K View King Shipbuilding_k_Shi RP air Ship Repair Electrician $46.15 7X 4J View King Shipbuilding Et Ship Repair Ship Repair Heat Et Frost $76.61 5.1 4H View Insulator King Shipbuilding Et Ship Repair Ship Repair Laborer $46.15 7X 4.1 View King Shipbuilding Et Ship Repair Ship Repair Machinist $46.15 7X 4.1 View King Shipbuilding Et Ship Repair Ship Repair Operating $45.06 7Y 4K View Engineer King Shipbuilding Et Ship Repair Ship Repair Painter $46.151 7X 4.1 View King Shipbuitding EEt_Shp Repair Ship Repair Pipefitter $46.151 7X 4.1 View King Shipbuilding Et Ship Repair Ship Repair Rigger $46.15 7X 4J i View King Shipbuilding Et. Ship Repair Ship Repair Sheet Metal $46.15 7X 4J View King ah it�building Et Ship Repair Ship Repair Shipwright $44.95 7X 4.1 View King Shipbuilding Et Ship Repair Ship Repair Warehouse / $45.06 7Y 4K View Teamster King Sign Makers Et Instatle_rs Journey Level $50.90 0 1 View f Electrical) King Sign Makers Et Installers Journey Level $31.52 0 1 View. Non-Electrical King Soft Ftoor Layers Journey Level $51.07 5A 3J View King Solar Controls For Windows Journey Level $13.50 1 View King Sprinkler Fitters (Fire Journey Level $81.39 5C 1X View Protection) King Stage Rigging Mechanics (Non Journey Level $13.50 1 View Structural) King Stone Masons Journey Level $58.82 5A 2View King Street and Parking i_ot Journey Level $19.09 1 View Sweeper Workers King Surveyors Assistant Construction Site $68.02 7A 3K 8X View Surveyor King Surveyors Chainman $65.05 7A I 3K 8X View King Surveyors Construction Site Surveyor $69.16 7A 3K 8X View King Telecommunication Journey Level $51.07 7E 1E View Technicians King Telephone Line Construction Cable Splicer $41.81 5A 2B View - Outside King Telephone Line Construction Hole Digger/Ground Person $23.53 5A 2B View - Outside ;King Telephone Line Construction Installer (Repairer) $40.09 5A 2B View - Outside King Telephone tine Construction Special Aparatus Installer 1 $41.81 5A 2B View - Outside King Tetephone Line Construction Special Apparatus Installer II $40.99 5A 2B View - Outside King Telephone Line Construction Telephone Equipment $41.81 5A 2B View - Outside Operator (Heavy) King Telephone Line Construction_ Telephone Equipment $38.92 5A 2B View Outside Operator (Light) https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 King [,--tept,one Lime Const- on Tetephone Lineperson $38.' 5A 2B View Outside King Telephone Line Construction Television Groundperson $22.32 5A � 2B View - Outside King Telephone_Ure 'Construction Television $29.60 5A 2B View - Outside Lineperson/Installer King Telephone Line Construction Television System Technician $35.20 5A 2B I View - Outside King Telephone line Construction Television Technician $31.67 5A 2B View - Outside King Teleahone Line Construction Tree Trimmer $38.92 5A 2B View - Outside Kina Terrazzo Workers Journey Level $54.06SA 1M View Ding Tile Setters Journey Level $54.06 5A 1M View ;King Tile. Marbie a._Terrazzo Finisher $44.89 5A 1B View Finishers King Traffic Control SLijp-e s Journey Level $47.68 7A 1K View King Truck Drivers Asphalt Mix Over 16 Yards $61.59 5D 4Y 8L View King Truck Drivers Asphalt Mix To 16 Yards $60.75 5D 4Y 8L View King Truck Drivers Dump Truck $60.75 5D 4Y 8L View King Truck Drivers Dump Truck Et Trailer $61.59 5D 4Y 8L View King Truck Drivers Other Trucks $61.59 5D 4Y 8L View King ITruck Drivers - Ready AX Transit Mix $61.59 5D 4Y 8L View King Neil Drillers a Irrigation (Irrigation Pump Installer $17.71 1 View Pump lnstaliars J King Well Drillers Ft Irri ation Oiler $13.50 1 View Pump Installers � King Well Drillers_a lr'.igatron Well Driller $18.00 1 View Pump instaltvrs https://fortress.wa.gov/lni/wagelookup/prvWagelookup.aspx 1/27/2020 EXHIBIT "J" INTRODUCTION TO THE SPECIAL PROVISIONS (August 14, 2013 APWA GSP) The work on this project shall be accomplished in accordance with the Standard Specifications for Road, Bridge and Municipal Construction, 2020 edition, as issued by the Washington State Department of Transportation (WSDOT) and the American Public Works Association (APWA), Washington State Chapter (hereafter "Standard Specifications"). The Standard Specifications, as modified or supplemented by the Amendments to the Standard Specifications and these Special Provisions, all of which are made a part of the Contract Documents, shall govern all of the Work. These Special Provisions are made up of both General Special Provisions (GSPs) from various sources, which may have project-specific fill-ins; and project-specific Special Provisions. Each Provision either supplements, modifies, or replaces the comparable Standard Specification, or is a new Provision. The deletion, amendment, alteration, or addition to any subsection or portion of the Standard Specifications is meant to pertain only to that particular portion of the section, and in no way should it be interpreted that the balance of the section does not apply. The project-specific Special Provisions are not labeled as such. The GSPs are labeled under the headers of each GSP, with the effective date of the GSP and its source. For example: (March 8, 2013 APWA GSP) (April 1, 2013 WSDOT GSP) (April 12, 2018 CFW GSP) (***PROJECT-SPECIFIC SPECIAL PROVISION***) Also incorporated into the Contract Documents by reference are: Manual on Uniform Traffic Control Devices for Streets and Highways, currently adopted edition, with Washington State modifications, if any WSDOT Standard Plans City of Federal Way Public Works Development Standards National Electric Code, current edition Contractor shall obtain copies of these publications, at Contractor's own expense. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SPA CFW SPECIAL PROVISIONS VER. 2019.12 DIVISION 1 GENERAL REQUIREMENTS DESCRIPTION OF WORK (March 13, 1995 WSDOT GSP) This Contract provides for the improvement of the 2020-2021 Neighborhood Traffic Safety (NTS) Program and other work, all in accordance with the attached Contract Plans, these Contract Provisions, and the Standard Specifications. 1-01.3 Definitions (January 4, 2016 APWA GSP) Delete the heading Completion Dates and the three paragraphs that follow it, and replace them with the following: Dates Bid Opening Date The date on which the Contracting Agency publicly opens and reads the Bids. Award Date The date of the formal decision of the Contracting Agency to accept the lowest responsible and responsive Bidder for the Work. Contract Execution Date The date the Contracting Agency officially binds the Agency to the Contract. Notice to Proceed Date The date stated in the Notice to Proceed on which the Contract time begins. Substantial Completion Date The day the Engineer determines the Contracting Agency has full and unrestricted use and benefit of the facilities, both from the operational and safety standpoint, any remaining traffic disruptions will be rare and brief, and only minor incidental work, replacement of temporary substitute facilities, plant establishment periods, or correction or repair remains for the Physical Completion of the total Contract. Physical Completion Date The day all of the Work is physically completed on the project. All documentation required by the Contract and required by law does not necessarily need to be furnished by the Contractor by this date. Completion Date The day all the Work specified in the Contract is completed and all the obligations of the Contractor under the contract are fulfilled by the Contractor. All documentation required by the Contract and required by law must be furnished by the Contractor before establishment of this date. Final Acceptance Date The date on which the Contracting Agency accepts the Work as complete. Supplement this Section with the following: All references in the Standard Specifications, Amendments, or WSDOT General Special Provisions, to the terms "Department of Transportation", "Washington State Transportation Commission", "Commission", "Secretary of Transportation", "Secretary", "Headquarters", and "State Treasurer" shall be revised to read "Contracting Agency." CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-2 CFW SPECIAL PROVISIONS VER. 2019.12 All references to the terms "State" or "state" shall be revised to read "Contracting Agency" unless the reference is to an administrative agency of the State of Washington, a State statute or regulation, or the context reasonably indicates otherwise. All references to "State Materials Laboratory" shall be revised to read "Contracting Agency designated location." All references to "final contract voucher certification" shall be interpreted to mean the Contracting Agency form(s) by which final payment is authorized, and final completion and acceptance granted. Additive A supplemental unit of work or group of bid items, identified separately in the Bid Proposal, which may, at the discretion of the Contracting Agency, be awarded in addition to the base bid. Alternate One of two or more units of work or groups of bid items, identified separately in the Bid Proposal, from which the Contracting Agency may make a choice between different methods or material of construction for performing the same work. Business Day A business day is any day from Monday through Friday except holidays as listed in Section 1-08.5. Contract Bond The definition in the Standard Specifications for "Contract Bond" applies to whatever bond form(s) are required by the Contract Documents, which may be a combination of a Payment Bond and a Performance Bond. Contract Documents See definition for"Contract." Contract Time The period of time established by the terms and conditions of the Contract within which the Work must be physically completed. Notice of Award The written notice from the Contracting Agency to the successful Bidder signifying the Contracting Agency's acceptance of the Bid Proposal. Notice to Proceed The written notice from the Contracting Agency or Engineer to the Contractor authorizing and directing the Contractor to proceed with the Work and establishing the date on which the Contract time begins. Traffic Both vehicular and non-vehicular traffic, such as pedestrians, bicyclists, wheelchairs, and equestrian traffic. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-3 CFW SPECIAL PROVISIONS VER. 2019.12 1-02 BID PROCEDURES AND !20NDITIONS 1-02.1 Prequalification of Bidders Delete this Section and replace it with the following: 1-02.1 Qualifications of Bidder (January 24, 2011 APWA GSP) Before award of a public works Contract, a bidder must meet at least the minimum qualifications of RCW 39.04.350(1) to be considered a responsible bidder and qualified to be awarded a public works project. 1-02.2 Plans and S ecifications (June 27, 2011 APWA GSP) Delete this section and replace it with the following: Information as to where Bid Documents can be obtained or reviewed can be found in the Call for Bids (Advertisement for Bids)for the work. After award of the Contract, Plans and specifications will be issued to the Contractor at no cost as detailed below: To Prime Contractor No. of Basis of Distribution Sets Reduced Plans (11" x 17") 1 Furnished automatically upon award. Contract Provisions 1 Furnished automatically upon award. Large Plans (e.g., 22" x 34") 1 Furnished only upon request. Additional Plans and Contract Provisions may be obtained by the Contractor from the source stated in the Call for Bids, at the Contractor's own expense. 1-02.4 Examination of Plans, Specifications, and Site Work (June 27, 2011 APWA GSP) 1-02.4(1) General (August 15, 2016 APWA GSP, Option B) The first sentence of the last paragraph is revised to read: Any prospective Bidder desiring an explanation or interpretation of the Bid Documents, shall request the explanation or interpretation in writing by close of business three (3) business days preceding the bid opening to allow a written reply to reach all prospective Bidders before the submission of their Bids. 1-02.4(2) Subsurface Information (March S, 2013 APWA GSP) The second sentence in the first paragraph is revised to read: The Summary of Geotechnical Conditions and the boring logs, if and when included as an appendix to the Special Provisions, shall be considered as part of the Contract. 1-02.5 Proposal Forms (July 31, 2017 APWA GSP) Delete this section and replace it with the following: CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-4 CFW SPECIAL PROVISIONS VER. 2019.12 The Proposal Form will identify the project and its location and describe the work. It will also list estimated quantities, units of measurement, the items of work, and the materials to be furnished at the unit bid prices. The bidder shall complete spaces on the proposal form that call for, but are not limited to, unit prices; extensions; summations; the total bid amount; signatures; date; and, where applicable, retail sales taxes and acknowledgment of addenda; the bidder's name, address, telephone number, and signature; the bidder's UBDE/DBE/MNVBE commitment, if applicable; a State of Washington Contractor's Registration Number; and a Business License Number, if applicable. Bids shall be completed by typing or shall be printed in ink by hand, preferably in black ink. The required certifications are included as part of the Proposal Form. The Contracting Agency reserves the right to arrange the proposal forms with alternates and additives, if such be to the advantage of the Contracting Agency. The bidder shall bid on all alternates and additives set forth in the Proposal Form unless otherwise specified. 1-02.6 Preparation of Proposal (July 11, 2018 APWA GSP) Supplement the second paragraph with the following: 4. If a minimum bid amount has been established for any item, the unit or lump sum price must equal or exceed the minimum amount stated. 5. Any correction to a bid made by interlineation, alteration, or erasure, shall be initialed by the signer of the bid. Delete the last two paragraphs, and replace them with the following: If no Subcontractor is listed, the Bidder acknowledges that it does not intend to use any Subcontractor to perform those items of work. The Bidder shall submit with their Bid a completed Contractor Certification Wage Law Compliance form, provided by the Contracting Agency. Failure to return this certification as part of the Bid Proposal package will make this Bid Nonresponsive and ineligible for Award. A Contractor Certification of Wage Law Compliance form is included in the Proposal Forms. The Bidder shall make no stipulation on the Bid Form, nor qualify the bid in any manner. A bid by a corporation shall be executed in the corporate name, by the president or a vice president (or other corporate officer accompanied by evidence of authority to sign). A bid by a partnership shall be executed in the partnership name, and signed by a partner. A copy of the partnership agreement shall be submitted with the Bid Form if any UDBE requirements are to be satisfied through such an agreement. A bid by a joint venture shall be executed in the joint venture name and signed by a member of the joint venture. A copy of the joint venture agreement shall be submitted with the Bid Form if any UDBE requirements are to be satisfied through such an agreement. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-5 CFW SPECIAL PROVISIONS VER. 2019.12 Add the following new section: 1-02.6(1) Recycled Materials Proposal (January 4, 2016 APWA GSP) The Bidder shall submit with the Bid, its proposal for incorporating recycled materials into the project, using the form provided in the Contract Provisions. 1-02.7 Bid De osit (March 8, 2013 APWA GSP) Supplement this section with the following: Bid bonds shall contain the following: 1. Contracting Agency-assigned number for the project; 2. Name of the project; 3. The Contracting Agency named as obligee; 4. The amount of the bid bond stated either as a dollar figure or as a percentage which represents five percent of the maximum bid amount that could be awarded; 5. Signature of the bidder's officer empowered to sign official statements. The signature of the person authorized to submit the bid should agree with the signature on the bond, and the title of the person must accompany the said signature; 6. The signature of the surety's officer empowered to sign the bond and the power of attorney. If so stated in the Contract Provisions, bidder must use the bond form included in the Contract Provisions. If so stated in the Contract Provisions, cash will not be accepted for a bid deposit. 1-02.9 DeliveEy of Proposal (May 17, 2018 APWA GSP, OPTION A) Delete this section and replace it with the following: Each Proposal shall be submitted in a sealed envelope, with the Project Name and Project Number as stated in the Call for Bids clearly marked on the outside of the envelope, or as otherwise required in the Bid Documents, to ensure proper handling and delivery be considered responsive on a FHWA-funded project, the Bidder may be required to submit the following items, as required by Section 1-02.6: • UDBE Written Confirmation Document from each UDBE firm listed on the Bidder's completed UDBE Utilization Certification (WSDOT 272-056U) • Good Faith Effort (GFE) Documentation These documents, if applicable, shall be received either with the Bid Proposal or as a supplement to the Bid. These documents shall be received no later than 24 hours (not including Saturdays, Sundays and Holidays) after the time for delivery of the Bid Proposal. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-6 CFW SPECIAL PROVISIONS VER. 2019.12 If submitted after the Bid Proposal is due, the document(s) must be submitted in a sealed envelope labeled the same as for the Proposal, with "Supplemental Information" added. All other information required to be submitted with the Bid Proposal must be submitted with the Bid Proposal itself, at the time stated in the Call for Bids. The Contracting Agency will not open or consider any Bid Proposal that is received after the time specified in the Call for Bids for receipt of Bid Proposals, or received in a location other than that specified in the Call for Bids. The Contracting Agency will not open or consider any "Supplemental Information" (UDBE confirmations, or GFE documentation) that is received after the time specified above, or received in a location other than that specified in the Call for Bids. 1-02.10 Withdrawing, Revising, or Supplementing Proposal (July 23, 2015 APWA GSP) Delete this section, and replace it with the following: After submitting a physical Bid Proposal to the Contracting Agency, the Bidder may withdraw, revise, or supplement it if: 1. The Bidder submits a written request signed by an authorized person and physically delivers it to the place designated for receipt of Bid Proposals, and 2. The Contracting Agency receives the request before the time set for receipt of Bid Proposals, and 3. The revised or supplemented Bid Proposal (if any) is received by the Contracting Agency before the time set for receipt of Bid Proposals. If the Bidder's request to withdraw, revise, or supplement its Bid Proposal is received before the time set for receipt of Bid Proposals, the Contracting Agency will return the unopened Proposal package to the Bidder. The Bidder must then submit the revised or supplemented package in its entirety. If the Bidder does not submit a revised or supplemented package, then its bid shall be considered withdrawn. Late revised or supplemented Bid Proposals or late withdrawal requests will be date recorded by the Contracting Agency and returned unopened. Mailed, emailed, or faxed requests to withdraw, revise, or supplement a Bid Proposal are not acceptable. 1-02.13 Irregular Proposals (June 20, 2017 APWA GSP) Delete this section and replace it with the following: 1. A Proposal will be considered irregular and will be rejected if: a. The Bidder is not prequalified when so required; b. The authorized Proposal form furnished by the Contracting Agency is not used or is altered; C. The completed Proposal form contains any unauthorized additions, deletions, alternate Bids, or conditions; d. The Bidder adds provisions reserving the right to reject or accept the award, or enter into the Contract; e. A price per unit cannot be determined from the Bid Proposal; CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-7 CFW SPECIAL PROVISIONS VER. 2019.12 f. The Proposal form is not properly executed; g. The Bidder fails to submit or properly complete a Subcontractor list, if applicable, as required in Section 1-02.6; h. The Bidder fails to submit or properly complete an Underutilized Disadvantaged Business Enterprise Certification, if applicable, as required in Section 1-02.6; i. The Bidder fails to submit written confirmation from each UDBE firm listed on the Bidder's completed UDBE Utilization Certification that they are in agreement with the bidder's UDBE participation commitment, if applicable, as required in Section 1-02.6, or if the written confirmation that is submitted fails to meet the requirements of the Special Provisions; i The Bidder fails to submit UDBE Good Faith Effort documentation, if applicable, as required in Section 1-02.6, or if the documentation that is submitted fails to demonstrate that a Good Faith Effort to meet the Condition of Award was made; k. The Bid Proposal does not constitute a definite and unqualified offer to meet the material terms of the Bid invitation; or I. More than one Proposal is submitted for the same project from a Bidder under the same or different names. 2. A Proposal may be considered irregular and may be rejected if: a. The Proposal does not include a unit price for every Bid item; b. Any of the unit prices are excessively unbalanced (either above or below the amount of a reasonable Bid) to the potential detriment of the Contracting Agency; C. Receipt of Addenda is not acknowledged; d. A member of a joint venture or partnership and the joint venture or partnership submit Proposals for the same project (in such an instance., both Bids may be rejected); or e. If Proposal form entries are not made in ink. 1-02.14 Disqualification of Bidders (May 17, 2018 APWA GSP, OPTION B) Delete this section and replace it with the following: A Bidder will be deemed not responsible if the Bidder does not meet the mandatory bidder responsibility criteria in RCW 39.04.350(1), as amended; or does not meet Supplemental Criteria 1-7 listed in this Section. Contracting Agency will verify that the Bidder meets the mandatory bidder responsibility criteria in RCW 39.04.350(1), and Supplemental Criteria 1-2. Evidence that the Bidder meets Supplemental Criteria 3-7 shall be provided by the Bidder as stated later in this Section. 1. Delinquent State Taxes A. Criterion: The Bidder shall not owe delinquent taxes to the Washington State Department of Revenue without a payment plan approved by the Department of Revenue. B. Documentation: The Bidder, if and when required as detailed below, shall sign a statement (on a form to be provided by the Contracting Agency) that the Bidder does not owe delinquent taxes to the Washington State Department of Revenue, or if delinquent taxes are owed to the Washington State Department of Revenue, the Bidder must submit a written payment plan CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-8 CFW SPECIAL PROVISIONS VER. 2019.12 approved by the Department of Revenue, to the Contracting Agency by the deadline listed below. 2. Federal Debarment A. Criterion: The Bidder shall not currently be debarred or suspended by the Federal government. B. Documentation: The Bidder shall not be listed as having an "active exclusion" on the U.S. government's "System for Award Management" database (www.sam.gov). 3. Subcontractor Responsibility A. Criterion: The Bidder's standard subcontract form shall include the subcontractor responsibility language required by RCW 39.06.020, and the Bidder shall have an established procedure which it utilizes to validate the responsibility of each of its subcontractors. The Bidder's subcontract form shah also include a requirement that each of its subcontractors shall have and document a similar procedure to determine whether the sub-tier subcontractors with whom it contracts are also "responsible" subcontractors as defined by RCW 39.06.020. B. Documentation: The Bidder, if and when required as detailed below, shall submit a copy of its standard subcontract form for review by the Contracting Agency, and a written description of its procedure for validating the responsibility of subcontractors with which it contracts. 4. Claims Against Retainage and Bonds A. Criterion: The Bidder shall not have a record of excessive claims filed against the retainage or payment bonds for public works projects in the three years prior to the bid submittal date, that demonstrate a lack of effective management by the Bidder of making timely and appropriate payments to its subcontractors, suppliers, and workers, unless there are extenuating circumstances and such circumstances are deemed acceptable to the Contracting Agency. B. Documentation: The Bidder, if and when required as detailed below, shall submit a list of the public works projects completed in the three years prior to the bid submittal date that have had claims against retainage and bonds and include for each project the following information: • Name of project • The owner and contact information for the owner; • A list of claims filed against the retainage and/or payment bond for any of the projects listed; • A written explanation of the circumstances surrounding each claim and the ultimate resolution of the claim. 5. Public. Bidding Crime CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-9 CFW SPECIAL PROVISIONS VER. 2019.12 A. Criterion: The Bidder and/or its owners shall not have been convicted of a crime involving bidding on a public works contract in the five years prior to the bid submittal date. B. Documentation: The Bidder, if and when required as detailed below, shall sign a statement (on a form to be provided by the Contracting Agency) that the Bidder and/or its owners have not been convicted of a crime involving bidding on a public works contract. 6. Termination for Cause/Termination for Default A. Criterion: The Bidder shall not have had any public works contract terminated for cause or terminated for default by a government agency in the five years prior to the bid submittal date, unless there are extenuating circumstances and such circumstances are deemed acceptable to the Contracting Agency. B. Documentation: The Bidder, if and when required as detailed below, shall sign a statement (on a form to be provided by the Contracting Agency) that the Bidder has not had any public works contract terminated for cause or terminated for default by a government agency in the five years prior to the bid submittal date; or if Bidder was terminated, describe the circumstances. . 7. Lawsuits A. Criterion: The Bidder shall not have lawsuits with judgments entered against the Bidder in the five years prior to the bid submittal date that demonstrate a pattern of failing to meet the terms of contracts, unless there are extenuating circumstances and such circumstances are deemed acceptable to the Contracting Agency B. Documentation: The Bidder, if and when required as detailed below, shall sign a statement (on a form to be provided by the Contracting Agency) that the Bidder has not had any lawsuits with judgments entered against the Bidder in the five years prior to the bid submittal date that demonstrate a pattern of failing to meet the terms of contracts, or shall submit a list of all lawsuits with judgments entered against the Bidder in the five years prior to the bid submittal date, along with a written explanation of the circumstances surrounding each such lawsuit. The Contracting Agency shall evaluate these explanations to determine whether the lawsuits demonstrate a pattern of failing to meet of terms of construction related contracts As evidence that the Bidder meets the Supplemental Criteria stated above, the apparent low Bidder must submit to the Contracting Agency by 12:00 P.M. (noon) of the second business day following the bid submittal deadline, a written statement verifying that the Bidder meets the supplemental criteria together with supporting documentation (sufficient in the sole judgment of the Contracting Agency) demonstrating compliance with the Supplemental Criteria. The Contracting Agency reserves the right to request further documentation as needed from the low Bidder and documentation from other Bidders as well to assess Bidder responsibility and compliance with all bidder responsibility criteria. The Contracting Agency also reserves the right to obtain information from third-parties and independent sources of information concerning a Bidder's compliance with the mandatory and supplemental criteria, and to use that CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-10 CFW SPECIAL PROVISIONS VER. 2019.12 information in their evaluation. The Contracting Agency may consider mitigating factors in determining whether the Bidder complies with the requirements of the supplemental criteria. The basis for evaluation of Bidder compliance with these mandatory and supplemental criteria shall include any documents or facts obtained by Contracting Agency (whether from the Bidder or third parties) including but not limited to: (i) financial, historical, or operational data from the Bidder; (ii) information obtained directly by the Contracting Agency from others for whom the Bidder has worked, or other public agencies or private enterprises; and (iii) any additional information obtained by the Contracting Agency which is believed to be relevant to the matter. If the Contracting Agency determines the Bidder does not meet the bidder responsibility criteria above and is therefore not a responsible Bidder, the Contracting Agency shall notify the Bidder in writing, with the reasons for its determination. If the Bidder disagrees with this determination, it may appeal the determination within two (2) business days of the Contracting Agency's determination by presenting its appeal and any additional information to the Contracting Agency. The Contracting Agency will consider the appeal and any additional information before issuing its final determination. If the final determination affirms that the Bidder is not responsible, the Contracting Agency will not execute a contract with any other Bidder until at least two business days after the Bidder determined to be not responsible has received the Contracting Agency's final determination. Request to Change Supplemental Bidder Responsibility Criteria Prior To Bid: Bidders with concerns about the relevancy or restrictiveness of the Supplemental Bidder Responsibility Criteria may make or submit requests to the Contracting Agency to modify the criteria. Such requests shall be in writing, describe the nature of the concerns, and propose specific modifications to the criteria. Bidders shall submit such requests to the Contracting Agency no later than five (5) business days prior to the bid submittal deadline and address the request to the Project Engineer or such other person designated by the Contracting Agency in the Bid Documents. 1-03 AWARD AND EXECUTION OF CONTRACT 1-03.1 Consideration of Bids (January 23, 2006 APINA GSP) Revise the first paragraph to read: After opening and reading proposals, the Contracting Agency will check them for correctness of extensions of the prices per unit and the total price. If a discrepancy exists between the price per unit and the extended amount of any bid item, the price per unit will control. If a minimum bid amount has been established for any item and the bidder's unit or lump SLIM price is less than the minimum specified amount, the Contracting Agency will unilaterally revise the unit or lump sum rice. to the minimum specified amount and recalculate the extension. The total of extensions, corrected where necessary, including sales taxes where applicable and such additives and/or alternates as selected by the Contracting Agency, will be used by the Contracting Agency for award purposes and to fix the Awarded Contract Price amount and the amount of the contract bond. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SPA CFW SPECIAL PROVISIONS VER. 2019.12 1-03.1(1) Identical Bid Totals (January 4, 2016 APWA GSP) Revise this section to read: After opening Bids, if two or more lowest responsive Bid totals are exactly equal, then the tie-breaker will be the Bidder with an equal lowest bid. that proposed to use the highest percentage of recycled materials in the Project, per the form submitted with the Bid Proposal. If those percentages are also exactly eaual, then the tie-breaker will be determined by drawing as follows: Two or more slips of paper will be marked as follows: one marked "Winner" and the other(s) marked "unsuccessful." The slips will be folded to make the marking unseen. The slips will be placed inside a box. One authorized representative of each Bidder shall draw a slip from the box. Bidders shall draw in alphabetic order by the name of the firm as registered with the Washington State Department of Licensing. The slips shall be unfolded and the firm with the slip marked "Winner' will be determined to be the successful Bidder and eligible for Award of the Contract. Only those Bidders who submitted a Bid total that is exactly equal to the lowest responsive Bid, and with a proposed recycled materials percentage that is exactly eaUal to the highest proposed recycled materials amount, are eligible to draw. 1-03.3 Execution of Contract (October 1, 2005 APWA GSP) Revise this section to read: Copies of the Contract Provisions. including the unsigned Form of Contract, will be available for signature by the successful bidder on the first business day following award. The number of copies to be executed by the Contractorwill be determined by the Contracting Aggncy_. Within 10 calendar days after the award date, the successful bidder shall return the signed Contracting Agency-prepared contract, an insurance certification as required by Section 1-07.18, and a satisfactory bond as required by law and Section 1-03.4. Before execution of the contract by the Contracting Agency, the successful bidder shall provide any pre-award information the Contracting Agency may require under Section 1-02.15. Until the Contracting Agency executes a contract, no proposal shall bind the Contracting Agency nor shall any work begin within the project limits or within Contracting Agency- furnished sites. The Contractor shall bear all risks for any work begun outside such areas and for any materials ordered before the contract is executed by the Contracting Agency. If the bidder experiences circumstances beyond their control that prevents return of the contract documents within the calendar days after the award date stated above, the Contracting Agency may grant up to a maximum of 5 additional calendar days for return of the documents, provided the Contracting Agency deems the circumstances warrant it. 1-03.4 Contract Bond (July 23, 2015 APWA GSP) Delete the first paragraph and replace it with the following: The successful bidder shall provide executed payment and performance bond(s) for the full contract amount. The bond may be a combined payment and performance bond; or be separate payment and performance bonds. In the case of separate payment and performance bonds, each shall be for the full contract amount. The bond(s) shall: CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-12 CFW SPECIAL PROVISIONS VER. 2019.12 1. Be on Contracting Agency-furnished form(s); 2. Be signed by an approved surety (or sureties) that: a. Is registered with the Washington State Insurance Commissioner, and b. Appears on the current Authorized Insurance List in the State of Washington published by the Office of the Insurance Commissioner, 3. Guarantee that the Contractor will perform and comply with all obligations, duties, and conditions under the Contract, including but not limited to the duty and obligation to indemnify, defend, and protect the Contracting Agency against all losses and claims related directly or indirectly from any failure: a. Of the Contractor (or any of the employees, subcontractors, or lower tier subcontractors of the Contractor) to faithfully perform and comply with all contract obligations, conditions, and duties, or b. Of the Contractor (or the subcontractors or lower tier subcontractors of the Contractor) to pay all laborers, mechanics, subcontractors, lower tier subcontractors, material person, or any other person who provides supplies or provisions for carrying out the work; 4. Be conditioned upon the payment of taxes, increases, and penalties incurred on the projert under titles 50, 51, and 82 RCW; and 5. Be accompanied by a power of attorney for the Surety's officer empowered to sign the bond; and 6. Be signed by an officer of the Contractor empowered to sign official statements (sole proprietor or partner). If the Contractor is a corporation, the bond(s) must be signed by the president or vice president, unless accompanied by written proof of the authority of the individual signing the bond(s) to bind the corporation (i.e., corporate resolution, power of attorney, or a letter to such effect signed by the president or vice president). 1-03.7 Judicial Review (November 30, 2018 APWA GSP) Revise this section to read: Any decision made by the Contracting Agency regarding the Award and execution of the Contract or Bid rejection shall be conclusive subject to the scope of judicial review permitted under Washington Law. Such review, if any, shall be timely filed in the Superior Court of the county where the Contracting Agency headquarters is located, provided that where an action is asserted against a county, RCW 36.01.050 shall control venue and jurisdiction. 1-04 SCOPE OF THE WORK 1-04.2 Coordination of Contract Documents, Plans, Special Provisions, Specifications, and Addenda CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-13 CFW SPECIAL PROVISIONS VER. 2019.12 (April 12, 2019 CFW GSP) Revise the second paragraph to read: Any inconsistency in the parts of the contract shall be resolved by following this order of precedence (e.g., 1 presiding over 2, 2 over 3, 3 over 4, and so forth): 1. Contract, 2. Change Orders, with those of a later date taking precedence of those of an earlier date, 3. Addenda, with those of a later date taking precedence of those of an earlier date, 4. Bid Proposal Form, 5. Special Provisions, 6. Contract Plans, 7. Amendments to the Standard Specifications, 8. Standard Specifications, 9. Contracting Agency's Standard Plans or Details (if any), and 10. WSDOT Standard Plans for Road, Bridge, and Municipal Construction. 1-05 CONTROL OF WORK 1-05.4 Conformity With and Deviations from Plans and Stakes (April 2, 2018, WSDOT GSP, OPTION 4) Section 1-05.4 is supplemented with the following: Contractor Surveying -ADA Features ADA Feature Staking Requirements The Contractor shall be responsible for setting, maintaining, and resetting all alignment stakes, and grades necessary for the construction of the ADA features. Calculations, surveying, and measuring required for setting and maintaining the necessary lines and grades shall be the Contractor's responsibility. The Contractor shall build the ADA features within the specifications in the Standard Plans and contract documents. ADA Feature As-Built Measurements The Contractor shall be responsible for providing electronic As-Built records of all ADA feature improvements completed in the Contract. The survey work shall include but not be limited to completing the measurements, recording the required measurements and completing other data fill-ins found on the ADA Measurement Forms, and transmitting the electronic Forms to the Engineer. The ADA Measurement Forms are found at the following website location: http://www.wsdot.wa.gov/Design/ADAGuidance.htm In the instance where an ADA Feature does not meet accessibility requirements, all work to replace non-conforming work and then to measure, record the as-built measurements, and transmit the electronic Forms to the Engineer shall be CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-14 CFW SPECIAL PROVISIONS VER. 2019.12 completed at no additional cost to the Contracting Agency, as ordered by the Engineer. Payment Payment will be made for the following bid item that is included in the Proposal: "ADA Features Surveying", lump sum. The unit Contract price per lump sum for "ADA Features Surveying" shall be full pay for all the Work as specified. 1-05.7 Removal of Defective and Unauthorized Work (October 1, 2005 APWA GSP) Supplement this section with the following: If the Contractor fails to remedy defective or unauthorized work within the time specified in a written notice from the Engineer, or fails to perform any part of the work required by the Contract Documents, the Engineer may correct and remedy such work as may be identified in the written notice, with Contracting Agency forces or by such other means as the Contracting Agency may deem necessary. If the Contractor fails to comply with a written order to remedy what the Engineer determines to be an emergency situation, the Engineer may have the defective and unauthorized work corrected immediately, have the rejected work removed and replaced, or have work the Contractor refuses to perform completed by using Contracting Agency or other forces. An emergency situation is any situation when, in the opinion of the Engineer, a delay in its remedy could be potentially unsafe, or might cause serious risk of loss or damage to the public. Direct or indirect costs incurred by the Contracting Agency attributable to correcting and remedying defective or unauthorized work, or work the Contractor failed or refused to perform, shall be paid by the Contractor. Payment will be deducted by the Engineer from monies due, or to become due, the Contractor. Such direct and indirect costs shall include in particular, but without limitation, compensation for additional professional services required, and costs for repair and replacement of work of others destroyed or damaged by correction, removal, or replacement of the Contractor's unauthorized work. No adjustment in Contract time or compensation will be allowed because of the delay in the performance of the work attributable to the exercise of the Contracting Agency's rights provided by this section. The rights exercised under the provisions of this section shall not diminish the Contracting Agency's right to pursue any other avenue for additional remedy or damages with respect to the Contractor's failure to perform the work as required. 1-05.11 Final Inspection (October 1, 2005 APWA GSP) Delete this section and replace it with the following: 1-05.11 Final Inspections and Operational Testing CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SPA CFW SPECIAL PROVISIONS VER. 2019.12 1-05.11(1) Substantial Completion Date When the Contractor considers the work to be substantially complete, the Contractor shall so notify the Engineer and request the Engineer establish the Substantial Completion Date. The Contractor's request shall list the specific items of work that remain to be completed in order to reach physical completion. The Engineer will schedule an inspection of the work with the Contractor to determine the status of completion. The Engineer may also establish the Substantial Completion Date unilaterally. If, after this inspection, the Engineer concurs with the Contractor that the work is substantially complete and ready for its intended use, the Engineer, by written notice to the Contractor, will set the Substantial Completion Date. If, after this inspection the Engineer does not consider the work substantially complete and ready for its intended use, the Engineer will, by written notice, so notify the Contractor giving the reasons therefore. Upon receipt of written notice concurring in or denying substantial completion, whichever is applicable, the Contractor shall pursue vigorously, diligently and without unauthorized interruption, the work necessary to reach Substantial and Physical Completion. The Contractor shall provide the Engineer with a revised schedule indicating when the Contractor expects to reach substantial and physical completion of the work. The above process shall be repeated until the Engineer establishes the Substantial Completion Date and the Contractor considers the work physically complete and ready for final inspection. 1-05.11(2) Final Inspection and Physical Completion_Date When the Contractor considers the work physically complete and ready for final inspection, the Contractor by written notice, shall request the Engineer to schedule a final inspection. The Engineer will set a date for final inspection. The Engineer and the Contractor will then make a final inspection and the Engineer will notify the Contractor in writing of all particulars in which the final inspection reveals the work incomplete or unacceptable. The Contractor shall immediately take such corrective measures as are necessary to remedy the listed deficiencies. Corrective work shall be pursued vigorously, diligently, and without interruption until physical completion of the listed deficiencies. This process will continue until the Engineer is satisfied the listed deficiencies have been corrected. If action to correct the listed deficiencies is not initiated within 7 days after receipt of the written notice listing the deficiencies, the Engineer may, upon written notice to the Contractor, take whatever steps are necessary to correct those deficiencies pursuant to Section 1-05.7. The Contractor will not be allowed an extension of Contract time because of a delay in the performance of the work attributable to the exercise of the Engineer's right hereunder. Upon correction of all deficiencies, the Engineer will notify the Contractor and the Contracting Agency, in writing, of the date upon which the work was considered CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-16 CFW SPECIAL PROVISIONS VER. 2019.12 physically complete. That date shall constitute the Physical Completion Date of the Contract, but shall not imply acceptance of the work or that all the obligations of the Contractor under the Contract have been fulfilled. 1-05.11(3) Operational Testing It is the intent of the Contracting Agency to have at the Physical Completion Date a complete and operable system. Therefore when the work involves the installation of machinery or other mechanical equipment; street lighting, electrical distribution or signal systems; irrigation systems; buildings; or other similar work it may be desirable for the Engineer to have the Contractor operate and test the work for a period of time after final inspection but prior to the physical completion date. Whenever items of work are listed in the Contract Provisions for operational testing they shall be fully tested under operating conditions for the time period specified to ensure their acceptability prior to the Physical Completion Date. During and following the test period, the Contractor shall correct any items of workmanship, materials, or equipment which prove faulty, or that are not in first class operating condition. Equipment, electrical controls, meters, or other devices and equipment to be tested during this period shall be tested under the observation of the Engineer, so that the Engineer may determine their suitability for the purpose for which they were installed. The Physical Completion Date cannot be established until testing and corrections have been completed to the satisfaction of the Engineer. The costs for power, gas, labor, material, supplies, and everything else needed to successfully complete operational testing, shall be included in the unit Contract prices related to the system being tested, unless specifically set forth otherwise in the Proposal. Operational and test periods, when required by the Engineer, shall not affect a manufacturer's guaranties or warranties furnished under the terms of the Contract. 1-05.12 Final Acceptance (April 12, 2019 CFW GSP) Delete the third and fourth sentences in the first paragraph and replace it with the following: Final acceptance date of the work shall be the date the Federal Way City Council accepts the project as complete. Add the following new section. 1-05.120) One-Year Guarantee Period (March 8, 2013 APWA GSP) The Contractor shall return to the project and repair or replace all defects in workmanship and material discovered within one year after Final Acceptance of the Work. The Contractor shall start work to remedy any such defects within 7 calendar days of receiving Contracting Agency's written notice of a defect, and shall complete such work within the time stated in the Contracting Agency's notice. In case of an emergency, where damage may result from delay or where loss of services may result, such corrections may be made by the Contracting Agency's own forces or another contractor, In which case the cost of corrections shall be paid by the Contractor. In the event the Contractor does not accomplish corrections within the time specified, the work will be otherwise accomplished and the cost of same shall be paid by the Contractor. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-17 CFW SPECIAL PROVISIONS VER. 2019.12 When corrections of defects are made, the Contractor shall then be responsible for correcting all defects in workmanship and materials in the corrected work for one year after acceptance of the corrections by Contracting Agency. This guarantee is supplemental to and does not limit or affect the requirements that the Contractor's work comply with the requirements of the Contract or any other legal rights or remedies of the Contracting Agency. '1-05.13 Superintendents, Labor and Equipment of Contractor (August 14, 2013 APWA GSP) Delete the sixth and seventh paragraphs of this section. 1-05.15 Method of Serving Notices (March 25, 2009 APWA GSP) Revise the second paragraph to read: All correspondence from the Contractor shall be directed to the Project Engineer. All correspondence from the Contractor constituting any notification, notice of protest, notice of dispute, or other correspondence constituting notification required to be furnished under the Contract, must be in paper format, hand delivered or sent via mail delivery service to the Project Engineer's office. Electronic copies such as e-mails or electronically delivered copies of correspondence will not constitute such notice and will not comply with the requirements of the Contract. Add the following new section: 1-05.16 Water and Power (October 1, 2005 APWA GSP) The Contractor shall make necessary arrangements, and shall bear the costs for power and water necessary for the performance of the work, unless the Contract includes power and water as a pay item. 1-05.18 Contractor's Daily Mary (April 12, 2018 CFW GSP) Section 1-05.18 is a new section: The Contractor and subcontractors, as additional consideration for payment for this contract work, hereby agree to maintain and provide to the Owner and the Engineer a Daily Diary Record of this Work. The diary must be kept and maintained by the Contractor's designated project superintendent. Entries must be made on a daily basis and must accurately represent all of the project activities on each day. At a minimum, the diary shall show on a daily basis: The day and date. ® The weather conditions, including changes throughout the day. ® A complete description of work accomplished during the day with adequate references to the Plans and Specifications so that the reader can easily and accurately identify said work on the Plans. An entry for each and every changed condition, dispute or potential dispute, incident, accident, or occurrence of any nature whatsoever which might affect the Contract, Owner, or any third party in any manner. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SPA 8 CFW SPECIAL PROVISIONS VER. 2019.12 • Listing of any materials received and stored on or off-site by the Contractor for future installation, to include the manner of storage and protection of the same. • Listing of materials installed during each day. • List of all subcontractors working on-site during each day. • Listing of the number of Contractor's employees working during each day by category of employment. • Listing of Contractor's equipment working on the site during each day. Idle equipment on the site shall be listed and designated as idle. • Notations to explain inspections, testing, stake-out, and all other services furnished to the Contractor by the Owner or other during each day. • Entries to verify the daily (including non-work days) inspection and maintenance of traffic control devices and condition of the traveled roadway surfaces. The Contractor shall not allow any conditions to develop that would be hazardous to the public. • Any other information that serves to give an accurate and complete record of the nature, quantity, and quality of the Contractor's progress on each day. • Summary of total number of working days to date, and total number of delay days to date. The Contractor's designated project superintendent must sign the diary at the end of each working day. The Contractor must provide a copy of the diary to the Owner and the Engineer each morning for the preceding workday.All copies must be legible. It is expressly agreed between the contractor and the owner that the daily diary maintained by the Contractor shall be the "Contractor's Book of Original Entry" for the documentation of any potential claims or disputes that might arise during this contract. Failure of the Contractor to maintain this diary in the manner described above will constitute a waiver of any such claims or disputes by the Contractor. The daily diary maintained by the Contractor does not constitute the official record of the project. The official record of the project is prepared and maintained exclusively by the engineer. 1-05.19 Defects Arising in One Year and Remedies (February 15, 2019 CFW GSP) Section 1-05.19 is a new section: The Contractor shall, at its own sole cost and expense, be responsible for correcting all defects in workmanship and material discovered within one year after acceptance of this work by the City of Federal Way. When corrections of defects are made, the Contractor shall be responsible for correcting all defects in workmanship and/or materials in the corrected work for one year after acceptance of the corrections by the Owner. Conducting of tests and inspections, review of specifications or plans, payment for goods or services, or acceptance by the City does not constitute waiver, modification, or exclusion of any express or implied warranty or any right under law. This warranty shall survive termination of this Contract. The Contractor shall start work to remedy such defects within seven (7) calendar days of mailing notice of discovery thereof by the Owner and shall complete such work within a reasonable time. In emergencies, where damage may result from delay or where loss of services may result, such corrections may be made by the Owner, in which case the cost shall be borne by the Contractor. In the event the Contractor does not accomplish CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SPA 9 CFW SPECIAL PROVISIONS VER. 2019.12 corrections at the time specified, the work will be otherwise accomplished and the cost of same shall be paid by the Contractor. These actions will be pursuant to the provisions of Section 1-05.8 of the Standard Specifications. The Contractor shall be liable for any costs, losses, expenses, or damages, including consequential damages suffered by the Owner resulting from defects in the Contractor's work including, but not limited to, cost of materials and labor extended by Owner in making emergency repairs and cost of engineering, inspection and supervision by the Owner or the Engineer. The Contractor shall hold the Owner harmless from any and all claims which may be made against the Owner as a result of any defective work, and the Contractor shall defend any such claims at his own expense. The Contractor agrees the above one-year limitation shall not exclude or diminish the Owner's rights under any law to obtain damages and recover costs resulting from defective and unauthorized work discovered after one year but prior to the expiration of the legal time period set forth in RCW 9.16.040 limiting actions upon a contract in writing or liability, expressed or implied, arising out of a written agreement. This warranty may also extend beyond the one year time period pursuant to any other warranties specified in the Special Provisions, Contract Plans, other parts of the Contract Documents, or incorporated by this reference. 1-06 CONTROL OF MATERIAL 1-06.6 Recycled Materials (January 4, 2016 APWA GSP) Delete this section, including its subsections, and replace it with the following: The Contractor shall make their best effort to utilize recycled materials in the construction of the project. Approval of such material use shall be as detailed elsewhere in the Standard Specifications. Prior to Physical Completion the Contractor shall report the quantity of recycled materials that were utilized in the construction of the project for each of the items listed in Section 9-03.21. The report shall include hot mix asphalt, recycled concrete aggregate, recycled glass, steel furnace slag and other recycled materials (e.g. utilization of on-site material and aggregates from concrete returned to the supplier). The Contractor's report shall be provided on DOT form 350-075 Recycled Materials Reporting. 1-06.7 Hazardous Chemicals (April 12, 2019 CFW GSP) Section 1-06.7 is a new section: In order to comply with WAC 296-62-054 Hazard Communication, the Contractor shall submit with each shipment a Material Safety Data Sheet (MSDS) for all products containing any toxic products that may be harmful to the end user. The MSDS Sheet is to accompany the toxic product(s) to the specified delivery sites. Include the following in the MSDS: A. Chemical Abstract Service (CAS) numbers for every chemical that is listed in the MSDS. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-20 CFW SPECIAL PROVISIONS VER. 2019.12 B. If the product is actually used diluted, the dilution rate should be so stated in the MSDS and the hazards and corresponding personal protection, etc., also be listed. C. A statement as to the intended use of the product. 1-07 LEGAL RELATIONS AND RESPONSIBILITIES TO THE PUBLIC 1-07.1 Laws to be Observed (October 1, 2005 APWA GSP) Supplement this section with the following: In cases of conflict between different safety regulations, the more stringent regulation shall apply. The Washington State Department of Labor and Industries shall be the sole and paramount administrative agency responsible for the administration of the provisions of the Washington Industrial Safety and Health Act of 1973 (WISHA). The Contractor shall maintain at the project site office, or other well-known place at the project site, all articles necessary for providing first aid to the injured. The Contractor shall establish, publish, and make known to all employees, procedures for ensuring immediate removal to a hospital, or doctor's care, persons, including employees, who may have been injured on the project site. Employees should not be permitted to work on the project site before the Contractor has established and made known procedures for removal of injured persons to a hospital or a doctor's care. The Contractor shall have sole responsibility for the safety, efficiency, and adequacy of the Contractor's Plant, appliances, and methods, and for any damage or injury resulting from their failure, or improper maintenance, use, or operation. The Contractor shall be solely and completely responsible for the conditions of the project site, including safety for all persons and property in the performance of the work. This requirement shall apply continuously, and not be limited to normal working hours. The required or implied duty of the Engineer to conduct construction review of the Contractor's performance does not, and shall not, be intended to include review and adequacy of the Contractor's safety measures in, on, or near the project site. Section 1-07.1 is supplemented with the following: (April 12, 2019 CFW GSP) Confined Space Confined spaces are known to exist at the following locations: Existing storm drainage, sanitary sewer, and other utility systems, vaults, and structures, along with all new similar new construction items that meet the requirements of WAC 296-809-100. The Contractor shall be fully responsible for the safety and health of all on-site workers and compliant with Washington Administrative Code (WAC 296-809). The Contractor shall prepare and implement a confined space program for each of the confined spaces identified above. The Contractors Confined Space program shall be sent to the contracting agency at least 5 days prior to the Contractor beginning work in or adjacent to the confined space. No work shall be performed in or adjacent to the CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-21 CFW SPECIAL PROVISIONS VER. 2019.12 confined space until the plan is submitted to the Engineer as required. The Contractor shall communicate with the Engineer to ensure a coordinated effort for providing and maintaining a safe worksite for both the Contracting Agency's and Contractor's workers when working in or near a confined space. All costs to prepare and implement the confined space program shall be included in the bid prices for the various items associated with the confined space work. 1-07.2 State Taxes Delete this section, including its sub-sections, in its entirety and replace it with the following: 1-07.2 State Sales Tax (June 27, 2011 APWA GSP) The Washington State Department of Revenue has issued special rules on the State sales tax. Sections 1-07.2(1) through 1-07.2(3) are meant to clarify those rules. The Contractor should contact the Washington State Department of Revenue for answers to questions in this area. The Contracting Agency will not adjust its payment if the Contractor bases a Bid on a misunderstood tax liability. The Contractor shall include all Contractor-paid taxes in the unit Bid prices or other Contract amounts. In some cases, however, state retail sales tax will not be included. Section 1-07.2(2) describes this exception. The Contracting Agency will pay the retained percentage (or release the Contract Bond if a FHWA-funded Project) only if the Contractor has obtained from the Washington State Department of Revenue a certificate showing that all Contract-related taxes have been paid (RCW 60.28.051). The Contracting Agency may deduct from its payments to the Contractor any amount the Contractor may owe the Washington State Department of Revenue, whether the amount owed relates to this Contract or not. Any amount so deducted will be paid into the proper State fund. 1-07.2(1) State Sales Tax— Rule 171 WAC 458-20-171, and its related rules, apply to building, repairing, or improving streets, roads, etc., which are owned by a municipal corporation, or political subdivision of the state, or by the United States, and which are used primarily for foot or vehicular traffic. This includes storm or combined sewer systems within and included as a part of the street or road drainage system and power lines when such are part of the roadway lighting system. For work performed in such cases, the Contractor shall include Washington State Retail Sales Taxes in the various unit Bid item prices, or other Contract amounts, including those that the Contractor pays on the purchase of the materials, equipment, or supplies used or consumed in doing the work. 1-07.2(2) State Sales Tax— Rule 170 WAC 458-20-170, and its related rules, apply to the constructing and repairing of new or existing buildings, or other structures, upon real property. This includes, but is not limited to, the construction of streets, roads, highways, etc., owned by the state of Washington; water mains and their appurtenances; sanitary sewers and sewage disposal systems unless such sewers and disposal systems are within, and a part of, a street or road drainage system; telephone, telegraph, CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-22 CFW SPECIAL PROVISIONS VER. 2019.12 electrical power distribution lines, or other conduits or lines in or above streets or roads, unless such power lines become a part of a street or road lighting system; and installing or attaching of any article of tangible personal property in or to real property, whether or not such personal property becomes a part of the realty by virtue of installation. For work performed in such cases, the Contractor shall collect from the Contracting Agency, retail sales tax on the full Contract price. The Contracting Agency will automatically add this sales tax to each payment to the Contractor. For this reason, the Contractor shall not include the retail sales tax in the unit Bid item prices, or in any other Contract amount subject to Rule 170, with the following exception. Exception: The Contracting Agency will not add in sales tax for a payment the Contractor or a subcontractor makes on the purchase or rental of tools, machinery, equipment, or consumable supplies not integrated into the project. Such sales taxes shall be included in the unit Bid item prices or in any other Contract amount. 1.07.2(3) Services The Contractor shall not collect retail sales tax from the Contracting Agency on any Contract wholly for professional or other services (as defined in Washington State Department of Revenue Rules 138 and 244). 1-07.6 Permits and Licenses (April 12, 2018 CFW GSP) Section 1-07.6 is supplemented with the following: Survey Monuments In accordance with RCW 58.24.040(8), no cadastral or geodetic survey monument may be disturbed without a valid permit to remove or destroy a survey monument, issued by the Washington State Department of Natural Resources. Permit applications can be obtained on the DNR Public Land Survey Office website. The permit application must be stamped by a registered Washington State Land Surveyor. The Contractor shall obtain the permit to Remove or Destroy a Survey Monument as necessary. All costs to obtain and comply with the permit shall be considered incidental to other bid items and no additional payment will be made. 1-07.7 Load Limits (March 13, 1995 WSDOT GSP, OPTION 6) Section 1-07.7 is supplemented with the following: If the sources of materials provided by the Contractor necessitate hauling over roads other than State Highways, the Contractor shall, at the Contractor's expense, make all arrangements for the use of the haul routes. 1-07.9(5) Required Documents Section 1-07.9(5) is revised to read (January 6, 2020, WSDOT GSP, OPT 1) CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-23 CFW SPECIAL PROVISIONS VER. 2019.12 General All "Statements of Intent to Pay Prevailing Wages", "Affidavits of Wages Paid" and 3 Certified Payrolls, including a signed Statement of Compliance for Federal-aid 4 projects, shall be submitted to the Engineer using the State L&I online Prevailing 5 Wage Intent &Affidavit (PWIA) system. Intents and Affidavits On forms provided by the Industrial Statistician of State L&I, the Contractor shall 9 submit to the Engineer the following for themselves and for each firm covered 10 under RCW 39.12 that will or has provided Work and materials for the Contract: 1. The approved "Statement of Intent to Pay Prevailing Wages" State L&I's form number F700- 029-000. The Contracting Agency will make no payment under this Contract until this statement has been approved by State L&I and reviewed by the Engineer. 2. The approved "Affidavit of Prevailing Wages Paid", State L&I's form number F700-007-000. The Contracting Agency will not grant Completion until all approved Affidavit of Wages paid for the Contractor and all Subcontractors have been received by the Engineer. The Contracting Agency will not release to the Contractor any funds retained under RCW 22 60.28.011 until "Affidavit of Prevailing Wages Paid"forms have been approved by State L&I and all of the approved forms have been submitted to the Engineer for every firm that worked on the Contract. The Contractor is responsible for requesting these forms from State L&I and for paying any fees required by State L&I. Certified Payrolls Certified payrolls are required to be submitted by the Contractor for themselves, all Subcontractors and all lower tier subcontractors. The payrolls shall be submitted weekly on all Federal-aid projects and no less than monthly on State funded projects. Penalties for Noncompliance The Contractor is advised, if these payrolls are not supplied within the prescribed deadlines, any or all payments may be withheld until compliance is achieved. In addition, failure to provide these payrolls may result in other sanctions as provided by State laws (RCW 39.12.050) and/or Federal regulations (29 CFR 5.12). 1-07.13 Contractor's Responsibility for Work 1-117.13(4) Repair of Damage (August 6, 2001 WSDOT GSP) Section 1-07.13(4) is revised to read: The Contractor shall promptly repair all damage to either temporary or permanent work as directed by the Engineer. For damage qualifying for relief under Sections 1-07.13(1), 1-07.13(2) or 1-07.13(3), payment will be made in accordance with Section 1-04.4. Payment will be limited to repair of damaged work only. No payment will be made for delay or disruption of work. 1-07.16 Protection and Restoration of Property 1-07.16(2) Vegetation Protection and Restoration (August 2, 2010 WSDOT GSP) CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-24 CFW SPECIAL PROVISIONS VER. 2019.12 Section 1-07.16(2) is supplemented with the following: Vegetation and soil protection zones for trees shall extend out from the trunk to a distance of 1 foot radius for each inch of trunk diameter at breast height. Vegetation and soil protection zones for shrubs shall extend out from the stems at ground level to twice the radius of the shrub. Vegetation and soil protection zones for herbaceous vegetation shall extend to encompass the diameter of the plant as measured from the outer edge of the plant. 1-07.17 Utilities and Similar Facilities (April 2, 2007 WSDOT GSP, OPTION 1) Section 1-07.17 is supplemented with the following: Locations and dimensions shown in the Plans for existing facilities are in accordance with available information obtained without uncovering, measuring, or other verification. The following addresses and telephone numbers of utility companies known or suspected of having facilities within the project limits are supplied for the Contractor's convenience. UTILITY CONTACTS Puget Sound Energy Century Link Attn: Jason Airey Attn: Tanaiya Anderson 3130 S 38th St 23315 66th Ave S Tacoma, WA 98409 Kent, WA 98032 Telephone: (206) 348-9637 Telephone: (253) 313-8961 Lakehaven Water & Sewer District Comcast Attn: Wes Hill Attn: Aaron Cantrell 31627 1 St Avenue S 4020 Auburn Way North Federal Way, WA 98003 Auburn, WA 98002 Telephone: (253)946-5440 Telephone: (253) 864-4281 King County Traffic Operations AT&T Attn: Mark Parrett Attn: Daniel McGeough 155 Monroe Ave NE 11241 Willows Rd NE, #130 Renton, WA 98056 Redmond, WA 98052 Telephone: (206) 296-8153 Telephone: (425) 896-9830 Zayo City of FW IT Dept (City Fiber) Attn: Scott Morrison Attn: Thomas Fichtner 22651 83rd Ave S 33325 8th Ave S Kent, WA 98032 Federal Way, WA 98003 Telephone: (206) 832-4862 Telephone: (253) 835-2547 ADDITIONAL CONTACTS King County METRO Transit South King Fire $ Rescue CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-25 CFW SPECIAL PROVISIONS VER. 2019.12 81270 6th Ave S, Bldg 2 31617 1 st Ave S Seattle, WA 98134 Federal Way, WA 98003 Telephone: (206) 684-2785 Telephone: (253) 946-7253 City of Federal Way Police Federal Way School District 33325 8th Ave S Attn: Transportation Department Federal Way, WA 98003 1211 S. 332nd St Telephone: (253) 835-6701 Federal Way, WA 98003 (for officer traffic control scheduling) Telephone: (253) 945-5960 Telephone: (253) 835-6767 (for traffic/ road closure issues) 1-07.18 Public Liability and Property Damage Insurance Delete this section in its entirety, and replace it with the following: 1-07.18 Insurance (January 4, 2016 APWA GSP) 1-07.18(1) General Requirements A. The Contractor shall procure and maintain the insurance described in all subsections of section 1-07.18 of these Special Provisions, from insurers with a current A. M. Best rating of not less than A-: VII and licensed to do business in the State of Washington. The Contracting Agency reserves the right to approve or reject the insurance provided, based on the insurer's financial condition. B. The Contractor shall keep this insurance in force without interruption from the commencement of the Contractor's Work through the term of the Contract and for thirty (30) days after the Physical Completion date, unless otherwise indicated below. C. If any insurance policy is written on a claims made form, its retroactive date, and that of all subsequent renewals, shall be no later than the effective date of this Contract. The policy shall state that coverage is claims made, and state the retroactive date. Claims- made form coverage shall be maintained by the Contractor for a minimum of 36 months following the Completion Date or earlier termination of this Contract, and the Contractor shall annually provide the Contracting Agency with proof of renewal. If renewal of the claims made form of coverage becomes unavailable, or economically prohibitive, the Contractor shall purchase an extended reporting period ("tail") or execute another form of guarantee acceptable to the Contracting Agency to assure financial responsibility for liability for services performed. D. The Contractor's Automobile Liability, Commercial General Liability and Excess or Umbrella Liability insurance policies shall be primary and non-contributory insurance as respects the Contracting Agency's insurance, self-insurance, or self-insured pool coverage. Any insurance, self-insurance, or self-insured pool coverage maintained by the Contracting Agency shall be excess of the Contractor's insurance and shall not contribute with it. E. The Contractor shall provide the Contracting Agency and all additional insureds with written notice of any policy cancellation, within two business days of their receipt of such notice. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-26 CFW SPECIAL PROVISIONS VER. 2019.12 F. The Contractor shall not begin work under the Contract until the required insurance has been obtained and approved by the Contracting Agency G. Failure on the part of the Contractor to maintain the insurance as required shall constitute a material breach of contract, upon which the Contracting Agency may, after giving five business days' notice to the Contractor to correct the breach, immediately terminate the Contract or, at its discretion, procure or renew such insurance and pay any and all premiums in connection therewith, with any sums so expended to be repaid to the Contracting Agency on demand, or at the sole discretion of the Contracting Agency, offset against funds due the Contractor from the Contracting Agency. H. All costs for insurance shall be incidental to and included in the unit or lump sum prices of the Contract and no additional payment will be made. 1-07.18(2) Additional Insured All insurance policies, with the exception of Workers Compensation, and of Professional Liability and Builder's Risk (if required by this Contract) shall name the following listed entities as additional insured(s) using the forms or endorsements required herein: • The Contracting Agency and its officers, elected officials, employees, agents, and volunteers. • The consultant that completed the preparation of the engineering design and project plans, and its officers, employees, agents, and subconsultants. • Consultants hired by the Contracting Agency for design, construction support, or materials testing. The above-listed entities shall be additional insured(s) for the full available limits of liability maintained by the Contractor, irrespective of whether such limits maintained by the Contractor are greater than those required by this Contract, and irrespective of whether the Certificate of Insurance provided by the Contractor pursuant to 1-07.18(4) describes limits lower than those maintained by the Contractor. For Commercial General Liability insurance coverage, the required additional insured endorsements shall be at least as broad as ISO forms CG 20 10 10 01 for ongoing operations and CG 20 37 10 01 for completed operations. 1-07.18(3) Subcontractors The Contractor shall cause each Subcontractor of every tier to provide insurance coverage that complies with all applicable requirements of the Contractor-provided insurance as set forth herein, except the Contractor shall have sole responsibility for determining the limits of coverage required to be obtained by Subcontractors. The Contractor shall ensure that all Subcontractors of every tier add all entities listed in 1-07.18(2) as additional insureds, and provide proof of such on the policies as required by that section as detailed in 1-07.18(2) using an endorsement as least as broad as ISO CG 20 10 10 01 for ongoing operations and CG 20 37 10 01 for completed operations. Upon request by the Contracting Agency, the Contractor shall forward to the Contracting Agency evidence of insurance and copies of the additional insured endorsements of each Subcontractor of every tier as required in 1-07.18(4) Verification of Coverage. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-27 CFW SPECIAL PROVISIONS VER. 2019.12 1-07.18(4) Verification of Coverage The Contractor shall deliver to the Contracting Agency a Certificate(s) of Insurance and endorsements for each policy of insurance meeting the requirements set forth herein when the Contractor delivers the signed Contract for the work. Failure of Contracting Agency to demand such verification of coverage with these insurance requirements or failure of Contracting Agency to identify a deficiency from the insurance documentation provided shall not be construed as a waiver of Contractor's obligation to maintain such insurance. Verification of coverage shall include: 1. An ACORD certificate or a form determined by the Contracting Agency to be equivalent. 2. Copies of all endorsements naming Contracting Agency and all other entities listed in 1-07.18(2) as additional insured(s), showing the policy number. The Contractor may submit a copy of any blanket additional insured clause from its policies instead of a separate endorsement. 3. Any other amendatory endorsements to show the coverage required herein. 4. A notation of coverage enhancements on the Certificate of Insurance shall not satisfy these requirements—actual endorsements must be submitted. Upon request by the Contracting Agency, the Contractor shall forward to the Contracting Agency a full and certified copy of the insurance policy(s). If Builders Risk insurance is required on this Project, a full and certified copy of that policy is required when the Contractor delivers the signed Contract for the work. 1-07.18(5) Coverages and Limits The insurance shall provide the minimum coverages and limits set forth below. Contractor's maintenance of insurance, its scope of coverage, and limits as required herein shall not be construed to limit the liability of the Contractor to the coverage provided by such insurance, or otherwise limit the Contracting Agency's recourse to any remedy available at law or in equity. All deductibles and self-insured retentions must be disclosed and are subject to approval by the Contracting Agency. The cost of any claim payments falling within the deductible or self-insured retention shall be the responsibility of the Contractor. In the event an additional insured incurs a liability subject to any policy's deductibles or self-insured retention, said deductibles or self-insured retention shall be the responsibility of the Contractor. 1-07.18(5)A Commercial General Liability Commercial General Liability insurance shall be written on coverage forms at least as broad as ISO occurrence form CG 00 01, including but not limited to liability arising from premises, operations, stop gap liability, independent contractors, products-completed operations, personal and advertising injury, and liability assumed under an insured contract. There shall be no exclusion for liability arising from explosion, collapse or underground property damage. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-28 CFW SPECIAL PROVISIONS VER. 2019.12 The Commercial General Liability insurance shall be endorsed to provide a per project general aggregate limit, using ISO form CG 25 03 05 09 or an equivalent endorsement. Contractor shall maintain Commercial General Liability Insurance arising out of the Contractor's completed operations for at least three years following Substantial Completion of the Work. Such policy must provide the following minimum limits: $1,000,000 Each Occurrence $2,000,000 General Aggregate $2,000,000 Products & Completed Operations Aggregate $1,000,000 Personal & Advertising Injury each offense $1,000,000 Stop Gap / Employers' Liability each Accident 1-07.18(5)6 Automobile Liability Automobile Liability shall cover owned, non-owned, hired, and leased vehicles; and shall be written on a coverage form at least as broad as ISO form CA 00 01. If the work involves the transport of pollutants, the automobile liability policy shall include MCS 90 and CA 99 48 endorsements. Such policy must provide the following minimum limit: $1,000,000 Combined single limit each accident 1-07.18(5)C Workers' Compensation The Contractor shall comply with Workers' Compensation coverage as required by the Industrial Insurance laws of the State of Washington. 1-07.18(5)D Excess or Umbrella Liabili#y (January 4, 2016 APWA GSP) The Contractor shall provide Excess or Umbrella Liability insurance with limits of not less than $3,000,000 each occurrence and annual aggregate. This excess or umbrella liability coverage shall be excess over and as least as broad in coverage as the Contractor's Commercial General and Auto Liability insurance. All entities listed under 1-07.18(2) of these Special Provisions shall be named as additional insureds on the Contractor's Excess or Umbrella Liability insurance policy. This requirement may be satisfied instead through the Contractor's primary Commercial General and Automobile Liability coverages, or any combination thereof that achieves the overall required limits of insurance. 1-07.18(5)J Pollution Liability (January 4, 2016 APWA GSP) The Contractor shall provide a Contractors Pollution Liability policy, providing coverage for claims involving bodily injury, property damage (including loss of use of tangible property that has not been physically injured), cleanup costs, remediation, disposal or other handling of pollutants, including costs and expenses incurred in the investigation, defense, or settlement of claims, arising out of any one or more of the following: 1. Contractor's operations related to this project. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-29 CFW SPECIAL PROVISIONS VER. 2019.12 2. Remediation, abatement, repair, maintenance or other work with lead-based paint or materials containing asbestos. 3. Transportation of hazardous materials away from any site related to this project. All entities listed under 1-07.18(2) of these Special Provisions shall be named by endorsement as additional insureds on the Contractors Pollution Liability insurance policy. Such Pollution Liability policy shall provide the following minimum limits: $1,000,000 each loss and annual aggregate 1-07.23 Public Convenience and Safe 1-07.23(1) Construction under Traffic (January 2, 2012 WSDOT GSP, OPTION 2) Section 1-07.23(1) is supplemented with the following: Work Zone Clear Zone The Work Zone Clear Zone (WZCZ) applies during working and nonworking hours. The WZCZ applies only to temporary roadside objects introduced by the Contractor's operations and does not apply to preexisting conditions or permanent Work. Those work operations that are actively in progress shall be in accordance with adopted and approved Traffic Control Plans, and other contract requirements. During nonworking hours equipment or materials shall not be within the WZCZ unless they are protected by permanent guardrail or temporary concrete barrier. The use of temporary concrete barrier shall be permitted only if the Engineer approves the installation and location. During actual hours of work, unless protected as described above, only materials absolutely necessary to construction shall be within the WZCZ and only construction vehicles absolutely necessary to construction shall be allowed within the WZCZ or allowed to stop or park on the shoulder of the roadway. The Contractor's nonessential vehicles and employees private vehicles shall not be permitted to park within the WZCZ at any time unless protected as described above. Deviation from the above requirements shall not occur unless the Contractor has requested the deviation in writing and the Engineer has provided written approval. Minimum WZCZ distances are measured from the edge of traveled way and will be determined as follows: Regulatory Distance From Posted Speed Traveled Way Feet 35 mph or less 10* 40 mph 15 CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-30 CFW SPECIAL PROVISIONS VER. 2019.12 45 to 55 mph 20 60 mph or greater 30 *or 2-feet beyond the outside edge of sidewalk Minimum Work Zone Clear Zone Distance (January 5, 2015 WSDOT GSP, OPTION 5) Section 1-07.23(1) is supplemented with the following: Lane closures are subject to the following restrictions: • Only one lane of traffic may be closed to traffic between the hours of 8:30AM and 3:30PM. • Left turns may be restricted (by the Contractor) within the project limits at the discretion of the Project Engineer. • If a lane closure is required, at least one lane of traffic (alternating directions/flagger controlled) shall be maintained at all times. • Unless otherwise approved or shown on plans, the Contractor shall maintain two-way traffic during construction. The Contractor shall maintain continuous two-way traffic along streets throughout the project site. The Contractor shall have the option, with the approval of the Engineer, of momentarily interrupting the continuous two-way traffic to allow one-way traffic. Such interruptions shall utilize qualified flaggers placed in strategic locations to insure the public safety and minimize driver confusion. A momentary interruption shall be defined as a period of time not to exceed two (2) minutes. Regardless of the period of time no queue greater than ten (10) cars in length will be allowed. • Working at night (8pm to 7am weekdays, 8 pm-9am weekends & holidays) is not mandated by the City. Should the contractor schedule project work during nighttime hours, it shall be the Contractor's responsibility to obtain any required noise variance or exemption for such work. • For approved night work, the Contractor shall, at no additional cost to the City, make all arrangements for operations during hours of darkness. Flagger stations shall be illuminated using a minimum 150-watt floodlight. Lighting used for nighttime work shall, whenever possible, be directed away from or shielded from residences and oncoming traffic. Signs and barricades shall be supplemented by Type C steady burn lights to delineate edge of roadway during the hours of darkness. • The Contractor shall keep all pedestrian routes & access points (including, but not limited to, sidewalks, and crosswalks when located within the project limits) open and clear at all times unless permitted otherwise by the Engineer in an approved traffic control plan. An ADA accessible route must be provided through the project site at all times. • Pedestrians must have access to pedestrian push buttons at all times. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-31 CFW SPECIAL PROVISIONS VER. 2019.12 • The Contractor shall provide flaggers, signs, and other traffic control devices. The Contractor shall erect and maintain all construction signs, warning signs, detour signs, and other traffic control devices necessary to warn and protect the public at all times from injury or damage as a result of the Contractor's operations which may occur on highways, roads, streets, sidewalks, or paths. No work shall be done on or adjacent to any traveled way until all necessary signs and traffic control devices are in place. • All signs and traffic control devices for the permitted closures shall only be installed during the specified hours. Construction signs, if placed earlier than the specified hours of closure, shall be turned or covered so as not to be visible to motorists • The Contractor shall be responsible for notifying all affected property owners and tenants prior to commencing the barricading of streets, alleys, sidewalks and driveways. Notifications should be at least 48 hours in advance of closures, if possible. • The Contractor shall, at all times throughout the project, conduct the work in such a manner as will obstruct and inconvenience vehicular and pedestrian traffic as little as possible. The streets, sidewalks and private driveways shall be kept open by the Contractor except for the brief periods when actual work is being done. The Contractor shall so conduct his operations so as to have under construction no greater length or amount of work than he can prosecute vigorously and he shall not open up sections of the work and leave them in an unfinished condition. • Lane closures shall not impact business accesses. All business accesses will remain open during business hours. • Lane closures shall not restrict vehicular access for buses through the project site. Bus stops shall remain ADA accessible to pedestrians at all times throughout the project If the Engineer determines the permitted closure hours adversely affect traffic, the Engineer may adjust the hours accordingly. The Engineer will notify the Contractor in writing of any change in the closure hours. Lane closures are not allowed on any of the following: 1. A holiday, 2. A holiday weekend; holidays that occur on Friday, Saturday, Sunday or Monday are considered a holiday weekend. A holiday weekend includes Saturday, Sunday, and the holiday. 3. After 12:00 PM (noon) on the day prior to a holiday or holiday weekend, and 4. Before 7:00 AM on the day after the holiday or holiday weekend. 1-07.24 Rights of Way CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-32 CFW SPECIAL PROVISIONS VER. 2019.12 (July 23, 2015 APWA GSP) Delete this section and replace it with the following: Street Right of Way lines, limits of easements, and limits of construction permits are indicated in the Plans. The Contractor's construction activities shall be confined within these limits, unless arrangements for use of private property are made. Generally, the Contracting Agency will have obtained, prior to bid opening, all rights of way and easements, both permanent and temporary, necessary for carrying out the work. Exceptions to this are noted in the Bid Documents or will be brought to the Contractor's attention by a duly issued Addendum. Whenever any of the work is accomplished on or through property other than public Right of Way, the Contractor shall meet and fulfill all covenants and stipulations of any easement agreement obtained by the Contracting Agency from the owner of the private property. Copies of the easement agreements may be included in the Contract Provisions or made available to the Contractor as soon as practical after they have been obtained by the Engineer. Whenever easements or rights of entry have not been acquired prior to advertising, these areas are so noted in the Plans. The Contractor shall not proceed with any portion of the work in areas where right of way, easements or rights of entry have not been acquired until the Engineer certifies to the Contractor that the right of way or easement is available or that the right of entry has been received. If the Contractor is delayed due to acts of omission on the part of the Contracting Agency in obtaining easements, rights of entry or right of way, the Contractor will be entitled to an extension of time. The Contractor agrees that such delay shall not be a breach of contract. Each property owner shall be given 48 hours notice prior to entry by the Contractor. This includes entry onto easements and private property where private improvements must be adjusted. The Contractor shall be responsible for providing, without expense or liability to the Contracting Agency, any additional land and access thereto that the Contractor may desire for temporary construction facilities, storage of materials, or other Contractor needs. However, before using any private property, whether adjoining the work or not, the Contractor shall file with the Engineer a written permission of the private property owner, and, upon vacating the premises, a written release from the property owner of each property disturbed or otherwise interfered with by reasons of construction pursued under this contract. The statement shall be signed by the private property owner, or proper authority acting for the owner of the private property affected, stating that permission has been granted to use the property and all necessary permits have been obtained or, in the case of a release, that the restoration of the property has been satisfactorily accomplished. The statement shall include the parcel number, address, and date of signature. Written releases must be filed with the Engineer before the Completion Date will be established. 1-07.28 Communication with Businesses and Property Owners (April 12, 2018 CFW GSP) Section 1-07.28 is added: CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-33 CFW SPECIAL PROVISIONS VER. 2019.12 The Contractor will be responsible for communicating all work activities with the property owners /tenants that are located adjacent to the project. The Contractor, along with the City's inspector & project engineer, shall have one formal meeting (door-to-door project walk-through) with the property owners/tenants prior to the start of construction. It will be the Contractor's responsibility to initiate and set up the meeting. Thereafter, the Contractor shall keep the property owners / tenants informed of their general work locations and upcoming activities by distributing a monthly status/schedule memo to the businesses. The memo shall be approved by the City's Project Engineer prior to distribution. 1-08 PROSECUTION AND PROGRESS Add the following new section: 1-08.0 Preliminary Matters (May 25, 2006 APWA GSP) 1-08.0(1) Preconstruction Conference (October 10, 2008 APWA GSP) Prior to the Contractor beginning the work, a preconstruction conference will be held between the Contractor, the Engineer, and such other interested parties as may be invited. The purpose of the preconstruction conference will be: 1. To review the initial progress schedule; 2. To establish a working understanding among the various parties associated or affected by the work; 3. To establish and review procedures for progress payment, notifications, approvals, submittals, etc.; 4. To establish normal working hours for the work; 5. To review safety standards and traffic control; and 6. To discuss such other related items as may be pertinent to the work. The Contractor shall prepare and submit at the preconstruction meeting the following: 1. A breakdown of all lump sum items; 2. A preliminary schedule of working drawing submittals; and 3. A list of material sources for approval if applicable. 1-08.0(2) Flours of Work (December 8, 2014 APWA GSP) Add the following new section: Except in the case of emergency or unless otherwise approved by the Engineer, the normal working hours for the Contract shall be any consecutive 8-hour period between 7:00 a.m. and 6:00 p.m. Monday through Friday, exclusive of a lunch break. If the Contractor desires different than the normal working hours stated above, the request must be submitted in writing prior to the preconstruction CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-34 CFW SPECIAL PROVISIONS VER. 2019.12 conference, subject to the provisions below. The working hours for the Contract shall be established at or prior to the preconstruction conference. All working hours and days are also subject to local permit and ordinance conditions (such as noise ordinances). If the Contractor wishes to deviate from the established working hours, the Contractor shall submit a written request to the Engineer for consideration. This request shall state what hours are being requested, and why. Requests shall be submitted for review no later than noon two working days prior to the day(s) the Contractor is requesting to change the hours. If the Contracting Agency approves such a deviation, such approval may be subject to certain other conditions, which will be detailed in writing. For example: 1. On non-Federal aid projects, requiring the Contractor to reimburse the Contracting Agency for the costs in excess of straight-time costs for Contracting Agency representatives who worked during such times. (The Engineer may require designated representatives to be present during the work. Representatives who may be deemed necessary by the Engineer include, but are not limited to: survey crews; personnel from the Contracting Agency's material testing lab; inspectors; and other Contracting Agency employees or third party consultants when, in the opinion of the Engineer, such work necessitates their presence.) 2. Considering the work performed on Saturdays, Sundays, and holidays as working days with regard to the contract time. 3. Considering multiple work shifts as multiple working days with respect to contract time even though the multiple shifts occur in a single 24-hour period. 4. If a 4-10 work schedule is requested and approved the non-working day for the week will be charged as a working day. 5. If Davis Bacon wage rates apply to this Contract, all requirements must be met and recorded properly on certified payroll. 1-08.1 Subcontracting (May 30, 2019 APWA GSR OPTION B) Delete the ninth paragraph, beginning with "On all projects, the Contractor shall certify...". 1-08.3 Progress Schedule 1-08.3(2)A Type A Progress Schedule (March 13, 2012 APWA GSP) Revise this section to read: The Contractor shall submit 3 copies of a Type A Progress Schedule no later than at the preconstruction conference, or some other mutually agreed upon submittal time. The schedule may be a critical path method (CPM) schedule, bar chart, or other standard schedule format. Regardless of which format used, the schedule shall identify the critical path. The Engineer will evaluate the Type A CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-35 CFW SPECIAL PROVISIONS VER. 2019.12 Progress Schedule and approve or return the schedule for corrections within 15 calendar days of receiving the submittal. 1-08.4 Prosecution of Work Delete this section and replace it with the following: 1-08.4 Notice to Proceed and Prosecution of Work (July 23, 2015 APWA GSP) Notice to Proceed will be given after the contract has been executed and the contract bond and evidence of insurance have been approved and filed by the Contracting Agency. The Contractor shall not commence with the work until the Notice to Proceed has been given by the Engineer. The Contractor shall commence construction activities on the project site within ten days of the Notice to Proceed Date, unless otherwise approved in writing. The Contractor shall diligently pursue the work to the physical completion date within the time specified in the contract. Voluntary shutdown or slowing of operations by the Contractor shall not relieve the Contractor of the responsibility to complete the work within the time(s) specified in the contract. When shown in the Plans, the first order of work shall be the installation of high visibility fencing to delineate all areas for protection or restoration, as described in the Contract. Installation of high visibility fencing adjacent to the roadway shall occur after the placement of all necessary signs and traffic control devices in accordance with 1-10.1(2). Upon construction of the fencing, the Contractor shall request the Engineer to inspect the fence. No other work shall be performed on the site until the Contracting Agency has accepted the installation of high visibility fencing, as described in the Contract. 1-08.5 Time for Completion (November 30, 2018 APWA GSP, OPTION A) Revise the third and fourth paragraphs to read: Contract time shall begin on the first working day following the Notice to Proceed Date. Each working day shall be charged to the contract as it occurs, until the contract work is physically complete. If substantial completion has been granted and all the authorized working days have been used, charging of working days will cease. Each week the Engineer will provide the Contractor a statement that shows the number of working days: (1) charged to the contract the week before; (2) specified for the physical completion of the contract; and (3) remaining for the physical completion of the contract. The statement will also show the nonworking days and any partial or whole day the Engineer declares as unworkable. Within 10 calendar days after the date of each statement, the Contractor shall file a written protest of any alleged discrepancies in it. To be considered by the Engineer, the protest shall be in sufficient detail to enable the Engineer to ascertain the basis and amount of time disputed. By not filing such detailed protest in that period, the Contractor shall be deemed as having accepted the statement as correct. If the Contractor is approved to work 10 hours a daV and 4 days a week (a 4-10 schedule) and the fifth day of the week in which a 4-10 shift is worked would ordinarily be charged as a working day then the fifth day of that week will be charged as a working day whether or not the Contractor works on that daV. Revise the sixth paragraph to read: The Engineer will give the Contractor written notice of the completion date of the contract after all the Contractor's obligations under the contract have been performed by CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-36 CFW SPECIAL PROVISIONS VER. 2019.12 the Contractor. The following events must occur before the Completion Date can be established: 1. The physical work on the project must be complete; and 2. The Contractor must furnish all documentation required by the contract and required by law, to allow the Contracting Agency to process final acceptance of the contract. The following documents must be received by the Project Engineer prior to establishing a completion date: a. Certified Payrolls (per Section 1-07.9(5)). b. Material Acceptance Certification Documents c. Monthly Reports of Amounts Credited as DBE Participation, as required by the Contract Provisions. d. Final Contract Voucher Certification e. Copies of the approved "Affidavit of Prevailing Wages Paid" for the Contractor and all Subcontractors f. A copy of the Notice of Termination sent to the Washington State Department of Ecology (Ecology); the elapse of 30 calendar days from the date of receipt of the Notice of Termination by Ecology; and no rejection of the Notice of Termination by Ecology. This requirement will not apply if the Construction Stormwater General Permit is transferred back to the Contracting Agency in accordance with Section 8-01.3(16). g. Property owner releases per Section 1-07.24 (March 13, 1995 WSDOT GSP, OPTION 7) Section 1-08.5 is supplemented with the following: This project shall be physically complete within 20 working days. 1-08.9 Liquidated Damages (December 2, 2019 WSDOT GSP, OPTION 3) Section 1-08.9 is revised to read: Time is of the essence of the Contract. Delays inconvenience the traveling public, obstruct traffic, interfere with and delay commerce, and increase risk to Highway users. Delays also cost tax payers undue sums of money, adding time needed for administration, engineering, inspection, and supervision. Accordingly, the Contractor agrees: 1. To pay liquidated damages in the amount of$550.00 for each working day beyond the number of working days established for Physical Completion, and 2. To authorize the Engineer to deduct these liquidated damages from any money due or coming due to the Contractor. When the Contract Work has progressed to the extent that the Contracting Agency has full use and benefit of the facilities, both from the operational and safety standpoint, all the initial plantings are completed and only minor incidental Work, replacement of temporary substitute facilities, plant establishment periods, or correction or repair remains to physically complete the total Contract, the Engineer may determine the CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-37 CFW SPECIAL PROVISIONS VER. 2019.12 Contract Work is substantially complete. The Engineer will notify the Contractor in writing of the Substantial Completion Date. For overruns in Contract time occurring after the date so established, liquidated damages shown above will not apply. For overruns in Contract time occurring after the Substantial Completion Date, liquidated damages shall be assessed on the basis of direct engineering and related costs assignable to the project until the actual Physical Completion Date of all the Contract Work. The Contractor shall complete the remaining Work as promptly as possible. Upon request by the Engineer, the Contractor shall furnish a written schedule for completing the physical Work on the Contract. Liquidated damages will not be assessed for any days for which an extension of time is granted. No deduction or payment of liquidated damages will, in any degree, release the Contractor from further obligations and liabilities to complete the entire Contract. 1-09 MEASUREMENT AND PAYMENT 1-09.2(1) General Requirements for Weighing Equipment (July 23, 2015 APWA GSP, OPTION 2) Revise item 4 of the fifth paragraph to read: 4. Test results and scale weight records for each day's hauling operations are provided to the Engineer daily. Reporting shall utilize WSDOT form 422-027, Scaleman's Daily Report, unless the printed ticket contains the same information that is on the Scalernan's Daily Report Form The scale operator must provide AM and/or PM tare weights for each truck on the printed ticket- 1-09.2(5) Measurement (May 2, 2017 APWA GSP) Revise the first paragraph to read: Scale Verification Checks — At the Engineer's discretion. the Engineer may perform verification checks on the accuracy of each batch, hopper, or platform scale used in weighing contract items of Work. 1-09.6 Force Account (October 10, 2008 APWA GSP) Supplement this section with the following: The Contracting Agency has estimated and included in the Proposal, dollar amounts for all items to be paid per force account, only to provide a common proposal for Bidders. All such dollar amounts are to become a part of Contractor's total bid. However, the Contracting Agency does not warrant expressly or by implication, that the actual amount of work will correspond with those estimates. Payment will be made on the basis of the amount of work actually authorized by Engineer. 1-09.7 Mobilization (April 12, 2018 CFW GSP) Supplement Section 1-09.7 with the following: Obtaining a site for the Contractor's mobilization, field office(s), storage of materials, access and personnel parking spaces, and other general operations shall be the responsibility of the Contractor. The Contactor will be responsible for maintaining these spaces in a safe and orderly condition throughout the duration of the project. The CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-38 CFW SPECIAL PROVISIONS VER. 2019.12 Contractor shall provide the City with a copy of agreement(s) with property owner. All costs associated with securing sites shall be included in the other bid items on the project and no other compensation will be made. 1-09.9 Payments (March 13, 2012 APWA GSP) Delete the first four paragraphs and replace them with the following: The basis of payment will be the actual quantities of Work performed according to the Contract and as specified for payment. The Contractor shall submit a breakdown of the cost of lump sum bid items at the Preconstruction Conference, to enable the Project Engineer to determine the Work performed on a monthly basis. A breakdown is not required for lump sum items that include a basis for incremental payments as part of the respective Specification. Absent a lump sum breakdown, the Project Engineer will make a determination based on information available. The Project Engineer's determination of the cost of work shall be final. Progress payments for completed work and material on hand will be based upon progress estimates prepared by the Engineer. A progress estimate cutoff date will be established at the preconstruction conference. The initial progress estimate will be made not later than 30 days after the Contractor commences the work, and successive progress estimates will be made every month thereafter until the Completion Date. Progress estimates made during progress of the work are tentative, and made only for the purpose of determining progress payments. The progress estimates are subject to change at any time prior to the calculation of the final payment. The value of the progress estimate will be the sum of the following: 1. Unit Price Items in the Bid Form — the approximate quantity of acceptable units of work completed multiplied by the unit price. 2. Lump Sum Items in the Bid Form — based on the approved Contractor's lump sum breakdown for that item, or absent such a breakdown, based on the Engineer's determination. 3. Materials on Hand — 100 percent of invoiced cost of material delivered to Job site or other storage area approved by the Engineer. 4. Change Orders — entitlement for approved extra cost or completed extra work as determined by the Engineer. Progress payments will be made in accordance with the progress estimate less: 1. Retainage per Section 1-09.9(1), on non FHWA-funded projects; 2. The amount of progress payments previously made; and 3. Funds withheld by the Contracting Agency for disbursement in accordance with the Contract Documents. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-39 CFW SPECIAL PROVISIONS VER. 2019.12 Progress payments for work performed shall not be evidence of acceptable performance or an admission by the Contracting Agency that any work has been satisfactorily completed. The determination of payments under the contract will be final in accordance with Section 1-05.1. 1-09.11 DiSPLItes and Claims (September 3, 2019 WSDOT GSP) Sections 1-09.11 through 1-09.11(1)B are replaced with the following: Disputes and Claims When protests occur during a Contract, the Contractor shall pursue resolution through the Engineer in accordance with Section 1-04.5. Unless noted otherwise in the specifications, compliance with all the requirements of Section 1-04.5 is a condition precedent to initiating any action pursuant to these Special Provisions. If the negotiations using the procedures outlined in Section 1-04.5 fail to provide satisfactory resolution of the protest, then the Contractor shall provide the Engineer with written notification of dispute stating that the Contractor will continue to pursue the dispute in accordance with the provisions of these Special Provisions. The written notification of dispute shall be provided within 14 calendar days after receipt of the Engineer's written determination that the Contractor's protest is invalid pursuant to Section 1-04.5. Should the Contractor not provide written notification of dispute within the designated time period, the Contractor shall be deemed to have waived any right to pursue the protest further and the matter shall be considered resolved. When the Proposal Form includes the Bid item "Disputes Review Board", unresolved protests shall be subject to the Disputes Review Board subsection of this Special Provision. Either party, Engineer or Contractor, may refer a matter in dispute to the Disputes Review Board. Compliance with the requirements of the Disputes Review Board subsection of this Special Provision is a condition precedent to any further right of the Contractor to pursue the dispute either by certified claim or litigation/arbitration. When the Proposal Form does not include the Bid item "Disputes Review Board", the Contractor's written notification of dispute shall indicate whether the Contractor is requesting to resolve the dispute through the use of a Disputes Review Board as outlined in the Disputes Review Board section of this Special Provision, or will submit a formal certified claim directly to the Engineer pursuant to Section 1-09.11(2). If the Contractor requests a Disputes Review Board, the Engineer will notify the Contractor in writing within 7 calendar days of receipt of the request whether the request is acceptable. If both parties to the dispute agree to use a Disputes Review Board, then a pay item "Disputes Review Board" will be added to the Contract by change order and the dispute will be subject to the provisions of the Disputes Review Board subsection of this Special Provision. If the parties do not agree to establish a Disputes Review Board or the Contractor does not request a Disputes Review Board in its written notification of dispute, the Contractor shall comply with the provisions of Section 1-09.11(2). Regardless of any protest or dispute, the Contractor shall proceed promptly with the Work as the Engineer orders. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-40 CFW SPECIAL PROVISIONS VER. 2019.12 Disputes Review Board The procedures set forth in these Special Provisions shall only apply when the Contract includes the pay item "Disputes Review Board". Disputes Review Board— General In order to assist in the resolution of dispute(s) between the Contracting Agency and the Contractor arising out of the work of this Contract, a Disputes Review Board, hereinafter called the "Board", will consider disputes referred to it and furnish written recommendations to the Contracting Agency and Contractor to assist in resolution of the dispute(s). The purpose of the Board response to such issues is to provide nonbinding findings and recommendations designed to expose the disputing parties to an independent view of the dispute. Disputes Eligible for Consideration by the Disputes Review Board The Board shall consider and provide written recommendations concerning the following disputes: 1. Interpretation of the Contract. 2. Entitlement to additional compensation and/or time for completion. 3. Other subjects mutually agreed by the Contracting Agency and Contractor to be a Board issue. Board Member Qualifications The following definitions apply for the purpose of setting forth experience and disclosure requirements for Board members. Financial ties - any ownership interest, loans, receivables or payables. Party directly involved -The Contracting Agency or Contractor of this Contract. Party indirectly involved - The firms associated with the Contractor on this Contract, including joint venture partners, subcontractors of any tier, and suppliers; and firms associated with the Contractor or the Contracting Agency on this Contract, such as designers, architects, engineers, or other professional service firms or consultants. The Board members shall 1. Be experienced in the interpretation of construction contract documents. 2_ Have attended training by the Dispute Resolution Board Foundation in dispute resolution within the last five years. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-41 CFW SPECIAL PROVISIONS VER. 2019.12 3. Be experienced in construction Contract dispute resolution for an owner or Contractor at the level of having responsibility and authority to settle disputes. 4. Be able to discharge their responsibilities impartially and independently, considering the facts and conditions related to the matters under consideration in strict compliance with the provisions of the Contract. 5. Not be a current employee of any party directly or indirectly involved. 6. Not have been an employee of any party directly or indirectly involved with the Project within a period of one year of the Contract Execution date. 7. Not have a financial interest in the Contract except for payments for services on the Board. Board Member Ongoing Responsibilities While serving on the Disputes Review Board on this project: 1. Board members shall not participate in any discussion contemplating the creation of an agreement or making an agreement with any party directly or indirectly involved in the Contract regarding employment or fee-based consulting services, or any other business arrangement after the Contract is completed. 2. Board members shall not officially give any advice to either party. The individual members will act in a completely independent manner and will have no consulting or business connections with either party, except for payments for services on the Board. 3. During routine meetings of the Board as well as during formal hearings, Board members shall refrain from expressing opinions on the merits of statements on matters under dispute or potential dispute. Opinions of Board members expressed in private sessions with other Board members should be kept strictly confidential. 4. The Board shall comply with the terms of the Contract and enforce such terms consistent with the laws of the State of Washington. Board members shall not supplant or otherwise interfere with the respective rights, authorities, duties and obligations of the parties as defined in the Contract. In making its recommendations, the Board shall not make a recommendation that ignores, disregards, or undermines the CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-42 CFW SPECIAL PROVISIONS VER.2019.12 intention, requirements, or allocation of risk, established by the Contract. 5. Throughout the life of the Contract, if Board members become aware of potential conflicts of interest, they shall be disclosed to the parties immediately. Establishment of the Board The Contracting Agency and Contractor shall meet prior to the start of Contract time to jointly select three Board nominees. If the pay item, "Disputes Review Board" is added by change order, the Contracting Agency and Contractor shall meet to select Board nominees after the change order is processed. The Contracting Agency and the Contractor shall provide to the Board nominees a list of the firms directly and indirectly involved with the Project, including, but not limited to designers, architects, engineers, professional service firms, consultants, JV partners, subcontractors and suppliers, along with a listing of key personnel of each. Board nominees shall provide to the Contractor and Contracting Agency the following information within 21 calendar days of nomination. Board nominees that are included on the Washington State Department of Transportation "Statewide Prequalified DRB Candidate Roster" will not be required to submit resumes. 1. Resume showing: a. Full name and contact information b. Experience qualifying the person as a Board member as outlined in the Board Member Qualifications subsection of this Special Provision. c. Previous Board participation, if any. List each Board assignment separately, indicating the name and location of the project, approximate dates of Board service, name of Contracting Agency, name of Contractor, names of the other Board members and the approximate number of disputes heard. When previous Board experience is extensive, the list may be truncated at the prospective Board member's discretion. 2. Disclosure statement addressing the following: a. Previous or current direct employment by one of the parties directly or indirectly involved. b. Previous or current engagement as a consultant to any party directly or indirectly involved - by the prospective CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-43 CFW SPECIAL PROVISIONS VER. 2019.12 Board member or by the firm to which the prospective Board member is directly employed. c. Previous, current, or future financial ties to any of the parties directly or indirectly involved. d. Previous or current personal or professional relationships with a key member of any party directly or indirectly involved. e. Previous and current service as a Board member on projects where any of the parties directly or indirectly involved in this Contract were also involved. f. Any prior involvement in this project. Within 14 calendar days of receiving the resumes and disclosure statements from the Board nominees, the Contracting Agency and the Contractor shall review and jointly agree on the final selection of the three members to serve on the Board. In the event that any of the three nominees are not acceptable to either party, the process shall be repeated until all positions are filled. The Contracting Agency, the Contractor, and the Board shall execute the Three-Party Agreement not later than the first Board meeting. The Three- Party Agreement form (WSDOT Form 134-091) is available online at WSDOT Electronic Forms webpage. The Board shall determine and notify the parties which Board member will act as the Board chair. Disputes Review Board Candidates The qualifications of some potential Board members have been reviewed and deemed potentially acceptable by the Washington State Department of Transportation (WSDOT). This list of potential Board members, Statewide Prequalified DRB Candidate Roster, is available from the WSDOT Headquarters Construction Office website at https://www.wsdot.wa.gov/business/construction/dispute-review- boards. Either party may propose a Board nominee that is not on the WSDOT list. In either case, Board nominees must comply with the requirements of the Board Member Qualifications, Board Member Ongoing Responsibilities, and Establishment of the Board subsection of this Special Provision, and every Board member must be deemed acceptable by both the Contracting Agency and the Contractor. Replacement or Termination of a Board Member Procedures for terminating Board members are defined in The Three-Party Agreement. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-44 CFW SPECIAL PROVISIONS VER. 2019.12 Disputes Review Board Procedures — General The Board, Contracting Agency, and Contractor may mutually develop rules of operation of the Board that supplement the Three-Party Agreement. Such supplemental rules must be in writing and accepted by the Board, Contracting Agency, and Contractor. The Board members shall act impartially and independently in the consideration of facts and conditions surrounding any dispute presented by the Contracting Agency or the Contractor and that the recommendations concerning any such dispute are advisory. The Contracting Agency and the Contractor shall furnish to the Board documents in accordance with the Three-Party Agreement. Regular Disputes Review Board Meetings All regular Board meetings will be held at or near the job site. The frequency of regular meetings will be set by mutual agreement of the Board, the Contracting Agency and the Contractor. Each regular meeting is expected to consist of a round table discussion and a field inspection of the project site. A member of the Contracting Agency and Contractor are expected to jointly facilitate the round table discussion. Round table discussion attendees are expected to include selected personnel from the Contracting Agency and the Contractor. The agenda for each meeting will be managed by the Board. Standard Procedure for Consideration of Disputes Dispute Referral Disputes shall be referred in writing to the Board chair with a copy concurrently provided to the other Board members and the other party. 1. The dispute referral shall concisely define the nature and specifics of the dispute that is proposed to be considered by the Board and the scope of the recommendation requested. This referral is not expected to contain a mutually agreed upon statement of the dispute. 2. The Board chair shall confer with the parties to establish a briefing schedule for delivering prehearing submittals/rebuttals, and a date, time, and location for convening the Board for a hearing. Pre-Hearing Submittal 1. The Contracting Agency and the Contractor shall each prepare a pre-hearing submittal and transmit both a hard copy and an electronic copy of it to all three members of the Board and the other party. The pre-hearing submittal, comprising a position paper with such backup data as is CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-45 CFW SPECIAL PROVISIONS VER. 2019.12 referenced in the position paper, shall be tabbed, indexed, and the pages consecutively numbered. 2. Both position papers shall, at a minimum, contain the following: a. A mutually agreed upon joint statement of the dispute and the scope of the desired report being requested of the Board, placed at the beginning of the papers. The language of this joint statement shall summarize in a few sentences the nature of the dispute. If the parties are unable to agree on the wording of the joint statement of dispute, each party's position paper shall contain both statements, and identify the party authoring each statement. b. The basis and justification for the party's position, with reference to Contract language and other supporting documents for each element of the dispute. In order to minimize duplication and repetitiveness, the parties may identify a common set of documents that will be referred to by both parties, and submit them in a separate package. 3. If requested by the Board or either party, the Contracting Agency and the Contractor shall each prepare and submit a rebuttal paper in response the position paper of the other party. 4. The number of copies, distribution requirements, and time for submittal will be established by the Board and communicated to the parties by the Board chair. Disputes Review Board Hearing 1. The Contracting Agency will arrange for or provide hearing facilities at or near the project site. 2. Attendance: a. The Contracting Agency and the Contractor will have a representative at all hearings. b. The Contracting Agency and Contractor shall both limit attendance at the hearing to personnel directly involved in the dispute and participants in the good- faith negotiations that were conducted prior to submittal to the Board except as noted elsewhere in this section. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-46 CFW SPECIAL PROVISIONS VER. 2019.12 c. At least 14 calendar days before the hearing, each party shall provide a list of proposed attendees to the Board and to the other party. In the event of any disagreement, the Board shall make the final determination as to who attends the hearing. d. Attorneys shall not attend hearings except as follows: i. Attorneys are identified as such on the list of proposed attendees; ii. All parties desiring their attorney present are able to do so. iii. Attorneys shall not participate in the hearing, unless the scope and extent of Attorney participation is mutually agreed to by the Contracting Agency, Contractor and the Board at least 7 calendar days before the hearing. e. For hearings regarding disputes involving a Subcontractor, the Contractor shall require and ensure that each Subcontractor involved in the dispute have present an authorized representative with actual knowledge of the facts underlying the Subcontractor disputes. 3. A party furnishing written evidence or documentation of any kind to the Board must furnish copies of such information to the other party and the Board a minimum of 21 calendar days prior to the date the Board sets to convene the hearing for the dispute, unless otherwise mutually agreed to by the parties and the Board. Either party shall produce such additional evidence as the Board may deem necessary and furnish copies to the other party prior to submittal to the Board. 4. The conduct of the hearing shall be established by the Board and be generally consistent with the following guidelines: a. The party who referred the dispute to the Board shall present first, followed by the other party. b. To assure each party a full and adequate opportunity to present their position, both parties shall be allowed successive rebuttals and to rebut the opposing party's position until, in the Board's opinion, all aspects of the dispute have been fully and fairly covered. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-47 CFW SPECIAL PROVISIONS VER. 2019.12 c. The Board shall be fully prepared to, and may at any time, ask questions, request clarifications, or ask for additional data, documents, and/or job records. d. Either party may request that the Board direct a question to, or request a clarification from the other party. The Board shall determine at what point in the proceedings such requests may be made and if they will be granted. In general, the Board will not allow one party to be questioned directly by the other party. e. In difficult or complex cases, additional hearings may be necessary to facilitate full consideration and understanding of the dispute. f. The Board, in its discretion, may allow introduction of arguments, exhibits, handouts, or documentary evidence that were not included in that party's prehearing position paper or rebuttal and have not been previously submitted to the other party. In such cases the other party will be granted time to review and prepare a rebuttal to the new material, which may require a continuation of the hearing. 5. After the hearing is concluded, the Board shall meet in private and reach a conclusion supported by two or more members. Its findings and recommendations, together with its reasons shall then be submitted as a written report to both parties. The recommendations shall be based on the pertinent Contract provisions, facts, and circumstances involved in the dispute. The Contract shall be interpreted and construed in accordance with the laws of the State of Washington. Failure to Prepare a Pre-Hearing Submittal or Attend a Hearing In the event that either party fails to deliver a pre-hearing submittal by the date established by the Board, the Board shall, at its discretion, determine whether the hearing shall proceed as originally scheduled, or allow additional time for the submittal and/or reschedule the hearing. On the final date and time established for the hearing, the Board shall proceed with the hearing utilizing the information that has been submitted. In the event that representatives of either the Contracting Agency or the Contractor fail to appear at the appointed time of a hearing, the Board shall postpone the hearing until such time as representatives from both parties are available to proceed with the hearing. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-48 CFW SPECIAL PROVISIONS VER. 2019.12 Use of Outside Experts 1. By the Contracting Agency or the Contractor: a. A party intending to offer an outside expert's analysis at the hearing shall notify the other party and the Board in writing no less than 30 calendar days prior to the due date for delivering the pre-hearing submittal, and provide the following disclosure: i. The expert's name and a general statement of the area of the dispute that will be covered by his or her testimony. ii. A statement prepared by the proposed expert which addresses the requirements of the Establishment of the Board subsection of this Special Provision, item 2. iii. A statement prepared by the proposed expert which identifies the experience and training which qualifies them as an expert. b. Upon receipt of the disclosure, the other party shall have the opportunity to secure the services of an outside expert to address or respond to those issues that may be raised by the other party's outside expert. The notification and disclosure requirement shall be the same as that specified elsewhere in this section, except the time requirement is 21 calendar days. 2. By the Board: a. When requested by the Board and subject to approval of the parties, outside experts may be needed to assist the Board. In such cases, the outside expert shall in no way be deemed authorized to usurp the Board's authority to issue the Board recommendations. Such authority shall remain vested solely in the Board. b. Prior to arranging for outside experts, the Board shall obtain prior approval from the Contracting Agency and the Contractor by providing: i. A statement explaining why the expert assistance is needed. ii. An estimate of the cost of the expert assistance. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-49 CFW SPECIAL PROVISIONS VER. 2019.12 iii. The expert's name and a general statement of the area of expertise they will provide. iv. A statement prepared by the proposed expert which addresses the requirements of the Establishment of the Board subsection of this Special Provision, item 2. v. A statement prepared by the proposed expert which identifies the experience and training which qualifies them as an expert. vi. A confidentiality statement, consistent with the confidentiality obligations of the Board described in the Three Party Agreement, executed by the proposed expert. Disputes Review Board Report The Board's recommendations shall be formalized in a written report signed by all Board members. The recommendations shall be based on the Contract Provisions and the facts and circumstances involved in the dispute. The report should include a description of the dispute, statements of each party's position, findings as to the facts of the dispute, discussion and rationale for the recommendation(s), and the recommendation(s). The report shall be submitted concurrently to the parties, as soon as possible after completion of the hearing as agreed by all parties. Either party may request clarification of a report within 14 calendar days following receipt of the report. Within a reasonable period of time, the Board shall provide written clarification to both parties. Requests for clarification shall be submitted in writing simultaneously to the Board and the other party. Either party may request reconsideration of a report, provided: 1. The request is made within 14 calendar days following receipt of the report, and 2. New information is obtained or developed that was not known at the time of the hearing or, in the party's opinion, the Board misunderstood or failed to consider pertinent facts of the dispute. Requests for reconsideration shall be submitted in writing simultaneously to the Board and the other party. The Board shall give the party not requesting reconsideration the option of submitting a rebuttal to any information that is the basis of the request for reconsideration. The Board shall provide a written response to the request for reconsideration. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-50 CFW SPECIAL PROVISIONS VER. 2019.12 Acceptance of Disputes Review Board Recommendations Within 30 calendar days of receiving the Board's report, or within 14 calendar days of receiving the Board's written clarification and/or reconsideration, both the Contracting Agency and the Contractor shall respond to the other in writing signifying that the dispute is either resolved or remains unresolved. Although both parties should place weight upon the Board recommendations, the recommendations are not binding. If the Board's assistance does not lead to resolution of the dispute, the Contractor must file a claim according to Section 1-09.11(2) before seeking any form of judicial relief. In the event the Board's recommendations do not lead to resolution of the dispute, the Board's recommendation consisting solely of the Board's written report and any written minority reports, along with the Board's written clarifications and written responses to requests for reconsideration, if any, will be admissible in any subsequent dispute resolution proceedings including, but not limited to litigation/arbitration. The aforementioned list of documentation shall be considered all inclusive. Payment for the Disputes Review Board The Contracting Agency and Contractor shall share equally in the cost of the Board's services and all operating expenses of the Board. The Board members' compensation shall be in accordance with the Three Party Agreement. After the Contractor and Contracting Agency review invoices from the Board and other operating expenses of the Board, the Contractor shall make full payment for all Board members and Board operating expenses. The Contracting Agency will reimburse the Contractor for fifty percent of such payments, under the pay item "Disputes Review Board". The Contractor and the Contracting Agency shall equally bear the cost of the services of the outside expert hired to advise the Board. Outside experts hired to advise the Board shall Contract directly with the Contractor after concurrence from the Board and approval from the Contracting Agency. Invoices for these services shall be submitted by the expert to both the Contractor and Contracting Agency for approval by both parties. The Contractor shall pay approved invoices in full, and the Contracting Agency will reimburse the Contractor for fifty percent of such payments, under the Bid item "Disputes Review Board". The cost for securing outside expert services for the Contracting Agency or the Contractor shall be borne by the party securing such services. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-51 CFW SPECIAL PROVISIONS VER. 2019.12 The Contracting Agency will provide administrative services, such as conference facilities and copying services, to the Board and the Contracting Agency will bear the costs for these services. Indemnification of Disputes Review Board Members The Contracting Agency and Contractor shall indemnify and hold harmless the Board members from and against all claims, damages, losses and expenses, including but not limited to attorney's fees arising out of and resulting from the actions and recommendations of the Board. 1-09.11(3) Time Limitation and Jurisdiction (November 30, 2018 APWA GSP) Revise this section to read: For the convenience of the parties to the Contract it is mutually agreed by the parties that any claims or causes of action which the Contractor has against the Contracting Agency arising from the Contract shall be brought within 180 calendar days from the date of final acceptance (Section 1-05.12) of the Contract by the Contracting Agency; and it is further agreed that any such claims or causes of action shall be brought only in the Superior Court of the county where the Contracting Agency headquarters is located, provided that where an action is asserted against a county, RCW 36.01.050 shall control venue and jurisdiction. The parties understand and agree that the Contractor's failure to bring suit within the time period provided, shall be a complete bar to any such claims or causes of action. It is further mutually agreed by the parties that when any claims or causes of action which the Contractor asserts against the Contracting Agency arising from the Contract are filed with the Contracting Agency or initiated in court, the Contractor shall permit the Contracting Agency to have timely access to any records deemed necessary by the Contracting Agency to assist in evaluating the claims or action. 1-09.13 Claim Resolution 1-09.13(3) Claims $250,000 or Less (October 1, 2005 APWA GSP) Delete this Section and replace it with the following: The Contractor and the Contracting Agency mutually agree that those claims that total $250,000 or less, submitted in accordance with Section 1-09.11 and not resolved by nonbinding ADR processes, shall be resolved through litigation unless the parties mutually agree in writing to resolve the claim through binding arbitration. 1-09.13(3)A Administration of Arbitration (November 30, 2018 APWA GSP) Revise the third paragraph to read: The Contracting Agency and the Contractor mutually agree to be bound by the decision of the arbitrator, and judgment upon the award rendered by the arbitrator may be entered in the Superior Court of the county in which the Contracting Agency's headquarters is located provided that where claims subiect to arbitration are asserted against a county. RCW 36.01.050 shall control venue and 'urisdiction of the Superior Court. The decision of the arbitrator and the CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-52 CFW SPECIAL PROVISIONS VER. 2019.12 specific basis for the decision shall be in writing. The arbitrator shall use the Contract as a basis for decisions. 1-10 TEMPORARY TRAFFIC CONTROL 1-10.2 Traffic Control Management 1-10.2(1) General (January 3, 2017 WSDOT GSP, OPTION 1) Section 1-10.2(1) is supplemented with the following: Only training with WSDOT TCS card and WSDOT training curriculum is recognized in the State of Washington. The Traffic Control Supervisor shall be certified by one of the following: The Northwest Laborers-Employers Training Trust 27055 Ohio Ave. Kingston, WA 98346 (360) 297-3035 Evergreen Safety Council 12545 135th Ave. NE Kirkland, WA 98034-8709 1-800-521-0778 The American Traffic Safety Services Association 15 Riverside Parkway, Suite 100 Fredericksburg, Virginia 22406-1022 Training Dept. Toll Free (877) 642-4637 Phone: (540) 368-1701 1-10.2(2) Traffic Control Plans (April 12, 2018 CFW GSP) Section 1-10.2(2) is supplemented with the following: The following minimum Traffic Control requirements shall be maintained during the construction of the project: 1. If the Contractor opts to utilize traffic control plans other than those provided in these Contract Documents, the Contractor shall provide traffic control plans to the City of Federal Way for review and approval a minimum of five (5) working days prior to implementation. These plans shall supplement Construction Staging Plans. The plans as provided by the Contractor shall include and not be limited to the following information: • Stop line locations with station and offset to verify safety of intersection turning radius for vehicles. • Minimum lane widths provided for vehicular travel. • Turn pocket length, gap, and tapers in conformance with the City of Federal Way Standard Detail DWG 3-19A. 2. Detours will not be allowed except as noted herein or Section 1-07.23(2) as amended. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-53 CFW SPECIAL PROVISIONS VER.2019.12 3. Temporary paint striping, reflective marking tape, and/or retroreflective tubular markers shall be required for each shift of traffic control. The Contractor shall provide temporary striping, reflective marking tape, and/or reflective tubular markers as required at the direction of the Engineer. 4. The Contractor provided Traffic Control Plans shall lay out traffic control device spacing, tapers, etc., to scale, and shall contain accurate dimensions and legends and shall be signed by the preparer. 1-10.3 Traffic Control Labor, Procedures and Devices 1-10.3(1) Traffic Control Labor (December Z 2019 CFW GSP) Section 1-10.3(1) is supplemented with the following: The City shall reimburse the Contractor for the use of off-duty uniformed police officers at the invoiced cost with no mark-up per Standard Specifications 1-09.6 Force Account. Off-duty uniformed police officer will be required only when the signal system is in flashing mode or is not operational or when otherwise deemed necessary by the Project Engineer. Federal Way Police Officer Requests (253) 835-6701 or (253) 835-6700 Saturday/Sunday cancellations (253) 835-6851 When scheduling off-duty uniformed police officers in the City of Federal Way, City of Federal Way Police Department (CFWPD) officers must be contacted first. If CFWPD cannot fill the job, off-duty King County Sheriff's Officers or Washington State Patrol Officers are allowed to work within the City of Federal Way, but must receive the CFWPD Chief's prior permission to work extra duty and fill the Contractor's request. No other agencies or private companies are authorized to perform off duty work within the City of Federal Way without project-specific approval from the CFWPD Chief or their designee, Lynette Allen (253)835-6701. The use of off-duty uniformed police officers shall be in accordance with the City of Federal Way Police Department's guidelines as follows: • The Contractor will be billed for the entire duration of the job as it was requested. For example, if the Contractor requested an officer for 8 hours and the job was completed in 4 hours, the Contractor will still be billed for the entire 8 hours. A minimum of three (3) hours call out time shall be paid by the Contractor for each request for off-duty police officers. • If a job is cancelled with less than 24 hours' notice, the Contractor will be required to pay a 3 hour minimum. It shall be the Contractor's responsibility to arrange a work schedule to minimize any additional costs incurred by the minimum three (3) hour call out requirement. No reimbursement of any portion of the minimum callout will be allowed where Contractor-made schedule revisions occur after an off-duty officer has been procured. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-54 CFW SPECIAL PROVISIONS VER. 2019.12 • The Contractor's request for a police officer does not guarantee they will get one. The Contractor must provide the date(s), times, location, and other details of their request and the CFWPD will put the job out to the officers. Whether an officer signs up for it depends on many variables, especially their availability on the day requested. The more advance notice provided by the Contractor, the more likely it is that the job will be filled. Requests shall be made a minimum of forty-eight(48) hours before the use of the off-duty police officers on the project site. • The officer usually arrives at the extra duty job in a police car. • Officers cannot work extra duty jobs in plain clothes; they must wear their police uniform. • If a major emergency occurs, the off-duty officer may be pulled from the project. An officer may also get pulled off the job if he/she is required to appear in court. • Officers must be given breaks and lunch according to the Federal Labor Standards Act (FLSA). 1-10.3(1) Traffic Control Labor Section 1-10.3(1) is supplemented with the following: All Traffic Control Labor necessary for the successful completion of items included in work- orders issued under this contract are incidental to each and every work item. Any work described under this section performed by a Traffic Control Supervisor will not be paid but will be considered incidental to other items of work. 1-10.4 Measurement Supplement with the following: All traffic control items, including Temporary Traffic Control, Traffic Control Labor and Traffic Control Supervisor shall be incidental to the contract and no measurement will be made. 1-10.5 Payment Section 1-10.5 is supplemented with the following: No Payment will be made for any traffic control items, Temporary Traffic Control, Traffic Control Labor or Traffic Control Supervisor and shall be considered incidental to the contract. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-55 CFW SPECIAL PROVISIONS VER. 2019.12 END OF DIVISION 1 CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-56 CFW SPECIAL PROVISIONS VER. 2019.12 DIVISION 2 EARTHWORK 2-01 CLEARING GRUBBING AND ROADSIDE CLEANUP 2-01.1 Description (March 13, 1995 WSDOT GSP, OPTION 1) Section 2-01.1 is supplemented with the following: Clearing and grubbing on this project shall be performed within the following limits: Limits for clearing & grubbing shall be as shown on the plans. Clearing shall include removal of trees as noted on the plans or as directed by the Engineer to accommodate the improvements. Tree removal shall include removal of stumps and/or grinding of stumps to a depth at least two feet below finish grade. 2-01.3 Construction Requirements 2-01.3(3) Clearing Limit Fence (April 12, 2018 CFW GSP) Section 2-01.3(3) is a new section: Clearing limit fence shall be 4-feet high, orange, high density polyethylene fencing with mesh openings 1'/z-inch by 3-inches nominal and weigh at least 7 oz. per linear foot. Either wood or steel posts shall be used. Wood posts shall have minimum dimensions of 1'/2 inches by 1'/2 inches by the minimum length of 5 feet, and shall be free of knots, splits, or gouges. Steel posts shall consist of either size No. 6 rebar or larger, ASTM A 120 steel pipe with a minimum diameter or 1 inch, U, T, L or C shape steel posts with a minimum weight of 1.35 lbs./ft. or other steel posts having equivalent strength and bending resistance to the post sizes listed. The spacing of the support posts shall be a maximum of 6'/z feet. 2-01.3(4) Roadside Cleanup (January 5, 1998 WSDOT GSP, OPTION 1) Section 2-01.3(4) is supplemented with the following: The Contractor shall restore, repair or correct all portions of the roadside or adjacent landscapes that were unavoidably damaged due to the performance or installation of the specified work. Unavoidable damage shall be determined only by the Engineer. All materials utilized shall be in accordance with Sections 9-14 and 9-15 and other applicable sections of the Standard Specifications or Special Provisions, whichever may apply. All work shall be performed in accordance with Sections 8-02 and 8-03 and other applicable sections of the Standard Specifications. The Contractor shall review the work with the Engineer and receive approval to proceed prior to commencing the work. 2-01.4 Measurement (April 12, 2018 CFW GSP) Section 2-01.4 is supplemented with the following: "Clearing and Grubbing" will be measured on a lump sum basis. Installation, maintenance, and removal of the Clearing Limit Fence shall be included in the Clearing and Grubbing bid item. "Roadside Cleanup", will be not measured and incidental to contract work order. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-57 CFW SPECIAL PROVISIONS VER. 2019.12 2-01.5 PaymenR (April 12, 2018 CFW GSP) Section 2-01.5 is supplemented with the following: "Clearing and Grubbing", lump sum. "Roadside Cleanupincidental to contract work order. 2-02 REMOVAL OF STRUCTURES AND OBSTRUCTIONS 2-02.3(6) Existing Utilities to Remain (April 12, 2018 CFW GSP) 2-02.3(6) is a new section: Utilities indicated in the Plans to remain shall be protected and supported in place in such a manner that they remain functional and undamaged. Utilities indicated to remain that are damaged as a result of Contractor's activity shall be repaired or replaced to the satisfaction of the Contracting Agency at no additional cost. 2-02.3(7) Remove Exisiting Pedestrian Refuge Island, Speed Hump peed Table and Raised CrossWalk New Section 2-02.3(7) Remove Exisiting Pedestrian Refuge Island, Speed Bump, Speed Table and Raised CrossWalk In removing the Pedestrian Refuge Island, Complete the contractor shall complete the following items as shown on plans and as incidental to this Bid item: 1. Remove permanent signage including signs and posts unless flashing beacons are present, then signage and beacons are to be removed by others. Salvaged signs become property of the City. 2. Remove pair of islands as shown in the scope of City of Federal Way detail drawing 3-58 including removal and haul of waste asphalt surface, crushed rock, and extruded curb. 3. Remove Detectable Warning Surface(s) its residue and any other adhesive residue within the scope of the island per City of Federal Way detail drawing 3-58. 4. Remove tubular markers per City of Federal Way detail drawing 3-58. 5. Remove Raised Pavement Markers as detailed per City of Federal Way detail drawing 3- 58. 6. Removal of paint, MMA, and thermoplastic permanent pavement markings done by others. 2-02.4 Vacant (April 12, 2018 CFW GSP) Section 2-02.4 Vacant shall be deleted and replaced with the following: 2-02.4 Measurement "Remove Pedestrian Refuge Island" will be measured per each CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-58 CFW SPECIAL PROVISIONS VER. 2019.12 "Remove Speed Hump", will be measured per each. "Remove Speed Table", will be measured per each. "Remove Raised Crosswalk", will be measured per each. 2-02.5 Payment (April 12, 2018 CFW GSP) Section 2-02.5 is supplemented with the following: Payment will be made in accordance with Section 1-04.1 for the following bid items when included in the proposal: "Removal of Structure and Obstruction", lump sum. Structure Excavation Class B for the removal of items shall be considered included in this bid item. "Remove Pedestrian Refuge Island Complete", per each. "Remove Speed Hump, Speed Table, or Raised Crosswalk", per each. Remove Speed Table", per each. "Remove Raised Crosswalk", per each. END OF DIVISION 2 CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-59 CFW SPECIAL PROVISIONS VER. 2019.12 DIVISION 3 AGGREGATE PRODUCTION AND ACCEPTANCE 3-01 PRODUCTION FROM QUARRY ,AND PIT SITES 3-01.4 Contractor Furnished Material Sources _ 3-01.4(1) Acquisition and Development (April 12, 2018 CFW GSP) Section 3-01.4(1) is supplemented with the following: No source has been provided for any materials necessary for the construction of these improvements. If the source of material provided by the Contractor necessitates hauling over roads other than City streets, the Contractor shall, at his own cost and expense, make all arrangements for the use of haul routes. END OF DIVISION 3 CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-60 CFW SPECIAL PROVISIONS VER. 2019.12 DIVISION 4 BASES 4-04 BALLAST AND CRUSHED SURFAQNG 4-04.3 Construction Requirements 4-04.3(3) Mixing (April 12, 2018 CFW GSP) Item 2 of Section 4-04.3(3), is replaced with the following: 2. Road Mix Method - The road mix method of mixing surfacing material will not be allowed. 4-04.3(4) Placing and Spreading (April 12, 2018 CFW GSP) Item 2 of Section 4-04(4), is replaced with the following: 2. Road Mix Method - The road mix method of mixing surfacing material will not be allowed. 4-04.5 Payment (April 12, 2018 CFW GSP) Section 4-04.5 is supplemented with the following: The unit contract price for Ballast and Crushed Surfacing shall also include compacting, and removing and hauling to waste when required by the Engineer. END OF DIVISION 4 CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-61 CFW SPECIAL PROVISIONS VER. 2019.12 DIVISION 5 SURFACE TREATMENTS AND PAVEMENTS 5-04 HOT MIX ASPHALT (July 18, 2018 APWA GSP) Delete Section 5-04 and amendments, Hot Mix Asphalt and replace it with the following: 5-04.1 Description This Work shall consist of providing and placing one or more layers of plant-mixed hot mix asphalt (HMA) on a prepared foundation or base in accordance with these Specifications and the lines, grades, thicknesses, and typical cross-sections shown in the Plans. The manufacture of HMA may include warm mix asphalt (WMA) processes in accordance with these Specifications. WMA processes include organic additives, chemical additives, and foaming. HMA shall be composed of asphalt binder and mineral materials as may be required, mixed in the proportions specified to provide a homogeneous, stable, and workable mixture. 5-04.2 Materials Materials shall meet the requirements of the following sections: Asphalt Binder 9-02.1(4) Cationic Emulsified Asphalt 9-02.1(6) Anti-Stripping Additive 9-02.4 HMA Additive 9-02.5 Aggregates 9-03.8 Recycled Asphalt Pavement 9-03 8(3)R Mineral Filler 9-03.8(5) Recycled Material 9-03.21 Portland Cement 9-01 Sand 9-03.1(2) (As noted in 5-04.3(5)C for crack sealing) Joint Sealant 9-04.2 Foam Backer Rod 9-04.2(3)A The Contract documents may establish that the various mineral materials required for the manufacture of HMA will be furnished in whole or in part by the Contracting Agency. If the documents do not establish the furnishing of any of these mineral materials by the Contracting Agency, the Contractor shall be required to furnish such materials in the amounts required for the designated mix. Mineral materials include coarse and fine aggregates, and mineral filler. The Contractor may choose to utilize recycled asphalt pavement (RAP) in the production of HMA. The RAP may be from pavements removed under the Contract, if any, or pavement material from an existing stockpile. The Contractor may use up to 20 percent RAP by total weight of HMA with no additional sampling or testing of the RAP. The RAP shall be sampled and tested at a frequency of one sample for every 1,000 tons produced and not less than ten samples per project. The asphalt content and gradation test data shall be reported to the Contracting Agency when submitting the mix design for approval on the QPL. The Contractor shall include the RAP as part of the mix design as defined in these Specifications. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-62 CFW SPECIAL PROVISIONS VER. 2019.12 The grade of asphalt binder shall be as required by the Contract. Blending of asphalt binder from different sources is not permitted. The Contractor may only use warm mix asphalt (WMA) processes in the production of HMA with 20 percent or less RAP by total weight of HMA. The Contractor shall submit to the Engineer for approval the process that is proposed and how it will be used in the manufacture of HMA. Production of aggregates shall comply with the requirements of Section 3-01. Preparation of stockpile site, the stockpiling of aggregates, and the removal of aggregates from stockpiles shall comply with the requirements of Section 3-02. 5-04.2(1) How to Get an HMA Mix Design on the QPL If the contractor wishes to submit a mix design for inclusion in the Qualified Products List (QPL), please follow the WSDOT process outlined in Standard Specification 5-04.2(1). 5-04.2(1)A Vacant 5-04.2(2) Mix Design — Obtaining Project Approval No paving shall begin prior to the approval of the mix design by the Engineer. Nonstatistical evaluation will be used for all HMA not designated as Commercial HMA in the contract documents. Commercial evaluation will be used for Commercial HMA and for other classes of HMA in the following applications: sidewalks, road approaches, ditches, slopes, paths, trails, gores, prelevel, and pavement repair. Other nonstructural applications of HMA accepted by commercial evaluation shall be as approved by the Project Engineer. Sampling and testing of HMA accepted by commercial evaluation will be at the option of the Project Engineer. The Proposal quantity of HMA that is accepted by commercial evaluation will be excluded from the quantities used in the determination of nonstatistical evaluation. Nonstatistical Mix Design. Fifteen days prior to the first day of paving the contractor shall provide one of the following mix design verification certifications for Contracting Agency review; * The WSDOT Mix Design Evaluation Report from the current WSDOT QPL, or one of the mix design verification certifications listed below. • The proposed HMA mix design on WSDOT Form 350-042 with the seal and certification (stamp & sig-nature) of a valid licensed Washington State Professional Engineer. The Mix Design Report for the proposed HMA mix design developed by a qualified City or County laboratory that is within one year of the approval date.** The mix design shall be performed by a lab accredited by a national authority such as Laboratory Accredita-tion Bureau, L-A-B for Construction Materials Testing, The Construction Materials Engineering Council (CMEC's) ISO 17025 or AASHTO Accreditation Program (AAP) and shall supply evidence of participation in the AASHTO: resource proficiency sample program. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-63 CFW SPECIAL PROVISIONS VER. 2019.12 Mix designs for HMA accepted by Nonstatistical evaluation shall; • Have the aggregate structure and asphalt binder content determined in accordance with WSDOT Standard Operating Procedure 732 and meet the requirements of Sections 9-03.8(2), except that Hamburg testing for ruts and stripping are at the discretion of the Engineer, and 9-03.8(6). • Have anti-strip requirements, if any, for the proposed mix design determined in accordance with AASHTO T 283 or T 324, or based on historic anti-strip and aggregate source compatibility from previous WSDOT lab testing. At the discretion of the Engineer, agencies may accept verified mix designs older than 12 months from the original verification date with a certification from the Contractor that the materials and sources are the same as those shown on the original mix design. Commercial Evaluation Approval of a mix design for "Commercial Evaluation" will be based on a review of the Contractor's submittal of WSDOT Form 350-042 (For commercial mixes, AASHTO T 324 evaluation is not required) or a Mix Design from the current WSDOT QPL or from one of the processes allowed by this section. Testing of the HMA by the Contracting Agency for mix design approval is not required. For the Bid Item Commercial HMA, the Contractor shall select a class of HMA and design level of Equivalent Single Axle Loads (ESAL's) appropriate for the required use. 5-04.2(2)B Usin-q Warm Mix Asphalt Processes The Contractor may elect to use additives that reduce the optimum mixing temperature or serve as a compaction aid for producing HMA. Additives include organic additives, chemical additives and foaming processes. The use of Additives is subject to the following: • Do not use additives that reduce the mixing temperature more than allowed in Section 5-04.3(6) in the production of mixtures. Before using additives, obtain the Engineer's approval using WSDOT Form 350- 076 to describe the proposed additive and process. 5-04.3 Construction requirements 5-04.3(1) Weather Limitations Do not place HMA for wearing course on any Traveled Way beginning October 1st through March 31st of the following year without written concurrence from the Engineer. Do not place HMA on any wet surface, or when the average surface temperatures are less than those specified below, or when weather conditions otherwise prevent the proper handling or finishing of the HMA. Minimum Surface Temperature for Pain Compacted Thickness(Feet) Wearing Course Other Courses Less than 0.10 55-F 45-F CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-64 CFW SPECIAL PROVISIONS VER. 2019.12 0.10 to .20 45-F 35-F ___-F ____-T More than 0.20 35-F 35-F 5-04.3(2) Paving Under Traffic When the Roadway being paved is open to traffic, the requirements of this Section shall apply. The Contractor shall keep intersections open to traffic at all times except when paving the intersection or paving across the intersection. During such time, and provided that there has been an advance warning to the public, the intersection may be closed for the minimum time required to place and compact the mixture. In hot weather, the Engineer may require the application of water to the pavement to accelerate the finish rolling of the pavement and to shorten the time required before reopening to traffic. Before closing an intersection, advance warning signs shall be placed and signs shall also be placed marking the detour or alternate route. During paving operations, temporary pavement markings shall be maintained throughout the project. Temporary pavement markings shall be installed on the Roadway prior to opening to traffic. Temporary pavement markings shall be in accordance with Section 8- 23. All costs in connection with performing the Work in accordanr;e with these requirements, except the cost of temporary pavement markings, shall be included in the unit Contract prices for the various Bid items involved in the Contract. 5-04.3(3) E ui ment 5-04.3(3)A Mixing Plant Plants used for the preparation of HMA shall conform to the following requirements- 1. Equipment for Preparation of Asphalt Binder — Tanks for the storage of asphalt binder shall be equipped to heat and hold the material at the required temperatures. The heating shall be accomplished by steam coils, electricity, or other approved means so that no flame shall be in contact with the storage tank. The circulating system for the asphalt binder shall be designed to ensure proper and continuous circulation during the operating period. A valve for the purpose of sampling the asphalt binder shall be placed in either the storage tank or in the supply line to the mixer. 2. Thermometric Equipment — An armored thermometer, capable of detecting temperature ranges expected in the HMA mix, shall be fixed in the asphalt binder feed line at a location near the charging valve at the mixer unit. The thermometer location shall be convenient and safe for access by Inspectors. The plant shall also be equipped with an approved dial-scale thermometer, a mercury actuated thermometer, an electric pyrometer, or another approved thermometric instrument placed at the discharge chute of the drier to automatically register or indicate the temperature of the heated aggregates. This device shall be in full view of the plant operator. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-65 CFW SPECIAL PROVISIONS VER. 2019.12 3. Heating of Asphalt Binder — The temperature of the asphalt binder shall not exceed the maximum recommended by the asphalt binder manufacturer nor shall it be below the minimum temperature required to maintain the asphalt binder in a homogeneous state. The asphalt binder shall be heated in a manner that will avoid local variations in heating. The heating method shall provide a continuous supply of asphalt binder to the mixer at a uniform average temperature with no individual variations exceeding 25°F. Also, when a WMA additive is included in the asphalt binder, the temperature of the asphalt binder shall not exceed the maximum recommended by the manufacturer of the WMA additive. 4. Sampling and Testing of Mineral Materials —The HMA plant shall be equipped with a mechanical sampler for the sampling of the mineral materials. The mechanical sampler shall meet the requirements of Section 1-05.6 for the crushing and screening operation. The Contractor shall provide for the setup and operation of the field testing facilities of the Contracting Agency as provided for in Section 3-01.2(2). 5. Sampling HMA — The HMA plant shall provide for sampling HMA by one of the following methods: a. A mechanical sampling device attached to the HMA plant. b. Platforms or devices to enable sampling from the hauling vehicle without entering the hauling vehicle. 5-04.3(3)B Hauling Equip ment Trucks used for hauling HMA shall have tight, clean, smooth metal beds and shall have a cover of canvas or other suitable material of sufficient size to protect the mixture from adverse weather. Whenever the weather conditions during the work shift include, or are forecast to include, precipitation or an air temperature less than 45°F or when time from loading to unloading exceeds 30 minutes, the cover shall be securely attached to protect the HMA. The contractor shall provide an environmentally benign means to prevent the HMA mixture from adhering to the hauling equipment. Excess release agent shall be drained prior to filling hauling equipment with HMA. Petroleum derivatives or other coating material that contaminate or alter the characteristics of the HMA shall not be used. For live bed trucks, the conveyer shall be in operation during the process of applying the release agent. 5-04.3(3)C Pavers HMA pavers shall be self-contained, power-propelled units, provided with an internally heated vibratory screed and shall be capable of spreading and finishing courses of HMA plant mix material in lane widths required by the paving section shown in the Plans. The HMA paver shall be in good condition and shall have the most current equipment available from the manufacturer for the prevention of segregation of the HMA mixture installed, in good condition, and in working order. The equipment certification shall list the make, model, and year of the paver and any equipment that has been retrofitted. The screed shall be operated in accordance with the manufacturer's recommendations and shall effectively produce a finished surface of the required evenness and texture without tearing, shoving, segregating, or gouging the mixture. A copy of the manufacturer's recommendations shall be provided upon request by the Contracting CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-66 CFW SPECIAL PROVISIONS VER. 2019.12 Agency. Extensions will be allowed provided they produce the same results, including ride, density, and surface texture as obtained by the primary screed. Extensions without augers and an internally heated vibratory screed shall not be used in the Traveled Way. When specified in the Contract, reference lines for vertical control will be required. Lines shall be placed on both outer edges of the Traveled Way of each Roadway. Horizontal control utilizing the reference line will be permitted. The grade and slope for intermediate lanes shall be controlled automatically from reference lines or by means of a mat referencing device and a slope control device. When the finish of the grade prepared for paving is superior to the established tolerances and when, in the opinion of the Engineer, further improvement to the line, grade, cross-section, and smoothness can best be achieved without the use of the reference line, a mat referencing device may be substituted for the reference line. Substitution of the device will be subject to the continued approval of the Engineer. A joint matcher may be used subject to the approval of the Engineer. The reference line may be removed after the completion of the first course of HMA when approved by the Engineer. Whenever the Engineer determines that any of these methods are failing to provide the necessary vertical control, the reference lines will be reinstalled by the Contractor. The Contractor shall furnish and install all pins, brackets, tensioning devices, wire, and accessories necessary for satisfactory operation of the automatic control equipment. If the paving machine in use is not providing the required finish, the Engineer may suspend Work as allowed by Section 1-08.6. Any cleaning or solvent type liquids spilled on the pavement shall be thoroughly removed before paving proceeds. 5-04.3(3)D Material Transfer Device or Material Transfer Vehicle A Material Transfer DeviceNehicle (MTDN) shall only be used with the Engineer's approval, unless other-wise required by the contract. Where an MTDN is required by the contract, the Engineer may approve paving without an MTD/V, at the request of the Contractor. The Engineer will determine if an equitable adjustment in cost or time is due. When used, the MTDN shall mix the HMA after delivery by the hauling equipment and prior to laydown by the paving machine. Mixing of the HMA shall be sufficient to obtain a uniform temperature throughout the mixture. If a windrow elevator is used, the length of the windrow may be limited in urban areas or through intersections, at the discretion of the Engineer. To be approved for use, an MTV: 1. Shall be self-propelled vehicle, separate from the hauling vehicle or paver. 2. Shall not be connected to the hauling vehicle or paver. 3. May accept HMA directly from the haul vehicle or pick up HMA from a windrow. 4. Shall mix the HMA after delivery by the hauling equipment and prior to placement into the paving machine. 5. Shall mix the HMA sufficiently to obtain a uniform temperature throughout the mixture. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-67 CFW SPECIAL PROVISIONS VER. 2019.12 To be approved for use, an MTD: 1. Shall be positively connected to the paver. 2. May accept HMA directly from the haul vehicle or pick up HMA from a windrow. 3. Shall mix the HMA after delivery by the hauling equipment and prior to placement into the paving machine. 4. Shall mix the HMA sufficiently to obtain a uniform temperature throughout the mixture. 5-04.3(3)E Rollers Rollers shall be of the steel wheel, vibratory, oscilatory, or pneumatic tire type, in good condition and capable of reversing without backlash. Operation of the roller shall be in accordance with the manufacturer's recommendations. When ordered by the Engineer for any roller planned for use on the project, the Contractor shall provide a copy of the manufacturer's recommendation for the use of that roller for compaction of HMA. The number and weight of rollers shall be sufficient to compact the mixture in compliance with the requirements of Section 5-04.3(10). The use of equipment that results in crushing of the aggregate will not be permitted. Rollers producing pickup, washboard, uneven compaction of the surface, displacement of the mixture or other undesirable results shall not be used. 5-04.3(4) Preparation of Existing Paved Surfaces When the surface of the existing pavement or old base is irregular, the Contractor shall bring it to a uniform grade and cross-section as shown on the Plans or approved by the Engineer. Preleveling of uneven or broken surfaces over which HMA is to be placed may be accomplished by using an asphalt paver, a motor patrol grader, or by hand raking, as approved by the Engineer. Compaction of preleveling HMA shall be to the satisfaction of the Engineer and may require the use of small steel wheel rollers, plate compactors, or pneumatic rollers to avoid bridging across preleveled areas by the compaction equipment. Equipment used for the compaction of preleveling HMA shall be approved by the Engineer. Before construction of HMA on an existing paved surface, the entire surface of the pavement shall be clean. All fatty asphalt patches, grease drippings, and other objectionable matter shall be entirely removed from the existing pavement. All pavements or bituminous surfaces shall be thoroughly cleaned of dust, soil, pavement grindings, and other foreign matter. All holes and small depressions shall be filled with an appropriate class of HMA. The surface of the patched area shall be leveled and compacted thoroughly. Prior to the application of tack coat, or paving, the condition of the surface shall be approved by the Engineer. A tack coat of asphalt shall be applied to all paved surfaces on which any course of HMA is to be placed or abutted; except that tack coat may be omitted from clean, newly paved surfaces at the discretion of the Engineer. Tack coat shall be uniformly applied to cover the existing pavement with a thin film of residual asphalt free of streaks and bare spots at a rate between 0.02 and 0.10 gallons per square yard of retained asphalt. The rate of application shall be approved by the Engineer. A heavy application of tack coat shall be CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-68 CFW SPECIAL PROVISIONS VER. 2019.12 applied to all joints. For Roadways open to traffic, the application of tack coat shall be limited to surfaces that will ,be paved during the same working shift. The spreading equipment shall be equipped with a thermometer to indicate the temperature of the tack coat material. Equipment shall not operate on tacked surfaces until the tack has broken and cured. If the Contractor's operation damages the tack coat it shall be repaired prior to placement of the HMA. The tack coat shall be CSS-1, or CSS-1h emulsified asphalt. The CSS-1 and CSS-1h emulsified asphalt may be diluted once with water at a rate not to exceed one part water to one part emulsified asphalt. The tack coat shall have sufficient temperature such that it may be applied uniformly at the specified rate of application and shall not exceed the maximum temperature recommended by the emulsified asphalt manufacturer. 5-04.3(4)A Crack Sealing 5-04.3(4)A1 General When the Proposal includes a pay item for crack sealing, seal all cracks 1/4 inch in width and greater. Cleaning: Ensure that cracks are thoroughly clean, dry and free of all loose and foreign material when filling with crack sealant material. Use a hot compressed air lance to dry and warm the pavement surfaces within the crack immediately prior to filling a crack with the sealant material. Do not overheat pavement. Do not use direct flame dryers. Routing cracks is not required. Sand Slurry: For cracks that are to be filled with sand slurry, thoroughly mix the components and pour the mixture into the cracks until full. Add additional CSS-1 cationic emulsified asphalt to the sand slurry as needed for workability to ensure the mixture will completely fill the cracks. Strike off the sand slurry flush with the existing pavement surface and allow the mixture to cure. Top off cracks that were not completely filled with additional sand slurry. Do not place the HMA overlay until the slurry has fully cured. The sand slurry shall consist of approximately 20 percent CSS-1 emulsified asphalt, approximately 2 percent portland cement, water (if required), and the remainder clean Class 1 or 2 fine aggregate per section 9-03.1(2). The components shall be thoroughly mixed and then poured into the cracks and joints until full. The following day, any cracks or joints that are not completely filled shall be topped off with additional sand slurry. After the sand slurry is placed, the filler shall be struck off flush with the existing pavement surface and allowed to cure. The HMA overlay shall not be placed until the slurry has fully cured. The requirements of Section 1-06 will not apply to the portland cement and sand used in the sand slurry. In areas where HMA will be placed, use sand slurry to fill the cracks. In areas where HMA will not be placed, fill the cracks as follows: 1. Cracks '/4 inch to 1 inch in width -fill with hot poured sealant. 2. Cracks greater than 1 inch in width —fill with sand slurry. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-69 CFW SPECIAL PROVISIONS VER. 2019.12 Hot Poured Sealant: For cracks that are to be filled with hot poured sealant, apply the material in accordance with these requirements and the manufacturer's recommendations. Furnish a Type 1 Working Drawing of the manufacturer's product information and recommendations to the Engineer prior to the start of work, including the manufacturer's recommended heating time and temperatures, allowable storage time and temperatures after initial heating, allowable reheating criteria, and application temperature range. Confine hot poured sealant material within the crack. Clean any overflow of sealant from the pavement surface. If, in the opinion of the Engineer, the Contractor's method of sealing the cracks with hot poured sealant results in an excessive amount of material on the pavement surface, stop and correct the operation to eliminate the excess material. 5-04.3(4)A2 Crack Sealing Areas Prior to Paving In areas where HMA will be placed, use sand slurry to fill the cracks. 5-04.3(4)A3 Crack Sealing Areas Not to be Paved In areas where HMA will not be placed, fill the cracks as follows: A. Cracks '/4 inch to 1 inch in width -fill with hot poured sealant. B. Cracks greater than 1 inch in width —fill with sand slurry. 5-04.3(4)6 Vacant 5-04.3(4)C Pavement Repair The Contractor shall excavate pavement repair areas and shall backfill these with HMA in accordance with the details shown in the Plans and as marked in the field. The Contractor shall conduct the excavation operations in a manner that will protect the pavement that is to remain. Pavement not designated to be removed that is damaged as a result of the Contractor's operations shall be repaired by the Contractor to the satisfaction of the Engineer at no cost to the Contracting Agency. The Contractor shall excavate only within one lane at a time unless approved otherwise by the Engineer. The Contractor shall not excavate more area than can be completely finished during the same shift, unless approved by the Engineer. Unless otherwise shown in the Plans or determined by the Engineer, excavate to a depth of 1.0 feet. The Engineer will make the final determination of the excavation depth required. The minimum width of any pavement repair area shall be 40 inches unless shown otherwise in the Plans. Before any excavation, the existing pavement shall be sawcut or shall be removed by a pavement grinder. Excavated materials will become the property of the Contractor and shall be disposed of in a Contractor-provided site off the Right of Way or used in accordance with Sections 2-02.3(3) or 9-03.21. Asphalt for tack coat shall be required as specified in Section 5-04.3(4). A heavy application of tack coat shall be applied to all surfaces of existing pavement in the pavement repair area. Placement of the HMA backfill shall be accomplished in lifts not to exceed 0.35-foot compacted depth. Lifts that exceed 0.35-foot of compacted depth may be accomplished CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-70 CFW SPECIAL PROVISIONS VER. 2019.12 with the approval of the Engineer. Each lift shall be thoroughly compacted by a mechanical tamper or a roller. 5-04.3(5) Producing/Stockpiling Aggregates and RAP Aggregates and RAP shall be stockpiled according to the requirements of Section 3-02. Sufficient storage space shall be provided for each size of aggregate and RAP. Materials shall be removed from stockpile(s) in a manner to ensure minimal segregation when being moved to the HMA plant for processing into the final mixture. Different aggregate sizes shall be kept separated until they have been delivered to the HMA plant. 5-04.3(5)A Vacant 5-04.3(6) Mixing After the required amount of mineral materials, asphalt binder, recycling agent and anti- stripping additives have been introduced into the mixer the HMA shall be mixed until complete and uniform coating of the particles and thorough distribution of the asphalt binder throughout the mineral materials is ensured. When discharged, the temperature of the HMA shall not exceed the optimum mixing temperature by more than 25°F as shown on the reference mix design report or as approved by the Engineer. Also, when a WMA additive is included in the manufacture of HMA, the discharge temperature of the HMA shall not exceed the maximum recommended by the manufacturer of the WMA additive. A maximum water content of 2 percent in the mix, at discharge, will be allowed providing the water causes no problems with handling, stripping, or flushing. If the water in the HMA causes any of these problems, the moisture content shall be reduced as directed by the Engineer. Storing or holding of the HMA in approved storage facilities will be permitted with approval of the Engineer, but in no event shall the HMA be held for more than 24 hours. HMA held for more than 24 hours after mixing shall be rejected. Rejected HMA shall be disposed of by the Contractor at no expense to the Contracting Agency. The storage facility shall have an accessible device located at the top of the cone or about the third point. The device shall indicate the amount of material in storage. No HMA shall be accepted from the storage facility when the HMA in storage is below the top of the cone of the storage facility, except as the storage facility is being emptied at the end of the working shift. Recycled asphalt pavement (RAP) utilized in the production of HMA shall be sized prior to entering the mixer so that a uniform and thoroughly mixed HMA is produced. If there is evidence of the recycled asphalt pavement not breaking down during the heating and mixing of the HMA, the Contractor shall immediately suspend the use of the RAP until changes have been approved by the Engineer. After the required amount of mineral materials, RAP, new asphalt binder and asphalt rejuvenator have been introduced into the mixer the HMA shall be mixed until complete and uniform coating of the particles and thorough distribution of the asphalt binder throughout the mineral materials, and RAP is ensured. 5-44.3(7) Spreading and Finishing The mixture shall be laid upon an approved surface, spread, and struck off to the grade and elevation established. HMA pavers complying with Section 5-04.3(3) shall be used CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-71 CFW SPECIAL PROVISIONS VER. 2019.12 to distribute the mixture. Unless otherwise directed by the Engineer, the nominal compacted depth of any layer of any course shall not exceed the following: HMA Class 1" 0.35 feet HMA Class %" and HMA Class 1/2" wearing course 0.30 feet other courses 0.35 feet HMA Class %" 0.15 feet On areas where irregularities or unavoidable obstacles make the use of mechanical spreading and finishing equipment impractical, the paving may be done with other equipment or by hand. When more than one JMF is being utilized to produce HMA, the material produced for each JMF shall be placed by separate spreading and compacting equipment. The intermingling of HMA produced from more than one JMF is prohibited. Each strip of HMA placed during a work shift shall conform to a single JMF established for the class of HMA specified unless there is a need to make an adjustment in the JMF. 5-04.3(8) Awreplate Acceptance Prior to Incorporation in HMA For HMA accepted by nonstatistical evaluation the aggregate properties of sand equivalent, uncompacted void content and fracture will be evaluated in accordance with Section 3-04. Sampling and testing of aggregates for HMA accepted by commercial evaluation will be at the option of the Engineer. 5-04.3(9) HMA Mixture Acceptance Acceptance of HMA shall be as provided under nonstatistical, or commercial evaluation. Nonstatistical evaluation will be used for the acceptance of HMA unless Commercial Evaluation is specified. Commercial evaluation will be used for Commercial HMA and for other classes of HMA in the following applications: sidewalks, road approaches, ditches, slopes, paths, trails, gores, prelevel, temporary pavement, and pavement repair. Other nonstructural applications of HMA accepted by commercial evaluation shall be as approved by the Engineer. Sampling and testing of HMA accepted by commercial evaluation will be at the option of the Engineer. The mix design will be the initial JMF for the class of HMA. The Contractor may request a change in the JMF. Any adjustments to the JMF will require the approval of the Engineer and may be made in accordance with this section. HMA Tolerances and Adjustments 1. Job Mix Formula Tolerances — The constituents of the mixture at the time of acceptance shall be within tolerance. The tolerance limits will be established as follows: For Asphalt Binder and Air Voids (Va), the acceptance limits are determined by adding the tolerances below to the approved JMF values. These values will also be the Upper Specification Limit (USL) and Lower Specification Limit (LSL) required in Section 1-06.2(2)D2 CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-72 CFW SPECIAL PROVISIONS VER. 2019.12 Property Non-Statistical Evaluation Commercial Evaluation Asphalt Binder +/-0.5% +/-0.7% Air Voids,Va 2.5%min. and 5.5% max N/A For Aggregates in the mixture: a. First, determine preliminary upper and lower acceptance limits by applying the following tolerances to the approved JMF. Aggregate Percent Non-Statistical Commercial Evaluation Passing Evaluation V. 1/4". '/2'. and 3/8"sieves +/-6% +/-8% No.4 sieve +/-6% +/-8% No. 8 Sieve +/-6% +/-8% No. 200 sieve 1 +/-2.01% +/-3.0% b. Second, adjust the preliminary upper and lower acceptance limits determined from step (a) the minimum amount necessary so that none of the aggregate properties are outside the control points in Section 9-03.8(6). The resulting values will be the upper and lower acceptance limits for aggregates, as well as the USL and LSL required in Section 1-06.2(2)D2. 2. Job Mix Formula Adjustments — An adjustment to the aggregate gradation or asphalt binder content of the JMF requires approval of the Engineer. Adjustments to the JMF will only be considered if the change produces material of equal or better quality and may require the development of a new mix design if the adjustment exceeds the amounts listed below. a. Aggregates —2 percent for the aggregate passing the 1'/2", 1", W, '/2", W, and the No. 4 sieves, 1 percent for aggregate passing the No. 8 sieve, and 0.5 percent for the aggregate passing the No. 200 sieve. The adjusted JMF shall be within the range of the control points in Section 9-03.8(6). b. Asphalt Binder Content — The Engineer may order or approve changes to asphalt binder content. The maximum adjustment from the approved mix design for the asphalt binder content shall be 0.3 percent 5-04.3(9)A Vacant 5-04.3(9)6 Vacant 5-04.3(9)C MiXtUre Acceptance — Nonstatistical Evaluation HMA mixture which is accepted by Nonstatistical Evaluation will be evaluated by the Contracting Agency by dividing the HMA tonnage into lots. 5-04.3(9)C1 Mixture Nonstatistical Evaluation — Lots and Sublots A lot is represented by randomly selected samples of the same mix design that will be tested for acceptance. A lot is defined as the total quantity of material or work produced for each Job Mix Formula placed. Only one lot per JMF is expected. A sublot shall be equal to one day's production or 800 tons, whichever is less except that the final sublot will be a minimum of 400 tons and may be increased to 1200 tons. All of the test results obtained from the acceptance samples from a given lot shall be evaluated collectively. If the Contractor requests a change to the JMF that is approved, the material produced after the change will be evaluated on the basis of the new JMF for the remaining sublots in the current lot and for acceptance of subsequent lots. For a lot in progress with a CPF less than 0.75, a new lot will begin at the Contractor's request after the Engineer is satisfied that material conforming to the Specifications can be produced. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-73 CFW SPECIAL PROVISIONS VER. 2019.12 Sampling and testing for evaluation shall be performed on the frequency of one sample per sublot. 5-04.3(9)C2 Mixture Nonstatistical Evaluation Sampling Samples for acceptance testing shall be obtained by the Contractor when ordered by the Engineer. The Contractor shall sample the HMA mixture in the presence of the Engineer and in accordance with AASH-TO T 168. A minimum of three samples should be taken for each class of HMA placed on a project. If used in a structural application, at least one of the three samples shall to be tested. Sampling and testing HMA in a Structural application where quantities are less than 400 tons is at the dis-cretion of the Engineer. For HMA used in a structural application and with a total project quantity less than 800 tons but more than 400 tons, a minimum of one acceptance test shall be performed. In all cases, a minimum of 3 samples will be obtained at the point of acceptance, a minimum of one of the three samples will be tested for conformance to the JMF: If the test results are found to be within specification requirements, additional testing will be at the Engineer's discretion. • If test results are found not to be within specification requirements, additional testing of the remaining samples to determine a Composite Pay Factor (CPF) shall be performed. 5-04.3(9)C3 Mixture Nonstatistical Evaluation — Acceptance Testing Testing of HMA for compliance of Va will at the option of the Contracting Agency. If tested, compliance of Va will use WSDOT SOP 731. Testing for compliance of asphalt binder content will be by WSDOT FOP for AASHTO T 308. Testing for compliance of gradation will be by FOP for WAQTC T 27/T 11, 5-04.3(9)C4 Mixture Nonstatistical Evaluation — Pao Factors For each lot of material failing outside the tolerance limits in 5-04.3(9), the Contracting Agency will determine a Composite Pay Factor (CPF) using the following price adjustment factors: Table of Price Adjustment Factors Constituent Factor 6.fy All aggregate passing: 1'/z", 1", W, '/Z", %" and 2 No.4 sieves All aggregate passing No. 8 sieve 15 All aggregate passing No.200 sieve 20 Asphalt binder 40 CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-74 CFW SPECIAL PROVISIONS VER. 2019.12 Air Voids(Va)(where applicable) 20 Each lot of HMA produced under Nonstatistical Evaluation and having all constituents falling within the toler-ance limits of the job mix formula shall be accepted at the unit Contract price with no further evaluation. When one or more constituents fall outside the nonstatistical tolerance limits in the Job Mix Formula shown in Table of Price Adjustment Factors, the lot shall be evaluated in accordance with Section 1-06.2 to determine the appro-priate CPF. The nonstatistical tolerance limits will be used in the calculation of the CPF and the maximum CPF shall be 1.00. When less than three sublots exist, backup samples of the existing sublots or samples from the Roadway shall be tested to provide a minimum of three sets of results for evaluation. 5-04.3(9)C5 Vacant 5-04.3(9)_Q6 Mixture Nonstatistical Evaluation — Price Adjustments For each lot of HMA mix produced under Nonstatistical Evaluation when the calculated CPF is less than 1.00, a Nonconforming Mix Factor (NCMF) will be determined. The NCMF equals the algebraic difference of CPF minus 1.00 multiplied by 60 percent. The total job mix compliance price adjustment will be calculated as the product of the NCMF, the quantity of HMA in the lot in tons, and the unit Contract price per ton of mix. If a constituent is not measured in accordance with these Specifications, its individual pay factor will be considered 1.00 in calculating the Composite Pay Factor(CPF). 5-04.3(9)C7 Mixture Nonstatistical Evaluation - Retests The Contractor may request a sublot be retested. To request a retest, the Contractor shall submit a written request within 7 calendar days after the specific test results have been received. A split of the original acceptance sample will be retested. The split of the sample will not be tested with the same tester that ran the original acceptance test. The sample will be tested for a complete gradation analysis, asphalt binder content, and, at the option of the agency, Va. The results of the retest will be used for the acceptance of the HMA in place of the original sublot sample test results. The cost of testing will be deducted from any monies due or that may come due the Contractor under the Contract at the rate of$500 per sample. 5-04.3 (9)D Mixture Acceptance— Commercial Evaluation If sampled and tested, HMA produced under Commercial Evaluation and having all constituents falling within the tolerance limits of the job mix formula shall be accepted at the unit Contract price with no further evaluation. When one or more constituents fall outside the commercial tolerance limits in the Job Mix Formula shown in 5-04.3(9), the lot shall be evaluated in accordance with Section 1-06.2 to determine the appropriate CPF. The commercial tolerance limits will be used in the calculation of the CPF and the maximum CPF shall be 1.00. When less than three sublots exist, backup samples of the existing sublots or samples from the street shall be tested to provide a minimum of three sets of results for evaluation. For each lot of HMA mix produced and tested under Commercial Evaluation when the calculated CPF is less than 1.00, a Nonconforming Mix Factor (NCMF) will be determined. The NCMF equals the algebraic difference of CPF minus 1.00 multiplied by 60 percent. The Job Mix Compliance Price Adjustment will be calculated as the product CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-75 CFW SPECIAL PROVISIONS VER. 2019.12 of the NCMF, the quantity of HMA in the lot in tons, and the unit Contract price per ton of mix. If a constituent is not measured in accordance with these Specifications, its individual pay factor will be considered 1.00 in calculating the Composite Pay Factor(CPF). 5-04.310) HMA Compaction Acceptance HMA mixture accepted by nonstatistical evaluation that is used in traffic lanes, including lanes for intersections, ramps, truck climbing, weaving, and speed change, and having a specified compacted course thickness greater than 0.10-foot, shall be compacted to a specified level of relative density. The specified level of relative density shall be a Composite Pay Factor (CPF) of not less than 0.75 when evaluated in accordance with Section 1-06.2, using a LSL of 92.0 (minimum of 92 percent of the maximum density). The maximum density shall be determined by WSDOT FOP for AASHTO T 729. The specified level of density attained will be determined by the evaluation of the density of the pavement. The density of the pavement shall be determined in accordance with WSDOT FOP for WAQTC TM 8, except that gauge correlation will be at the discretion of the Engineer, when using the nuclear density gauge and WSDOT SOP 736 when using cores to determine density. Tests for the determination of the pavement density will be taken in accordance with the required procedures for measurement by a nuclear density gauge or roadway cores after completion of the finish rolling. If the Contracting Agency uses a nuclear density gauge to determine density the test procedures FOP for WAQTC TM 8 and WSDOT SOP T 729 will be used on the day the mix is placed and prior to opening to traffic. Roadway cores for density may be obtained by either the Contracting Agency or the Contractor in accordance with WSDOT SOP 734. The core diameter shall be 4-inches minimum, unless otherwise approved by the Engineer. Roadway cores will be tested by the Contracting Agency in accordance with WSDOT FOP for AASHTO T 166. If the Contract includes the Bid item "Roadway Core" the cores shall be obtained by the Contractor in the presence of the Engineer on the same day the mix is placed and at locations designated by the Engineer. If the Contract does not include the Bid item "Roadway Core" the Contracting Agency will obtain the cores. For a lot in progress with a CPF less than 0.75, a new lot will begin at the Contractor's request after the Engineer is satisfied that material conforming to the Specifications can be produced. HMA mixture accepted by commercial evaluation and HMA constructed under conditions other than those listed above shall be compacted on the basis of a test point evaluation of the compaction train. The test point evaluation shall be performed in accordance with instructions from the Engineer. The number of passes with an approved compaction train, required to attain the maximum test point density, shall be used on all subsequent paving. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-76 CFW SPECIAL PROVISIONS VER. 2019.12 HMA for preleveling shall be thoroughly compacted. HMA that is used for preleveling wheel rutting shall be compacted with a pneumatic tire roller unless otherwise approved by the Engineer. Test Results For a sublot that has been tested with a nuclear density gauge that did not meet the minimum of 92 percent of the reference maximum density in a compaction lot with a CPF below 1.00 and thus subject to a price reduction or rejection, the Contractor may request that a core be used for determination of the relative density of the sublot. The relative density of the core will replace the relative density determined by the nuclear density gauge for the sublot and will be used for calculation of the CPF and acceptance of HMA compaction lot. When cores are taken by the Contracting Agency at the request of the Contractor, they shall be requested by noon of the next workday after the test results for the sublot have been provided or made available to the Contractor. Core locations shall be outside of wheel paths and as determined by the Engineer. Traffic control shall be provided by the Contractor as requested by the Engineer. Failure by the Contractor to provide the requested traffic control will result in forfeiture of the request for cores. When the CPF for the lot based on the results of the HMA cores is less than 1.00, the cost for the coring will be deducted from any monies due or that may become due the Contractor under the Contract at the rate of $200 per core and the Contractor shall pay for the cost of the traffic control. 5-04.3(10)A HMA Compaction — General Compaction Requirements Compaction shall take place when the mixture is in the proper condition so that no undue displacement, cracking, or shoving occurs. Areas inaccessible to large compaction equipment shall be compacted by other mechanical means. Any HMA that becomes loose, broken, contaminated, shows an excess or deficiency of asphalt, or is in any way defective, shall be removed and replaced with new hot mix that shall be immediately compacted to conform to the surrounding area. The type of rollers to be used and their relative position in the compaction sequence shall generally be the Contractor's option, provided the specified densities are attained. Unless the Engineer has approved otherwise, rollers shall only be operated in the static mode when the internal temperature of the mix is less than 175°F. Regardless of mix temperature, a roller shall not be operated in a mode that results in checking or cracking of the mat. Rollers shall only be operated in static mode on bridge decks. 5-04.3(10)6 HMA Compaction — Cyclic Densis Low cyclic density areas are defined as spots or streaks in the pavement that are less than 90 percent of the theoretical maximum density. At the Engineer's discretion, the Engineer may evaluate the HMA pavement for low cyclic density, and when doing so will follow WSDOT SOP 733. A $500 Cyclic Density Price Adjustment will be assessed for any 500-foot section with two or more density readings below 90 percent of the theoretical maximum density. 5-04.3(10)C Vacant CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-77 CFW SPECIAL PROVISIONS VER. 2019.12 5-04.3(10)D FIMA Nonstatistical Compaction 5-04.3(10)D1 HMA Nonstatistical Compaction — Lots and Sublots HMA compaction which is accepted by nonstatistical evaluation will be based on acceptance testing performed by the Contracting Agency dividing the project into compaction lots. A lot is represented by randomly selected samples of the same mix design that will be tested for acceptance. A lot is defined as the total quantity of material or work produced for each Job Mix Formula placed. Only one lot per JMF is expected. A sublot shall be equal to one day's production or 400 tons, whichever is less except that the final sublot will be a minimum of 200 tons and may be increased to 800 tons. Testing for compaction will be at the rate of 5 tests per sublot per WSDOT T 738. The sublot locations within each density lot will be determined by the Engineer. For a lot in progress with a CPF less than 0.75, a new lot will begin at the Contractor's request after the Engineer is satisfied that material conforming to the Specifications can be produced. HMA mixture accepted by commercial evaluation and HMA constructed under conditions other than those listed above shall be compacted on the basis of a test point evaluation of the compaction train. The test point evaluation shall be performed in accordance with instructions from the Engineer. The number of passes with an approved compaction train, required to.attain the maximum test point density, shall be used on all subsequent paving. HMA for preleveling shall be thoroughly compacted. HMA that is used to prelevel wheel ruts shall be compacted with a pneumatic tire roller unless otherwise approved by the Engineer. 5-04.3(10)D2 HMA Compaction Nonstatistical Evaluation — ,Acceptance Testing The location of the HMA compaction acceptance tests will be randomly selected by the Engineer from within each sublot, with one test per sublot. 5-04.3(10)D3 HMA Nonstatistical Compaction — Price Adjustments For each compaction lot with one or two sublots, having all sublots attain a relative density that is 92 percent of the reference maximum density the HMA shall be accepted at the unit Contract price with no further evaluation. When a sublot does not attain a relative density that is 92 percent of the reference maximum density, the lot shall be evaluated in accordance with Section 1-06.2 to determine the appropriate CPF. The maximum CPF shall be 1.00, however, lots with a calculated CPF in excess of 1.00 will be used to offset lots with CPF values below 1.00 but greater than 0.90. Lots with CPF lower than 0.90 will be evaluated for compliance per 5-04.3(11). Additional testing by either a nuclear moisture-density gauge or cores will be completed as required to provide a minimum of three tests for evaluation. For compaction below the required 92% a Non-Conforming Compaction Factor (NCCF) will be determined. The NCCF equals the algebraic difference of CPF minus 1.00 multiplied by 40 percent. The Compaction Price Adjustment will be calculated as the CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-78 CFW SPECIAL PROVISIONS VER. 2019.12 product of CPF, the quantity of HMA in the compaction control lot in tons, and the unit Contract price per ton of mix. 5-04.30 1Re'ect Work 5-04.3(11)A Reject Work General Work that is defective or does not conform to Contract requirements shall be rejected. The Contractor may propose, in writing, alternatives to removal and replacement of rejected material. Acceptability of such alternative proposals will be determined at the sole discretion of the Engineer. HMA that has been rejected is subject to the requirements in Section 1-06.2(2) and this specification, and the Contractor shall submit a corrective action proposal to the Engineer for approval. 5-04.3(11)13 Reiectivn by Contractor The Contractor may, prior to sampling, elect to remove any defective material and replace it with new material. Any such new material will be sampled, tested, and evaluated for acceptance. 5-04.3(11)C Resection Without Testing (Mixture or Compaction) The Engineer may, without sampling, reject any batch, load, or section of Roadway that appears defective. Material rejected before placement shall not be incorporated into the pavement. Any rejected section of Roadway shall be removed. No payment will be made for the rejected materials or the removal of the materials unless the Contractor requests that the rejected material be tested. If the Contractor elects to have the rejected material tested, a minimum of three representative samples will be obtained and tested. Acceptance of rejected material will be based on conformance with the nonstatistical acceptance Specification. If the CPF for the rejected material is less than 0.75, no payment will be made for the rejected material; in addition, the cost of sampling and testing shall be borne by the Contractor. If the CPF is greater than or equal to 0.75, the cost of sampling and testing will be borne by the Contracting Agency. If the material is rejected before placement and the CPF is greater than or equal to 0.75, compensation for the rejected material will be at a CPF of 0.75. If rejection occurs after placement and the CPF is greater than or equal to 0.75, compensation for the rejected material will be at the calculated CPF with an addition of 25 percent of the unit Contract price added for the cost of removal and disposal. 5-04.3[11}D Rejection - A Partial Sublot In addition to the random acceptance sampling and testing, the Engineer may also isolate from a normal sublot any material that is suspected of being defective in relative density, gradation or asphalt binder content. Such isolated material will not include an original sample location. A minimum of three random samples of the suspect material will be obtained and tested. The material will then be statistically evaluated as an independent lot in accordance with Section 1-06.2(2). 5-04.301)E Rejection -An Entire Sublot An entire sublot that is suspected of being defective may be rejected. When a sublot is rejected a minimum of two additional random samples from this sublot will be obtained. These additional samples and the original sublot will be evaluated as an independent lot in accordance with Section 1-06.2(2). CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-79 CFW SPECIAL PROVISIONS VER. 2019.12 5-04.3(11)F Reiection -A Lot in Progress The Contractor shall shut down operations and shall not resume HMA placement until such time as the Engineer is satisfied that material conforming to the Specifications can be produced: 1. When the Composite Pay Factor (CPF) of a lot in progress drops below 1.00 and the Contractor is taking no corrective action, or 2. When the Pay Factor (PF) for any constituent of a lot in progress drops below 0.95 and the Contractor is taking no corrective action, or 3. When either the PR for any constituent or the CPF of a lot in progress is less than 0.75. 5-04.3(11)G Rejection -An Entire Lot (Mixture or Compaction) An entire lot with a CPF of less than 0.75 will be rejected. 5-04.3(12) Joints 5-04.3(12)A HMA Joints 5-04.3(12)A1 Transverse Joints The Contractor shall conduct operations such that the placing of the top or wearing course is a continuous operation or as close to continuous as possible. Unscheduled transverse joints will be allowed and the roller may pass over the unprotected end of the freshly laid mixture only when the placement of the course must be discontinued for such a length of time that the mixture will cool below compaction temperature. When the Work is resumed, the previously compacted mixture shall be cut back to produce a slightly beveled edge for the full thickness of the course. A temporary wedge of HMA constructed on a 20HAV shall be constructed where a transverse joint as a result of paving or planing is open to traffic. The HMA in the temporary wedge shall be separated from the permanent HMA by strips of heavy wrapping paper or other methods approved by the Engineer. The wrapping paper shall be removed and the joint trimmed to a slightly beveled edge for the full thickness of the course prior to resumption of paving. The material that is cut away shall be wasted and new mix shall be laid against the cut. Rollers or tamping irons shall be used to seal the joint. 5-04.3(12)A2 Longitudinal Joints The longitudinal joint in any one course shall be offset from the course immediately below by not more than 6 inches nor less than '2 inches. All longitudinal joints constructed in the wearing course shall be located at a lane line or an edge line of the Traveled Way. A notched wedge joint shall be constructed along all longitudinal joints in the wearing surface of new HMA unless otherwise approved by the Engineer. The notched wedge joint shall have a vertical edge of not less than the maximum aggregate size or more than 'h of the compacted lift thickness and then taper down on a slope not steeper than 4H:1V. The sloped portion of the HMA notched wedge joint shall be uniformly compacted. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-80 CFW SPECIAL PROVISIONS VER. 2019.12 5-04.3(12)B Bridge Paving Joint Seals 5-04.3(12)B1 HMA Sawcut and Seal Prior to placing HMA on the bridge deck, establish sawcut alignment points at both ends of the bridge paving joint seals to be placed at the bridge ends, and at interior joints within the bridge deck when and where shown in the Plans. Establish the sawcut alignment points in a manner that they remain functional for use in aligning the sawcut after placing the overlay. Submit a Type 1 Working Drawing consisting of the sealant manufacturer's application procedure. Construct the bridge paving joint seal as specified ion the Plans and in accordance with the detail shown in the Standard Plans. Construct the sawcut in accordance with the detail shown in the Standard Plan. Con-struct the sawcut in accordance with Section 5- 05.3(8)6 and the manufacturer's application procedure. 5-04.3(12)B2 Paved Panel Joint Seal Construct the paved panel joint seal in accordance with the requirements specified in section 5-04.3(12)B1 and the following requirement: 1. Clean and seal the existing joint between concrete panels in accordance with Section 5-01.3(8) and the details shown in the Standard Plans. 5-04.3(13) Surface Smoothness The completed surface of all courses shall be of uniform texture, smooth, uniform as to crown and grade, and free from defects of all kinds. The completed surface of the wearing course shall not vary more than % inch from the lower edge of a 10-foot straightedge placed on the surface parallel to the centerline. The transverse slope of the completed surface of the wearing course shall vary not more than 1/4 inch in 10 feet from the rate of transverse slope shown in the Plans. When deviations in excess of the above tolerances are found that result from a high place in the HMA, the pavement surface shall be corrected by one of the following methods: 1. Removal of material from high places by grinding with an approved grinding machine, or 2. Removal and replacement of the wearing course of HMA, or 3. By other method approved by the Engineer. Correction of defects shall be carried out until there are no deviations anywhere greater than the allowable tolerances. Deviations in excess of the above tolerances that result from a low place in the HMA and deviations resulting from a high place where corrective action, in the opinion of the Engineer, will not produce satisfactory results will be accepted with a price adjustment. The Engineer shall deduct from monies due or that may become due to the Contractor the sum of $500.00 for each and every section of single traffic lane 100 feet in length in which any excessive deviations described above are found. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-81 CFW SPECIAL PROVISIONS VER. 2019.12 When utility appurtenances such as manhole covers and valve boxes are located in the traveled way, the utility appurtenances shall be adjusted to the finished grade prior to paving. This requirement may be waived when requested by the Contractor, at the discretion of the Engineer or when the adjustment details provided in the project plan or specifications call for utility appurtenance adjustments after the completion of paving. Utility appurtenance adjustment discussions will be included in the Pre-Paving planning (5-04.3(14)B3). Submit a written request to waive this requirement to the Engineer prior to the start of paving. 5-04.304) Planing (Milling) Bituminous Pavement The planing plan must be approved by the Engineer and a pre planing meeting must be held prior to the start of any planing. See Section 5-04.3(14)B2 for information on planning submittals. Locations of existing surfacing to be planed are as shown in the Drawings. Where planing an existing pavement is specified in the Contract, the Contractor must remove existing surfacing material and to reshape the surface to remove irregularities. The finished product must be a prepared surface acceptable for receiving an HMA overlay. Use the cold milling method for planing unless otherwise specified in the Contract. Do not use the planer on the final wearing course of new HMA. Conduct planing operations in a manner that does not tear, break, burn, or otherwise damage the surface which is to remain. The finished planed surface must be slightly grooved or roughened and must be free from gouges, deep grooves, ridges, or other imperfections. The Contractor must repair any damage to the sur-face by the Contractor's planing equipment, using an Engineer approved method. Repair or replace any metal castings and other surface improvements damaged by planing, as deter-mined by the Engineer. A tapered wedge cut must be planed longitudinally along curb lines sufficient to provide a minimum of 4 inches of curb reveal after placement and compaction of the final wearing course. The dimensions of the wedge must be as shown on the Drawings or as specified by the Engineer. A tapered wedge cut must also be made at transitions to adjoining pavement surfaces (meet lines) where butt joints are shown on the Drawings. Cut butt joints in a straight line with vertical faces 2 inches or more in height, producing a smooth transition to the existing adjoining pavement. After planing is complete, planed surfaces must be swept, cleaned, and if required by the Contract, patched and preleveled. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-82 CFW SPECIAL PROVISIONS VER. 2019.12 The Engineer may direct additional depth planing. Before performing this additional depth planing, the Contractor must conduct a hidden metal in pavement detection survey as specified in Section 5-04.3(14)A. 5-04.3(14)A Pre-Planing Metal Detection Check Before starting planing of pavements, and before any additional depth planing required by the Engineer, the Contractor must conduct a physical survey of existing pavement to be planed with equipment that can iden-tify hidden metal objects. Should such metal be identified, promptly notify the Engineer. See Section 1-07.16(1) regarding the protection of survey monumentation that may be hidden in pavement. The Contractor is solely responsible for any damage to equipment resulting from the Contractor's failure to conduct a pre-planing metal detection survey, or from the Contractor's failure to notify the Engineer of any hidden metal that is detected. 5-04.3(14)13 Paving and Planing Under Traffic 5-04.3(14)B1 General In addition the requirements of Section 1-07.23 and the traffic controls required in Section 1-10, and unless the Contract specifies otherwise or the Engineer approves, the Contractor must comply with the following: 1. Intersections: a. Keep intersections open to traffic at all times, except when paving or planing operations through an intersection requires closure. Such closure must be kept to the minimum time required to place and compact the HMA mixture, or plane as appropriate. For paving, schedule such closure to individual lanes or portions thereof that allows the traffic volumes and schedule of traffic volumes required in the approved traffic control plan. Schedule work so that adjacent intersections are not impacted at the same time and comply with the traffic control restrictions required by the Traffic Engineer. Each individual intersection closure or partial closure, must be addressed in the traffic control plan, which must be submitted to and accepted by the Engineer, see Section 1-10.2(2). b. When planing or paving and related construction must occur in an intersection, consider scheduling and sequencing such work into quarters of the intersection, or half or more of an intersection with side street detours. Be prepared to sequence the work to individual lanes or portions thereof. C. Should closure of the intersection in its entirety be necessary, and no trolley service is impacted, keep such closure to the minimum time required to place and compact the HMA mixture, plane, remove asphalt, tack coat, and as needed. d. Any work in an intersection requires advance warning in both signage and a number of Working Days advance notice as determined by the Engineer, to alert traffic and emergency services of the intersection closure or partial closure. e. Allow new compacted HMA asphalt to cool to ambient temperature before any traffic is allowed on it. Traffic is not allowed on newly placed asphalt until approval has been obtained from the Engineer. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-83 CFW SPECIAL PROVISIONS VER. 2019.12 2. Temporary centerline marking, post-paving temporary marking, temporary stop bars, and maintaining temporary pavement marking must comply with Section 8-23. 3. Permanent pavement marking must comply with Section 8-22. 5-04.3(14)B2 Submittals — Planing Plan and HMA Paving Plan The Contractor must submit a separate planing plan and a separate paving plan to the Engineer at least 5 Working Days in advance of each operation's activity start date. These plans must show how the moving operation and traffic control are coordinated, as they will be discussed at the pre-planing briefing and pre-paving briefing. When requested by the Engineer, the Contractor must provide each operation's traffic control plan on 24 x 36 inch or larger size Shop Drawings with a scale showing both the area of operation and sufficient detail of traffic beyond the area of operation where detour traffic may be required. The scale on the Shop Drawings is 1 inch = 20 feet, which may be changed if the Engineer agrees sufficient detail is shown. The planing operation and the paving operation include, but are not limited to, metal detection, removal of asphalt and temporary asphalt of any kind, tack coat and drying, staging of supply trucks, paving trains, rolling, scheduling, and as may be discussed at the briefing. When intersections will be partially or totally blocked, provide adequately sized and noticeable signage alerting traffic of closures to come, a minimum 2 Working Days in advance. The traffic control plan must show where peace officers will be stationed when signalization is or may be, countermanded, and show ar-eas where flaggers are proposed. At a minimum, the planing and the paving plan must include: 1. A copy of the accepted traffic control plan, see Section 1-10.2(2), detailing each day's traffic control as it relates to the specific requirements of that day's planing and paving. Briefly describe the se-quencing of traffic control consistent with the proposed planing and paving sequence, and scheduling of placement of temporary pavement markings and channelizing devices after each day's planing, and paving. 2. A copy of each intersection's traffic control plan. 3. Haul routes from Supplier facilities, and locations of temporary parking and staging areas, including return routes. Describe the complete round trip as it relates to the sequencing of paving operations. 4. Names and locations of HMA Supplier facilities to be used. 5. List of all equipment to be used for paving. 6. List of personnel and associated job classification assigned to each piece of paving equipment. 7. Description (geometric or narrative) of the scheduled sequence of planing and of paving, and intended area of planing and of paving for each day's work, must include the directions of proposed planing and of proposed paving, sequence of adjacent lane paving, sequence of skipped lane paving, intersection planing and paving scheduling and sequencing, and proposed notifications and coordinations to be timely made. The plan must show HMA joints relative to the final pavement marking lane lines. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-84 CFW SPECIAL PROVISIONS VER. 2019.12 8. Names, job titles, and contact information for field, office, and plant supervisory personnel. 9. A copy of the approved Mix Designs. 10. Tonnage of HMA to be placed each day. 11. Approximate times and days for starting and ending daily operations. 5-04.3(14)63 Pre-Paving and Pre-Planing Briefing At least 2 Working Days before the first paving operation and the first planing operation, or as scheduled by the Engineer for future paving and planing operations to ensure the Contractor has adequately prepared for notifying and coordinating as required in the Contract, the Contractor must be prepared to discuss that day's operations as they relate to other entities and to public safety and convenience, including driveway and business access, garbage truck operations, Metro transit operations and working around energized overhead wires, school and nursing home and hospital and other accesses, other contractors who may be operating in the area, pedestrian and bicycle traffic, and emergency services. The Contractor, and Subcontractors that may be part of that day's operations, must meet with the Engineer and discuss the proposed operation as it relates to the submitted planing plan and paving plan, approved traffic control plan, and public convenience and safety. Such discussion includes, but is not limited to: 1. General for both Paving Plan and for Planing Plan: a. The actual times of starting and ending daily operations. b. In intersections, how to break up the intersection, and address traffic control and signalization for that operation, including use of peace officers. c. The sequencing and scheduling of paving operations and of planing operations, as applicable, as it relates to traffic control, to public convenience and safety, and to other con-tractors who may operate in the Project Site. d. Notifications required of Contractor activities, and coordinating with other entities and the public as necessary. e. Description of the sequencing of installation and types of temporary pavement markings as it relates to planning and to paving. f. Description of the sequencing of installation of, and the removal of, temporary pavement patch material around exposed castings and as may be needed g. Description of procedures and equipment to identify hidden metal in the pavement, such as survey monumentation, monitoring wells, street car rail, and castings, before planning, see Section 5-04.3(14)B2. h. Description of how flaggers will be coordinated with the planing, paving, and related operations. i. Description of sequencing of traffic controls for the process of rigid pavement base repairs. j. Other items the Engineer deems necessary to address. 2. Paving — additional topics: a. When to start applying tack and coordinating with paving. b. Types of equipment and numbers of each type equipment to be used. If more pieces of equipment than personnel are proposed, describe the sequencing of the personnel operating the types of equipment. Discuss the continuance of operator personnel for each type equip-ment as it relates to meeting Specification requirements. c. Number of JMFs to be placed, and if more than one JMF how the Contractor will ensure different JMFs are distinguished, how pavers and MTVs are CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-85 CFW SPECIAL PROVISIONS VER. 2019.12 distinguished if more than one JMF is being placed at the time, and how pavers and MTVs are cleaned so that one JMF does not adversely influence the other JMF. d. Description of contingency plans for that day's operations such as equipment breakdown, rain out, and Supplier shutdown of operations. e. Number of sublots to be placed, sequencing of density testing, and other sampling and testing. 5-04.3(15) Sealing Pavement Surfaces Apply a fog seal where shown in the plans. Construct the fog seal in accordance with Section 5-02.3. Unless otherwise approved by the Engineer, apply the fog seal prior to opening to traffic. 5-04.3(16) HMA Road Approaches HMA approaches shall be constructed at the locations shown in the Plans or where staked by the Engineer. The Work shall be performed in accordance with Section 5-04. 5-04.3(17) Temporary Asphalt Pavement (April 12, 2018 CFW GSP) Section 5-04.3(17) is a new section: Temporary asphalt pavement shall be placed by the Contractor immediately upon the request of the Engineer for the maintenance of traffic during construction. These areas include: voids created by the removal of existing improvements (i.e. Traffic islands, curbs), providing paved access to private properties, and ramps for property access during cement concrete driveway approach construction. All temporary paving shall be approved by the Engineer before placement. Any areas of temporary pavement to be removed and replaced shall be approved by the Engineer beforehand. This work shall also include the removal of temporary asphalt concrete pavement in its entirety prior to final paving. Hot Mix Asphalt Temporary Pavement: Hot mix asphalt will be used for any trench restoration within the traveled way. Whether temporary or permanent, saw cut and treat edges with CSS-1 asphalt emulsion and apply a minimum 3- inch pavement depth or match existing, whichever is greater. Also, fill voids created by the removal of existing traffic islands and curbing, paving over excavated roadway to temporary access to adjacent properties, and ramps for property access during concrete approach construction. Cold Mix Asphalt Temporary Pavement: Cold mix asphalt is allowed for temporary paving outside the traveled way. The cold mix shall be approved by the Engineer and placed in a 2-inch minimum thickness. Placement of temporary pavement without prior approval of the Engineer shall be considered as a benefit of the Contractor and no cost to the owner. Any areas of temporary pavement to be removed and replaced require prior approval by the Engineer. This work shall include the removal of the temporary pavement prior to paving of final asphalt concrete pavement. 5-04.4 Measurement HMA Cl. PG _, HMA for _ Cl. _ PG , and Commercial HMA will be measured by the ton in accordance with Section 1-09.2, with no deduction being CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-86 CFW SPECIAL PROVISIONS VER. 2019.12 made for the weight of asphalt binder, mineral filler, or any other component of the mixture. If the Contractor elects to remove and replace mix as allowed by Section 5- 04.3(11), the material removed will not be measured. Roadway cores will be measured per each for the number of cores taken. Preparation of untreated roadway will be measured by the mile once along the centerline of the main line Roadway. No additional measurement will be made for ramps, Auxiliary Lanes, service roads, Frontage Roads, or Shoulders. Measurement will be to the nearest 0.01 mile. Soil residual herbicide will be measured by the mile for the stated width to the nearest 0.01 mile or by the square yard, whichever is designated in the Proposal. Pavement repair excavation will be measured by the square yard of surface marked prior to excavation. Asphalt for prime coat will be measured by the ton in accordance with Section 1-09.2. Prime coat aggregate will be measured by the cubic yard, truck measure, or by the ton, whichever is designated in the Proposal. Asphalt for fog seal will be measured by the ton, as provided in Section 5-02.4. Longitudinal joint seals between the HMA and cement concrete pavement will be measured by the linear foot along the line and slope of the completed joint seal. Planing bituminous pavement will be measured by the square yard. Temporary pavement marking will be measured by the linear foot as provided in Section 8-23.4. Water will be measured by the M gallon as provided in Section 2-07.4. (April 12, 2018 CFW GSP) Section 5-04.4 is supplemented with the following: Hot Mix Asphalt Temporary Pavement shall be measured by the ton of material actually placed, with no deduction being made for the weight of liquid asphalt, blending sand, mineral filler, or any other component of the mixture. Hot Mix Asphalt Temporary Pavement shall be paid under the "Temporary Pavement' bid item and shall include placement and compaction of hot mix asphalt, removal and disposal of temporary pavement. Cold Mix Asphalt Temporary Pavement will not be measured and shall be considered incidental to other bid items. 5-04.5 Payment Payment will be made for each of the following Bid items that are included in the Proposal: CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-87 CFW SPECIAL PROVISIONS VER. 2019.12 "HMA Cl. _ PG _", per ton. "HMA for Approach Cl. PG_", per ton. "HMA for Preleveling Cl. _ PG_", per ton. "HMA for Pavement Repair Cl. PG ", per ton. "Commercial HMA", per ton. The unit Contract price per ton for "HMA Cl. _ PG _", "HMA for Approach Cl. PG ", "HMA for Preleveling Cl. PG ", "HMA for Pavement Repair Cl. _ PG ", and "Commercial HMA" shall be full compensation for all costs, including anti- stripping additive, incurred to carry out the requirements of Section 5-04 except for those costs included in other items which are included in this Subsection and which are included in the Proposal. "Preparation of Untreated Roadway", per mile. The unit Contract price per mile for "Preparation of Untreated Roadway" shall be full pay for all Work described under 5-04.3(4) , with the exception, however, that all costs involved in patching the Roadway prior to placement of HMA shall be included in the unit Contract price per ton for "HMA Cl. PG _" which was used for patching. If the Proposal does not include a Bid item for "Preparation of Untreated Roadway", the Roadway shall be prepared as specified, but the Work shall be included in the Contract prices of the other items of Work. "Preparation of Existing Paved Surfaces", per mile. The unit Contract Price for "Preparation of Existing Paved Surfaces" shall be full pay for all Work described under Section 5-04.3(4) with the exception, however, that all costs involved in patching the Roadway prior to placement of HMA shall be included in the unit Contract price per ton for "HMA Cl. PG 11which was used for patching. If the Proposal does not include a Bid item for "Preparation of Untreated Roadway", the Roadway shall be prepared as specified, but the Work shall be included in the Contract prices of the other items of Work. "Crack Sealing", by force account. "Crack Sealing" will be paid for by force account as specified in Section 1-09.6. For the purpose of providing a common Proposal for all Bidders, the Contracting Agency has entered an amount in the Proposal to become a part of the total Bid by the Contractor. "Pavement Repair Excavation Incl. Haul", per square yard. The unit Contract price per square yard for "Pavement Repair Excavation Incl. Haul" shall be full payment for all costs incurred to perform the Work described in Section 5- 04.3(4) with the exception, however, that all costs involved in the placement of HMA shall be included in the unit Contract price per ton for"HMA for Pavement Repair Cl. PG _", per ton. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-88 CFW SPECIAL PROVISIONS VER. 2019.12 "Asphalt for Prime Coat", per ton. The unit Contract price per ton for "Asphalt for Prime Coat" shall be full payment for all costs incurred to obtain, provide and install the material in accordance with Section 5- 04.3(4). "Prime Coat Agg.", per cubic yard, or per ton. The unit Contract price per cubic yard or per ton for "Prime Coat Agg." shall be full pay for furnishing, loading, and hauling aggregate to the place of deposit and spreading the aggregate in the quantities required by the Engineer. "Asphalt for Fog Seal", per ton. Payment for"Asphalt for Fog Seal" is described in Section 5-02.5. "Longitudinal Joint Seal", per linear foot. The unit Contract price per linear foot for "Longitudinal Joint Seal" shall be full payment for all costs incurred to perform the Work described in Section 5-04.3(12). "Planing Bituminous Pavement", per square yard. The unit Contract price per square yard for "Planing Bituminous Pavement" shall be full payment for all costs incurred to perform the Work described in Section 5-04.3(14). "Temporary Pavement Marking", per linear foot. Payment for"Temporary Pavement Marking" is described in Section 8-23.5. "Wates", per M gallon. Payment for"Water" is described in Section 2-07.5. "Job Mix Compliance Price Adjustment", by calculation. "Job Mix Compliance Price Adjustment' will be calculated and paid for as described in Section 5-04.3(9)C6. "Compaction Price Adjustment", by calculation. "Compaction Price Adjustment" will be calculated and paid for as described in Section 5- 04..3(10)D3. "Roadway Core", per each. The Contractor's costs for all other Work associated with the coring (e.g., traffic control) shall be incidental and included within the unit Bid price per each and no additional payments will be made. CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-89 CFW SPECIAL PROVISIONS VER. 2019.12 "Cyclic Density Price Adjustment", by calculation. "Cyclic Density Price Adjustment" will be calculated and paid for as described in Section 5-04.3(10)6. (April 12, 2018 CFW GSP) Section 5-04.5 is supplemented with the following: "Temporary Pavement", per ton. END OF DIVISION 5 CITY OF FEDERAL WAY 2020-2021 Neighborhood Traffic Safety (NTS) Program SP-90 CFW SPECIAL PROVISIONS VER. 2019.12 DIVISION 8 MISCELLANEOUS CONSTRUCTION 8-01 EROSION CONTROL AND WATER POLLUTION CONTROL 8-01.4 Measurement Section 8-01.4 is supplemented with the following: There will be no separate measurement for all temporary water pollution/erosion control work during construction. 8-01.4 Payment Section 8-01.5 is supplemented with the following: There will be no separate payment for all temporary water pollution/erosion control work during construction. This work will be considered incidental to other bid prices in the Proposal. 8-04 CURBS,_CUTTERS, AND SPILLWAYS 8-04.3 Construction Requirements (April 12, 2018 CFW GSP) Section 8-04.3 is supplemented with the following: The sub-base for curb and gutter sections shall be compacted to 95 percent density at or below optimum moisture content, as per Section 2-03.3(14)D revised, before placing the curb and gutter. White-pigmented curing compounds will not be allowed. The top of the finished concrete shall not deviate more than one-eighth (1/8") in ten feet (10') or the alignment one-fourth (1/4") in ten feet (10'). Where shown on the Plans, the concrete curb will be ramped for wheel chairs as shown in the City Standard Plan Details. Where shown on the plans, the Contractor shall paint the curbs with 2 full coats of Paint formula No. H-2-83 or H-3-83 as shown on plans or directed by the Engineer. Paint and application shall conform to the Standard Specifications for traffic paint striping. Under 8-04.3(1)A, delete the second sentence of the second paragraph and the third paragraph. Extruded Curb Type 6 shall be installed without the #3 bar shown in Standard Plan F-10.42. Remove and replace curb and gutter as shown on the plans 8-04.4 Measurement (April 12, 2018 CFW GSP) CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY (NTS) PROGRAM AUGUST 2019 SP-91 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 Section 8-04.4 is supplemented with the following: Painting of curbs, where required, will not be measured and is considered incidental to the unit price of the type of curb. Measurement for Cement Concrete Curb and Gutter and Removing Cement Concrete Curb and Gutter up to twenty-five (25) feet for curb ramp construction will be incidental to Bid item "Remove & Replace Curb Ramp, Complete". "Pedestrian Refuge Island, Complete" shall be measured per each, and shall include all items necessary to install a complete Pedestrian Refuge, per appropriate detail. The City inspector shall designate the locations and limits of installation, removal, and replacement. All other work, materials, tools, equipment, and labor necessary for the completion of "Pedestrian Refuge Island, Complete" shall be considered incidental to the same. Such items may include, but are not limited to sawcutting, hauling, asphalt removal, asphalt restoration, and traffic control which shall be considered incidental and will not be measured. 8-04.5 Payment (April 12, 2018 CFW GSP) Section 8-04.5 is supplemented with the following: "Extruded Curb, Type 6", per linear foot. "Remove and Replace Concrete Curb and Gutter, Complete, per linear foot. "Pedestrian Refuge Island, Complete", per each 8-05 ROUNDABOUT AND TRAFFIC CIRCLE ISI ANDS 8-05.1 Description (July 9, 2019 CFW GSP) Roundabout or traffic circle islands shall consist of the construction of precast cement concrete curbs, removal of pavement and crushed rock within the curb circle, monument case/cover adjustment, and topsoil placement. All utility cover and lid adjustments will be performed by the utility. See CFW Development Standard Drawing No. 3-59. 8-05.4 Measurement (July 9, 2019 CFW GSP) The outer diameter of each circular island will be measured to determine the appropriate diameter range and pay item. Non-circular islands will be measured by averaging the measured diameter of the widest and narrowest points. The individual quantities of materials for each island will not be measured. Roundabout or Traffic Circle Islands will be measured as a lump sum for each complete island. 8-05.5 Payment (July 9,2019 CFW GSP) Payment will be made for each Bid item that is requested in a work order: "Traffic Circle Island, Complete (10'-16' Diameter)", per each "Traffic Circle Island, Complete (17'-24' Diameter)", per each CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY (NTS) PROGRAM AUGUST 2019 SP-92 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 "Traffic Circle Island, Complete (25-32' Diameter)", per each 8-06 CEIVIENT CONCRETE DRIVEWAY ENTRANCES 8-06.3 Construction Reguirements (April 12, 2018 CFW GSP) Section 8-06.3 is supplemented with the following: All driveways shall remain open except as necessary to permit curing of construction materials or for short periods of time as required for excavations. However, at least one (1) driveway per parcel shall remain open to vehicular traffic at all times unless otherwise approved by the Engineer and affected property owner in writing. If a parcel has only one driveway, then that driveway must be constructed one-half at a time to allow the passage of vehicles. The amount of time that a driveway can be closed will be limited. To meet these requirements, the Contractor may use a quick setting concrete. The Engineer shall approve the quick-setting mix prior to use. Property owners shall be notified in writing at least 48 hours in advance of any planned driveway closures Crushed rock may be used, with Engineer approval, to maintain a driving surface. 8-06.5 Pa ment (April 12, 2018 CFW GSP) Section 8-06.5 is supplemented with the following: If the Contractor chooses to use a quick-setting concrete mix for driveway construction, any additional costs to use such mix shall be incidental to the bid item for"Cement Conc. Driveway" and no additional payment will be made. If the Contractor chooses to use crushed rock to maintain a driveway surface, it shall be incidental to the bid item for "Cement Conc. Driveway" and no additional payment shall be made. 8-07 PRECAST TE:AFFIC CURB 8-07.1 Description (December 12, 2012 CFW GSP) Section 8-07.1 is deleted and replaced with the following: This Work consists of furnishing, removing, and installing precast traffic curb, block traffic curb, sloped mountable curb, or dual faced sloped mountable curb of the design and type specified in the Plans in accordance with these Specifications and the Standard Plans, in the locations indicated in the Plans or as identified by the Engineer. 8-07.2 Materials (August 9, 2014 CFW GSP) Section 8-07.2 is supplemented with the following: Block Traffic Curb 9-18.3 8-07.3 Construction Requirements 8.07.3'1 Installing Curbs (March 30, 2018 CFW GSP) CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY (NTS) PROGRAM AUGUST 2019 SP-93 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 Section 8-07.3(1) is supplemented with the following: For both types of curb, nosing pieces, connecting dividers, and radial sections, as detailed in the Plans, will be required at the ends of the curb lines, at transitions from Type C traffic curb to Type A traffic curb, and at Type A traffic curb installation with radii less than 10 feet. 8-07.4 Measurement (August 9, 2014 CFW GSP) Section 8-07.4 is supplemented with the following: Type A precast traffic curb and Type A block traffic curb will be measured by the linear foot along the front face of the curb and return. Type A nosing pieces and dividers will be measured as Type A curb. Type C precast traffic curb and Type C block traffic curb will be measured by the linear foot along the axis of the curb. Type C nosing pieces will be measured as Type C curb. 8-07.5 Payment (August 9, 2014 CFW GSP) Section 8-07.5 is supplemented with the following: "Type A Precast Traffic Curb", per linear foot. "Type C Precast Traffic Curb", per linear foot. "Type A Block Traffic Curb", per linear foot. "Type C Block Traffic Curb", per linear foot. "Remove Precast, Block or Extruded Curb per Linear Foot. "Precast Traffic Curb, Painted", per linear foot. "Block Traffic Curb, Painted", per linear foot. 8-13, MONUMENT CASES 8-13.1 Description (March 13, 1995 WSDOT GSP, OPTION 1) Section 8-13.1 is deleted and replaced by the following: This work shall consist of furnishing and placing monument cases, covers, and pipes in accordance with the Standard Plans and these Specifications, in conformity with the lines and locations shown in the Plans or as staked by the Engineer. 8-13.2 Materials (March 13, 1995 WSDOT GSP, OPTION 1) Section 8-13.2 is supplemented with the following: The pipe shall be Schedule 40 galvanized pipe. 8-13.3 Construction Requirements (April 12, 2018 CFW GSP) The last paragraph of Section 8-13.3 is revised to read: The Contractor will be responsible for placing the concrete core and tack or wire inside the pipe. Section 8-13.3 is supplemented with the following: Where shown in the Plans or where directed by the Engineer, existing monument case and covers shall be adjusted to grade as designated by the Engineer. The existing monument shall be carefully protected so as not to disturb its location in any way. The CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY(NTS) PROGRAM AUGUST 2019 SP-94 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 Contractor shall have a licensed professional land surveyor locate the monument prior to the case and cover adjustment if any disturbance of the existing monument is probable. The existing cast iron ring and cover shall first be removed and thoroughly cleaned for reinstalling at the new elevation. From that point, the existing structure shall be raised or lowered to the required elevation. The materials and method of construction shall conform to the requirements of the Standard Plan as approved by the Engineer. 8-13.4 Measurement (March 13, 1995 WSDOT GSP, OPTION 1) Section 8-13.4 is deleted and replaced by the following: Measurement of monument case, cover, and pipe will be not be made as it is incidental to other bid item. 8-13.5 Payment (April 12, 2018 CFW GSP) Section 8-13.5 is supplemented with the following: No payment will be made for monument case, cover, and pipe as these items are incidental to other bid item. 8-14 CEMENT CONCRETE SIDEWALKS 8-14.1 Cement Concrete Sidewalks (April 3, 2017 WSDOT GSP, OPTION 1) Section 8-14.1 is supplemented with the following: This work shall also include construction of pervious cement concrete sidewalks. 8-14.2 Materials (April 12, 2018 CFW GSP) Section 8-14.2 is supplemented with the following: The Cement Concrete Sidewalk and curb ramps shall be constructed of Class 3000 concrete or greater. Pervious Cement Concrete Concrete Mix Design: The Contractor shall submit a proposed mix design for the pervious cement concrete, with proportions of materials, to the Engineer 7 working days prior to commencement of work. ACI 522R-10 shall be used to determine mix design proportions. The data for the mix design shall include fresh density of the proposed pervious concrete mixture as determined in accordance with AASHTO T 19M/T 19 paragraph 11, jigging procedure. Concrete Mix Design Criteria • The cementitious content, including pozzolans if used, shall be between 450 and 550 pounds per cubic yard. • Total void content shall be greater than 15 percent and less than 25 percent, as measured by ASTM C 1688. • The water/cementitous material ratio, by weight, shall be between 0.27 and 0.35. CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY (NTS) PROGRAM AUGUST 2019 SP-95 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 • Cement: Portland Cement Type I or II conforming to ASTM C 150 or Portland Cement Type IP or IS conforming to ASTM C 595. • Aggregate: Use crushed gravel, stone meeting No. 8 coarse aggregate or No. 89 coarse aggregate per ASTM D 448. If other gradation of aggregate is to be used, submit data on proposed material to the Engineer for approval at least 7 working days prior to performing the work. • Air Entraining Agent: Comply with ASTM C 260 • Water: Comply with ASTM C 94 8-14.3 Construction Requirements (April 3, 2017 WSDOT GSP, OPTION 1) Section 8-14.3 is supplemented with the following: The Contractor shall request a pre-meeting with the Engineer to be held 2 to 5 working days before any work can start on cement concrete sidewalks, curb ramps or other pedestrian access routes to discuss construction requirements. Those attending shall include: 1. The Contractor and Subcontractor in charge of constructing forms, and placing, and finishing the cement concrete. 2. Engineer (or representative) and Project Inspectors for the cement concrete sidewalk, curb ramp or pedestrian access route Work. Items to be discussed in this meeting shall include, at a minimum, the following: 1. Slopes shown on the Plans. 2. Inspection 3. Traffic control 4. Pedestrian control, access routes and delineation 5. Accommodating utilities 6. Form work 7. Installation of detectable warning surfaces 8. Contractor ADA survey and ADA Feature as-built requirements 9. Cold Weather Protection (January 7, 2019 WSDOT GSP, OPTION 2) Section 8-14.3 is supplemented with the following: Timing Restrictions Curb ramps shall be constructed on one leg of the intersection at a time. The curb ramps shall be completed and open to traffic within five calendar days before construction can begin on another leg of the intersection unless otherwise allowed by the Engineer. Unless otherwise allowed by the Engineer, the five calendar day time restriction begins when an existing curb ramp for the quadrant or traffic island/median is closed to pedestrian use and ends when the quadrant or traffic island/median is fully functional and open for pedestrian access. CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY(NTS) PROGRAM AUGUST 2019 SP-96 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 (January 7, 2019 WSDOT GSP, OPTION 3) Section 8-14.3 is supplemented with the following: Layout and Conformance to Grades Using the information provided in the Contract documents, the Contractor shall layout, grade, and form each new curb ramp, sidewalk, and curb and gutter. (April 12, 2018 CFW GSP) Section 8-14.3 is supplemented with the following : Cement concrete sidewalk thickness shall be as shown on the Plans. Score joints shall be constructed at a maximum distance of 5 feet from each full depth expansion joint, except where specific dimensions are detailed on the Plans. Asphalt mastic joint fillers in the sidewalk shall be 3/8" x 4" and of the same material as that used in the curb, and shall be placed in the same location as that in the curb. No concrete for sidewalk shall be poured against dry forms or dry subgrade. The Contractor may provide suitable vibrating finishers for use in finishing concrete sidewalks. The type of vibrator and its method of use shall be subject to the approval of the City. All completed work shall be so barricaded as to prevent damage. Any damaged sections shall be removed and replaced at the Contractor's expense. Landscaped areas disturbed during construction shall be restored to original condition at the Contractor's expense. Scored Cement Concrete Sidewalk shall be broom finished and scored as detailed on the Plans. (April 12, 2018 CFW GSP) Section 8-14.3 is supplemented with the following : Pervious Cement Concrete Sidewalk Mix Time: Truck mixers shall be operated at the speed designated as mixing speed by the manufacturer for 75 to 100 revolutions of the drum. Transportation: The portland cement aggregate mixture may be transported or mixed on site and should be placed within one (1) hour of the introduction of mix water. This time can be increased to 90 minutes when utilizing a hydration stabilizer. Water may only be added by the concrete producer to obtain the required mix consistency.A minimum of 20 revolutions at the manufacturer's designated mixing speed shall be required following any addition of water to the mix. Jointing: Control (contraction) joints shall be installed normally at 12 foot to 15 foot intervals, a maximum of 15 foot intervals is allowed. Control joints shall be located so as to match the joints in the curb and gutter, whether the pervious concrete sidewalk is adjacent to the curb or separated by a planter strip. They shall be installed at a depth of '/4 the thickness of the sidewalk. These joints can be installed in the plastic concrete with a rolling joint tool designed specifically for this purpose or saw cut (with prior approval of Engineer). Sawcutting is not the preferred joint method. If saw cut, the procedure should begin as soon as the sidewalk has hardened sufficiently to prevent raveling and CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY(NTS) PROGRAM AUGUST 2019 SP-97 RFB#19-006 CFW SPECIAL PROVISIONS VER.2019.04 uncontrolled cracking (normally after curing). Transverse construction joints shall be installed whenever placing is suspended a sufficient length of time that concrete may begin to harden. In order to assure aggregate bond at construction joints, a bonding agent suitable for bonding fresh concrete to existing concrete shall be brushed, rolled or sprayed on the existing sidewalk surface edge. Isolation (expansion) joints will not be used except when sidewalk is abutting slabs or other adjoining structures. Placing and Finishing Equipment: Unless otherwise approved by the Engineer in writing, the Contractor shall provide mechanical equipment of either slip form or form riding with a following compactive unit that will provide a minimum of 10 psi vertical force. The pervious concrete sidewalk will be placed to the required cross section and shall not deviate more than +/- 3/8 inch in 10 feet from profile grade. If placing equipment does not provide the minimum specified vertical force, a full width roller or other full width compaction device that provides sufficient compactive effort shall be used immediately following the strike-off operation. After mechanical or other approved strike- off and compaction operation, no other finishing operation will be allowed. If vibration, internal or surface applied, is used, it shall be shut off immediately when forward progress is halted for any reason. The Contractor will be restricted to sidewalk placement widths of a maximum of fifteen (15') feet unless the Contractor can demonstrate competence to provide sidewalk placement widths greater than the maximum specified to the satisfaction of the Engineer. Curing: Curing procedures shall begin immediately after the final placement operations. The pavement surface shall be covered with a minimum of (6) mil thick polyethylene sheet of other approved covering material. Prior to covering, a fog shall be sprayed above the surface when required due to ambient conditions. The cover shall overlap all exposed edges and shall be secured to prevent dislocation due to wind or adjacent traffic conditions. Cure sidewalk for a minimum of 7 days, unless otherwise specified. Testing and Acceptance of Pervious Cement Concrete Sidewalk Test Panels: The Contractor shall place, joint and cure one test panel, each to be a minimum of 50 square feet at the project site to demonstrate to Engineer's satisfaction that a satisfactory sidewalk can be installed at the location. If the test panel meets Engineer's approval for aesthetics and pressure wash testing, it can be left in-place and included in the completed work. If the requirements mentioned above are not met, the test panel shall be removed at the Contractor's expense and disposed of in an approved landfill. Pervious Concrete Void Structure: The Pervious Concrete Void Structure shall be tested in accordance with ASTM C 1688 and shall be between 15 and 25 percent. Unit Weight: The Contractor shall test, in accordance with WAQTC TM 2 and AASHTO T 121, at least one sample for each day's placement of pervious cement concrete to verify unit weight. Delivered unit weights shall be determined in accordance with AASHTO T 121. The measure shall be filled and compacted in accordance with AASHTO T 19M/T 19 paragraph 11, jigging procedure. The unit weight of the concrete shall be +/- 5 pcf of the design unit weight. Pressure Wash Testing: The Contractor shall pressure wash the pervious concrete sidewalk using a washer working at a minimum of 3,000 psi and 1.0 gpm. The nozzle CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY(NTS) PROGRAM AUGUST 2019 SP-98 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 shall be held a maximum of 3 inches off the concrete. The Contractor shall wash the entire top surface of the pervious concrete sidewalk. Sections of pervious concrete that breaks up, pits or does not infiltrate shall be removed and replaced, at no cost to the Contracting Agency. Remove and Replace Concrete Curb Ramp, Complete In Remove and Replace Concrete Curb Ramp,Complete,the contractor shall complete the following items as shown in plans and as incidental to this Bid item: 1. Sawcutting of existing curb and gutter, sidewalk or pavement 2. Removing Cement Concrete Sidewalk to nearest joint or as directed by the City 3. Removing Cement Concrete Curb and Gutter adjacent to curb ramp location to nearestjoint or as directed by the City. 4. Install Cement Concrete Curb and Gutter(depressed section)and associated CSTC base 5. Removal and replacement of asphalt pavement with HNA CL 1/Z PG 64-22 6. Install Cement Conc. Curb Ramp,Type as directed bythe City,and associated CSTC base. 7. Install any necessary Cement Conc. Pedestrian Curb if required as part of Curb Ramp design selected by City from the list in 8-14.4. 8. Replace any Cement Conc.Sidewalk removed between sidewalk joint and constructed curb ramp The City shall designate the locations and limits of removals. 8-14.3(5) Detectable Warning Surface (April 12, 2018 CFW GSP) Section 8-14.3(5) is supplemented with the following: MMA-Style Truncated Dome Detectable Warning Surfaces applied to asphalt surfaces shall be liquid-applied Vanguard ADA Systems, or approved equal. 8-14.4 Measurement (April 12, 2018 CFW GSP) Section 8-14.4 is supplemented with the following: Cement concrete sidewalk and driveway approaches for removal and replacement shall be measured by the square yard of finished surface replaced. The City inspector shall designate the locations and limits of removal. Remove and Replace Concrete Curb Ramp shall be measured per each, and shall include all items necessary to install a complete curb ramp per appropriate detail, to include as incidental the detectable warning surface, removal and replacement of existing curb ramps, curb, gutter, sidewalks, cement conc. pedestrian curb, and all traffic control. The City inspector shall designate the locations and limits of removal. Asphalt removal, replacement, and/or patching shall be considered incidental. Pedestrian Curb behind the sidewalk (if required) will be considered incidental and not measured. The specific the type of Curb Ramp to be constructed shall be determined by the City. Accepted Curb Ramp types include: Combination Curb Ramp, per WSDOT Standard Plan F-40.14, CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY(NTS) PROGRAM AUGUST 2019 SP-99 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 Parallel Curb Ramp, per City of Federal Way Drawing No. 3-8, 3-8A, or 3-813 Single-Direction Curb Ramp, per City of Federal Way Drawing No. 3-10 or 3-10A Perpendicular Curb Ramp, per City of Federal Way Drawing No.3-11 Measurement for removing and installing Cement Concrete Curb and Gutter up to twenty-five (25)feet for curb ramp construction will be incidental to Bid item"Remove&Replace Curb Ramp, Complete". Measurement for removing and replacing Cement Concrete Sidewalk within the twenty- five (25)foot curb ramp envelope of curb ramp construction will also be incidental to Bid item "Remove &Replace Curb Ramp, Complete". Pervious cement concrete sidewalk will be measured by the square yard of finished surface. Thickened Edge Sidewalk will be measured per linear foot. 8-14.5 Payment (April 12, 2018 CFW GSP) Section 8-14.5 is supplemented with the following: Payment for "Cement Conc. Curb Ramp Type " will not be made until the City has verified that the ramp(s) meet ADA requirements. "Pervious Cement Concrete Sidewalk", per square yard. "Thickened Edge Sidewalk" per linear foot. Payment for "Thickened Edge Sidewalk" will be made in addition to any payment per square yard for"Cement Conc. Sidewalk." " Remove and Replace Concrete Curb Ramp, Complete", per Each "Remove and Replace Concrete sidewalk, Complete", per square yard 8-32 ASPHALT CONCRETE SPEED HUMP New Section 8-32.1 Description The work shall consist of constructing asphalt concrete speed humps with associated pavement striping per City of Federal Way Detail DWG No. 3-26. 8-32.2 Materials Asphalt concrete for speed humps shall be HMA Class 1/2" PG 64-22 meeting the requirements of Section 5-04 of the Standard Specifications. Pavement marking materials shall be white plastic meeting the requirements of Section 8-22.2 of the Standard Specifications. Raised pavement markers should be Type 2 YY and Type 2W meeting the requirements of Section 8-09.2 of the Standard Specifications. 8-32.3 Construction Requirements The various materials shall be installed as noted on the plan detail. 8-32.4 Measurement CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY(NTS) PROGRAM AUGUST 2019 SPA 00 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 Measurement will be per each where a speed hump and associated temprory pavement markings are installed. 8-32.5 Payment "Speed Hump, Complete", per each. The unit bid price per each proposal will be full compensation for the cost of all tools, labor, equipment, and materials necessary or incidental to provide and install the asphalt concrete speed hump and pavement markings. 8-33 ASPHALT CONCRETE SPEED TABLE OR RAISED CROSSWALK New Section 8-33.1 DESCRIPTION The work shall consist of constructing asphalt concrete speed table or raised crosswalk with temporary pavement striping per City of Federal Way Detail DWG No. 3-27 or 3-27A. 8-33.2 Materials Asphalt concrete for raised crosswalk shall be HMA Class '/2" PG 64-22 meeting the requirements of Section 5-04 of the Standard Specifications. Permanent pavement markings and Raised pavement markers done by others. 8-33.3 Construction Requirements A "toe" grind is required on the two long sides as noted on the plan details Drawing 3-27 or 3- 27A. 8-33.4 Measurement Measurement will be per each where a speed table or raised crosswalk when temporary pavement markings are installed. 8-33.5 Payment "Raised Crosswalk, Complete", per each. "Speed Table, Complete", per each. The unit bid price per each proposal will be full compensation for the cost of all tools, labor, equipment, traffic control, and materials necessary or incidental to provide and install the asphalt concrete speed table or raised crosswalk with temporary pavement markings. END OF DIVISION 8 CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY(NTS) PROGRAM AUGUST 2019 SP-101 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 DIVISION 9 MATERIALS 9-03 AGGREGATE 9-03.12 Gravel Backfill 9-03.12(6) Pit Run Sand (April 12, 2018 CFW GSP) Section 9-03.12(6) is a new section: Sieve Size Percent Passing 3/8" square 100 U.S. No. 4 90 Sand Equivalent 30 minimum 9-03.14(3) Common Borrow (April 12, 2018 CFW GSP) Section 9-03.14(3) is modified with the following requirements: Material from on-site excavations meeting the requirements for Common Borrow shall be used to the extent practicable. Material for common borrow shall consist of granular soil and/or aggregate which is free of trash, wood, debris, and other deleterious material. Common Borrow material shall be at the proper moisture content for compaction. This material is generally moisture sensitive. The natural moisture content shall range from not more than 1 percent wet of optimum to not more than 3 percent dry of optimum as determined in accordance with Section 2-03.3(14)D. The material shall not pump or yield under the weight of compaction equipment and construction traffic. The Contractor is responsible for protecting the material from excess moisture wherever/whenever possible. To the extent practicable, this material should be handled only during non-rainy periods and should be removed, hauled, placed, and compacted into final embankments without intermediate handling or stockpiling. Surfaces should be graded and sloped to drain and should not be left uncompacted. Common Borrow shall meet the following gradation limits: Sieve Size Percent Passing (by weight) 6" square ' 100 4" square 90 - 100 2" square 75 - 100 U.S. No. 4 50 - 80 U.S. No. 40 50 max. U.S. No 200 25 max. For geosynthetic reinforced walls or slopes, 100percent passing 1'/4- inch square sieve and 90 to 100 percent passing the 1-inch square sieve. Common Borrow shall contain sufficient fines for compaction and to bind the compacted soil mass together to form a stable surface when heavy construction equipment is operated on its surface. CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY (NTS) PROGRAM AUGUST 2019 SPA 02 RFB#19-006 CFW SPECIAL PROVISIONS VER.2019.04 SECTION 9-18 PRECAST TRAFFIC URB AND BLOCK TRAFFIC CURB 9-18.3 Vacant (December 12, 2012 CFW GSP) Section 9-18.3 is deleted and replaced with the following new Section: 9-18.3 Block Traffic Curb In construction of the block traffic curb, the Contractor shall have the option of using either length block shown in the plans, provided the same length block is used throughout the entire project. The curb units shall be made from portland cement and high quality sand and gravel, the proportions of which will be left to the discretion of the producer as long as the unit develops a minimum compressive strength of 1,600 psi at 28 days when tested for end loading. The proportions of sand, gravel, and cement, the type of forms used, and the method of compacting the concrete in the forms shall all be such that as dense, smooth, and uniform a surface as is practicable for a concrete masonry unit is obtained on the finished curb units. The faces that are to be exposed shall be free from chips, cracks, air holes, honeycomb, or other imperfections except that if not more than 5 percent of the curb units contain slight cracks, small chips not larger than 1/2 inch, or air holes not more than % inch in diameter or depth, this shall not be deemed grounds for rejection. The units used in any contiguous line of curb shall have approximately the same color and surface characteristics. END OF DIVISION 9 CITY OF FEDERAL WAY 2019-2021 NEIGHBORHOOD TRAFFIC SAFETY (NTS) PROGRAM AUGUST 2019 SP-103 RFB#19-006 CFW SPECIAL PROVISIONS VER. 2019.04 s 4 J00 W ZU3 Ic IL m a r IL Z VI \ ` C-4L I r. A` r, U U aa 'yy ry0p � 'ii �A,� A'•. 7 7 U W m 0 La S W A r V �2 Q 6�W =ANO w�xa i i �1LL .MLs.L " TD:1.3 N OZJmV � £a a Z ee Y_ JJ o W m Zr 0 ,<1ne - > CL W G V03 I N P fY 2 � a 2 m LU 4 V 0 V 0 LU W j O � 7j� SN3l1391110 :AS NMVUO a z w M7 J dtIL N Q e ~ 0 tu # o � ~ W 8 U I s = I JIMi i.l r w y�H 0 O W IOiV_� W �- w m�noLL J i . i it y (pYJ OO iO �\ E V ZVQ l J y o ^ uQu I ' y HNYO U _0m. F@LLO a O OO 1 O O O O O O O O ~ U 7 a F r - F H H H H H f H W w�nmU V N i NOm Z �•B� tl 9 7 8 Q J m W ------------------------- ILF W O + - N i = f } }5 SNaURS llle *AS NMtlHd � e Cc) 16 j e6 ZL I. m = ur; g c3 f � JV -7 �w •y h Q W O C Y h 1 V i W d #i 1 I x{ JO ff W dp�dx �r,�y d f W m IIil ++ me 1 w a i O sits g �9 ItJW O Z V9 d =W --, LC t \� t! I c J Z f r h -r o r zan>R.a � vttx,t Z cYi ul m V 0 N K r i c 1! G. z c p y O m C C 9 m W `14 poh m $ N c c r Y O � = m E'S m _ £� _, 5 2 . & assns Y w �Ec mL � �' w •re1iL v� c e 0 mE —T- CL acv Ctll O _ 20 , o tl tr zt z/t r b lu LU I a o ui W a ball q• 'A fq I I H V! � O d. Q C I N N r r N l• ' II 4 T z = c z � vI d r a} z ry •v 11 o LL. L � Zntt SN3b3S TIM :AS WY80 �� Z�'l� � k � 3C kS e. _s B 2w �o § \/ (If \ \ \ It \ . a ƒ d 2 \ _ LLI \ w ' < k ■E \ - <, - ' Ld . e � §cm k . w � � 2§ E -- � § .9 §� A s§ z a . a. a. u &% z z w cm , . w ■ 22 / G% 3 0Ld y \ w ZI _ 0313AV& £ a ƒ LLU i , a ED � � � � � , ! . B ƒ ! p U� � K 2& ui \ rfloi o ■ e , § � � © / 77 . . . § } zI z ■ M w � ( $ LAJ / . I . � \ / z u b < Of ) \ . % < \ \LLJ ƒ } } . 2 It eIr 5 F- , � sm� 2 E c0 w . w 2 ,J » 7 $ 2 zz E°°� k �� \ > � �k� / ui a� c &� a I _ ■# b ` %�/ § 0 W Lf �\ ¢0 / La �K) W / �§ <00 Wal Li / 0 W D x Q � � s .� c �e V . z \ LLJ h 2 §} f J u LLJ - c LE w � E - & M k LLJ& \ C � MCE UR 22 2 = � ! W zCY _ i uZ § \ O < o � <a i \ 7 I 3 / <LLI #� u § = b � o § , CEMENT CONC. BARRIER CURB 5'MIN. 4'MIN. 5'MIN. TRANSITION SIDEWALK TRANSITION SEE NOTE 2 (TYP) SEE NOTE 2 DISTANCE WILL SIDEWALK \ VARY-SEE NOTE 1 SEE NOTE 1 y\ SAWCUT MATCH LINE (TYP) EX.SIDEWALK N Q N EX.SIDEWALK = 00000000000 .PLANTER STRIP'.'.'. OcO00000000000000000000 2' PLANTER STRIP 0o 0000000 CURB & --- -- - --- - - - - GUTTER _ _ T _ _ _ DETECTABLE WARNING — SURFACE-SEE DETAIL 5%MAX. DUMMY JOINT(TYP) CENTER OF RAMP AS SLOPE MARKED IN THE FIELD CEMENT CONCRETE BARRIER CURB PER DWG 3-4.TOP OF CURB TO BE FLUSH WITH 4' N G TOP BACK OF EXISTING SIDEWALK TRANSITION SIDEWALK (TYP.EACH END OF RAMP) SEE NOTE 1 EXISTING SIDEWALK DETECTABLE WARNING SURFACE (SEE DETAIL) A r'i7_•' F PLANTER STRIP d -r P NOTES: 1. THE LENGTH OF THE TRANSITION SIDEWALK SECTION SHALL BE EQUAL TO 1 FOOT MULTIPLIED BY THE DIFFERENCE BETWEEN THE CROSS—SLOPE PERCENTAGE OF THE NEW AND EXISTING PANELS. (I.E.. EXISTING PANEL CROSS—SLOPE IS 4% AND NEW PANEL CROSS—SLOPE IS 2% FOR A DIFFERENCE OF 2. 2 MULTIPLIED BY 1 FOOT = 2 FOOT TRANSITION SECTION). IF — THE NEW AND EXISTING CROSS—SLOPES ARE EQUAL, THEN THE TRANSITION SECTION IS NOT NEEDED. den rn +� 2. LENGTH SHALL BE: 5 FEET (MIN.) AND UP TO 8.3%; 0 'X' FEET ® 8.3% (WHERE 'X' IS EQUAL TO THE LENGTH REQUIRED TO ACHIEVE 8.3% MAXIMUM SLOPE), BUT NOT TO EXCEED 15 FEET IN LENGTH. MAR 2017 PUBLIC CURB RAMP IN SIDEWALK DWG. NO. ° a `� WORKS WITH PLANTER STRIP 3-8 CEMENT CONC. BARRIER CURB --\ 5' MIN. 4'MIN. 5'MIN. TRANSITION SIDEWALK TRANSITION SEE NOTE 2 (TYP) SEE ��!C��E 2 DISTANCE WILL SIDEWALK ` VARY—SEE NOTE 1 SEE NOTE 1 y` 1 c IT X SAWCUT MATCH EX. c : N < LINE (TYP) SIDEWALK if 00000000000 EX.SIDEWALK 00000000000 2 00000000000 00000000000 CURB&- - - - - - - - - — GUTTER DETECTABLE WARNING — T SURFACE—SEE DETAIL \/_ 5`%MAX. DUMMY JOINT (TYP) CENTER OF RAMP AS ,.'� SLOPC MARKED IN THE FIELD CEMENT CONCRETE BARRIER CURB PER DWG 3-4.TOP OF CURB TO BE FLUSH WITH 4.Ml TOP BACK OF EXISTING SIDEWALK TRANSITION SIDEWALK TYP.EACH END OF RAMP, AS NEEDED—SEE NOTE I DETECTABLE WAR NIIIIG SURFACE (SEE DETAIL) a EXISTING SIDEWALK NOTES: 1. THE LENGTH OF THE TRANSITION SIDEWALK SECTION SHALL BE � EQUAL TO 1 FOOT MULTIPLIED BY THE DIFFERENCE BETWEEN THE CROSS—SLOPE PERCENTAGE OF THE NEW AND EXISTING PANELS. (I.E., EXIST;NG PANEL CROSS—SLOPE IS 4% AND NEW PANEL CROSS—�ACPE IS 2% FOR A DIFFERENCE OF 2. 2 MULTIPLIED BY 1 FOOT = 2 FOOT TRANSITION SECTION). IF THE NEW AND EXISTING CROSS—SLOPES ARE EQUAL, THEN THE TRANSITION _ SECTION IS NOT NEEDED. 2. LENGTH SHALL BE: 5 FEET (MIN.) AND UP TO 8.3%; -OR 'X' FEET 0 8.3% (WHERE 'x' IS EQUAL TO THE LENGTH REQUIRED TO ACHIEVE 8.3% MAXIMUM SLOPE), BUT NOT TO EXCEED 15 FEET IN LENGTH. MAR 2017 CUvw PUBLIC CURB RAMP IN SIDEWALK DWG. NO. ° Way WORKS NO PLANTER STRIP 3-8A m 2 D oX �tQ£WALK d R2 > vnq iN N PER PLAN rq � q � x Q M ' ri lmI or 0 0C Z;orm x I 7C r a m m I II Z s �� m q z u O Z� AZ z-4 I/I Lao h Y M Dn ' e Y� A~ m m M W� mp p9 W� U� mA m2 � i gz CalN � Z r t� s 1DrI7�� vpa A 0m rnr�i cn DA M O CROSSWALK CZ_nC O=i D=�"'tD mt> om cr^ -2cMm W 02 mN;S�-0 HA2 �. M rOpx AmZ A r� � D20 W p� n mr.znr -0mcn 1 DXQm'zl ONC D O to ZC7C AZZ ��rr �mrn-� r,� s _ Z DF-j-n Z00 rQi ��qp //�� -4 rl g Z z a t 0 9Ti 1 \/ >, �s .cz 0Q O O O O Q o vi m:�l©Qf''! 1_fm11 p ii m O C7 -W 7 [� NCr�gGS A> O O O O v� m Z r'"O_D m o �+ O `g tsn� E% o z *� r�Z�or ;m > yW r O �D $r/1Zm Oc � Al >i Ofmm�C Z� a Zn s E n � 2 a L sQQQ� T N Ir m W � 9 � r O O w m x °mpem m� v ► amm Wz ► fl xm� Am t 0 p mm H K Y ap no tl ti cm (n m A 1 `.+ m.. rn mm •u z m A_ mmC mm m m-n r r: ' ZT� m ! 1 la... mp 1 �z m ami o 0 p� Zp 0 m m m z 21;a z mac` y Z Y }a V GI Cm cm m mm a'm p rmt C T61 D L m op CRDSSWAK cn u a p c Y/ n r z m m _ � A M rm Dn z 15 R1 =��== D0O m Mm1^nm �.. n 0oz ;ozzKxim mm� aoO�v ��r m=1>D D x ;m� m CZ 220 �y � � � CCom _ M D01� ' ➢� o a c�'n g z �m Po d m Z 4^1 m mxC �Zo 1/r o o v Co mD 'V uDiunnC SNC �; m o o o jm* T1 C]C7Z ZZ ' CIO maa Sz Z rrq 7COi� 0 z z v� t m �z C7lj� Z�Z r aura =� rGl V1?9mr�] cZ,m to n i n-- H Dv O ?' mmo Dr�i� 01v „m m �gg m b ��fDbrn ern � mz��v n Z m T� x; C zrn— — Frl Fn � a rn 0 0 z m ozc n� W Dn'm zCD C > O = V CS 2 FOOT WIDE, ' EPTH ASPHA, RIND, _ < TYP, BOTH ENDS (SEE NOTE t) di33 S2 d J- RPM TYPE II (WHITE){ � I i A WL—.e---I-� Z 3 PM TM-PE!11. YELLOW - ON STREETS WITH MARKED CENTERLINE (TYP.) i W�ITE APLASTIC MARKINGS PER WSDOT STND PLAN M-24.60 (TYPICAL) a I m � 1S Q u � , �g a SIGN DESIGNATION / SIZE W8-1 BUMP 30" x 30" W8-IA BUMP AHEAD 30" x 30" W13-1(15) 15 MPH ADVISORY PLAQUE 18" x 18" NOTES: 1) ADVANCE SIGNS USED ONLY FOR FIRST IN SERIES 2) WHEN 2 OR MORE BUMPS. REPLACE W8-1A WITH WB-lA(S) (BUMPS AHEAD) 0 c, co o f7 N !y nl n! IA } ,. ,. SECTION A-A - PARABOLIC CROWN 2 FOOT WIDE, JS" DEPTH ASPHALT GRIND, TYP. BOTH ENDS (SEE NOTE 1) STANDARD CLASS D OR a 6" CLASS C MIX (TYP) 6" 6" �1'-2' mu--TAPER MAX.TAPER CURB FACE GUTTER SHOULDER TACK COAT (TYP) SECTION B-B (CURB AND GUTTER) SECTION B-B (SHOULDER) NOTE: 1.) PRIOR TO SPEED HUMP CONSTRUCTION. THE ENGINEER MAY REOUIRE ASPHALT GRINDING IN ORDER TO PROVIDE A SMOOTH TRANSITION. REV.MAY2013 PUBLIC SPEED (HUMP DWG. NO. 4 p ay WORKS 3-26 2 FOOT WIDE, )4" DEPTH j ASPHALT GRIND, TYP. BOTH ENDS (SEE NOTE 1) m I WHITE PLASTIC t; MARKINGS PER DWG NO 3-20 _m-iff PLASTIC MARKINGS PER (TYP) A a n WSDOT STND PIAN M-24.60 (TYP) 4 RPM TYPE II, YELLOW — ON STREETS WITH A MARKED CENTERLINE (TYP.) q; f' \---RPM TYPE II (WHITE) " � V l ' ZI �Tz D 'agNN N G SIGN DESIGNATION / SIZE W11-2 MAN WALKING 30" x 30" W8-1A BUMP AHEAD 30" x 30" W13-1(20) 20 MPH ADVISORY PLAQUE 18" x 18" W16-7P ARROW DOWN 24" x 12" NOTES: 1) ADVANCE SIGNS USED ONLY FOR FIRST IN SERIES 2) WHEN 2 OR MORE BUMPS, REPLACE W8-1A WITH W8—IA(S) (BUMPS AHEAD) I 3) USE YELLOW—GREEN SIGNS 4) USE S1-1 INSTEAD OF W11-2 FOR SCHOOL CROSSINGS b orn cp v 17 N N1 NN �_ m SECTION A-A - PARABOLIC CROWN 2 FOOT WIDE, )4" DEPTH ASPHALT GRIND, TYP. BOTH ENDS (SEE NOTE 1) STANDARD CLASS D OR L� � 3, CLASS C MIX (TYP) — b••1 —2 TAPER MAX 3' I TAPER CURB FACE �— GUTTER SHOULDER TACK COAT (TYP) SECTION B—B (CURB AND GUTTER) SECTION B—B (SHOULDER) NOTE: 1.) PRIOR TO SPEED HUMP CONSTRUCTION, THE ENGINEER MAY REQUIRE ASPHALT GRINDING IN ORDER TO PROVIDE A SMOOTH TRANSITION. REV.MAY 2015 _ PUBLIC RAISED CROSSWALK DWG. NO. 3-27 I� rloJg My WORKS 1aa' TYP 2 FOOT WIDE, h- DEPTH ASPHALT GRIND, TYP. BOTH ENDS (SEE NOTE 1) \ N; �r. I x C RPM TYPE II (WHITE )A ) '¢ I RPM TYPE II, YELLOW - ON STREETS WITH A IfIAR EO CENTERLINE (TYP.) WHITE PLASTIC MAJKIN 5 PER WSOOT STND PLAN M-24.60 (TYP) n 6 D 100' (-f-) SIGN DESIGNATION / SIZE W8-1 BUMP 30" x 30" W8-1A BUMP AHEAD 30" x 30" W13-1(20) 20 MPH ADVISORY PLAQUE -187-x 18" NOTES: 1) ADVANCE SIGNS USED ONLY FOR FIRST IN SERIES 2) WHEN 2 OR MORE BUMPS, REPLACE W8-1A WITH W8-IA(S) (BUMPS AHEAD) 0 'oi m `v e'1 N N N N U7 m ` O 1 } 1 1+ 1. 1 1• 1 1. a' SECTION A—A — PARABOLIC CROWN 2 FOOT WIDE, !4" DEPTH ASPHALT GRIND, TYP. BOTH ENDS (SEE NOTE 1) STANDARD CLASS D OR a � 3. CLASS C MIX (TV) 8"1 -2 MAX TAPER� MAX• 3 TAP'ER CURB FACE � GUTTER �SH.UL TACK COAT (TYP) SECTION B-B (CURB AND GUTTER) SECTION 8-8 (SHOULDER) NOTE: 1.) PRIOR TO SPEED HUMP CONSTRUCTION, THE ENGINEER MAY REQUIRE ASPHALT GRINDING IN ORDER TO PROVIDE A SMOOTH TRANSITION. REV.MAY 2015 �« PUBLIC SPEED TABLE DWG. NO. [ lSMO'My WORKS 3-27A U � m p ` 0 nCc, < -Z, K) w mem N w D O x O N r O E Z f. mD o m CrN3 O z m =ate en m m aq O r � 6 b'- � " O-1 mx {off z m i m �I t =E m— o G� cOn �� Z1 Z C7 n C1 C7 N i� r -! r C"7 C Z o z OC m w m m M O N O D CAJ v oN xZ Z -4 x G ov N C7 % :0 m- cn G) m Cl) ro -•I - ao c? z � � O�Z D C) o m 0 -n -n Cl) -1 r Z 1] T p -< O w I O m � + a A Z > � Z ` -< O > �m U) _ m� r : N m m OTD cn- IK pN � � r- ZN J D D x wo ❑ � C 2 Z N w m m r gm mo O 00 -- 0 p y gg DD C7 O1 � L ly4 N � vo M Om ;a Ci) � -4 Cl) 2 * > ;a m �� < z C) m Mn m C O cz �j � F- o -M U - c U' o � mm °) Z � Q rn m trn -nxc Cp v ND m N Z X?v A 0m cU) 0 x N r w N Ocn ;u Dm 0 = n C K Q N m �N `. o K N K U3 D ! I v 10 (nDmmCyn [ SIO mo m� O m mmm CO � L n z r n�m Onrr { r �p0 Dr � � = N ' � m = N x n q Tvm W m mU) OG m z m XMA m -4 C3 np D Q AZ �;0 v G Z w O Z N 0 r J R C z wo z Vo m Z S o �Q LL z m _ a- oU oW �~LLI LUc_imo a>� oo �< cc ir w_jw Wm wvw =aa LLJ OU 0� M W 2 Z O w" NX } a z wUZ a> W LLJ mz w ww z �� o >aa mN o0w 10 Ua0o Udo a0 w � w aN ZWw a � V) azo oz za uwiaa I -w2 wa 0 a O w mX wa z_� waw oa mm� z oUU� oQ0 � N as �-�� J U V) \z �w� LLJ Wim oa aL) �w�w ,�,V)L, ocr o,,, 00 NSW �� OOz0 �w-� m=0 ma �a �� zoo aJ z �0X mU�a J�o � w� X0 V-z� 0fx V" Z Oa o =)00 a='- 0 OU U Ow p- F Z 2 W m0 U? Sao ZCX ZIaZ a Z � a� a o cD� me w UOF Qi mZ � �V�m QX> Ud ww �w Z ,,,� Q a I o ��x:DNao NV) �� LVLJ z= Q�� mQ LLJ Z Twp3 Z��F U- 0 W Q � 00 O a JU0 2WW � 2Oa� JWC)W gym= O �- aw a zQ V) J JZ ~ �W XQ HmZ Z N Wa v) o Umz 0200 Jazo WO I Lr za zcnJ inV)w z w V)Q� 0 L�aLLa UUM c� -- � — W N Ki c LU � I J ! V a FZ V a a Q > ^�. i J d V) Z w V)t- 0 _ w o I W O LL QdQ ViZ)ati `, -11 WC a UL w c� I ! - >w Ln O 0 ��W .I I �' r"� LJU `!de VI V Al <Za p } cr � ! N O O � V)Vo i w w 1 amL) iy! � W Ww �- a » > QS �. , mJ 0 Z LL 0 11.0 O N� UJ NIIN z W L Z mu)o J L 0`F- Q v L' M(-) U tom¢ Q L) Of ~ UV) .� aaV) �Y o J mo a - a0 a ~ mr 00 Z U w m :mJ Q O O WmJ ~ LLJ LLJm o<4 r� wQ� w Zp W 3S UU CC_ )0V) - Q J J z w J J-� HH J m � J a W O Y aha W V)Wco 0- 0 O U Z~ O a 3: Of Q z I W Z m W U U a W i m W Z()f W dU�� aUa ,. irc Y # so b z10 z a Ej 1p a ! o6z F Tsj aZ v � m z ul oaf W bl T—F IL L z A oo W W LU re, s z A X t A .L .L Qt� � it io �■ � � �� b � �� a � iV ab -"16 'AQ ANAVW 5127(2020 Corporations and Charities System k,essWP07 sand Charities Filing System BUSINESS INFORMATION Business Name: TONY LIND PAVING LLC JB1 Number: 602 813 830 Business Type: WA LIMITED LIABILITY COMPANY Business Status: ACTIVE Principal Office Street Address: 23048172ND AVE SE,DENT,WA,980424213, UNITED STATES Principal Office Mailing Address: 23048 172ND AVE SE, KENT,WA, 98042-4713, UNITED STATES Expiration Date: 63/31/2021 jurisdiction: UNITED STATES,WASHINGTON Formation/ Registration Date: 03/16/2008 Period of Duration: PERPETUAL Inactive Date: Nature of Business: CONSTRUCTION REGISTERED AGENT INFORMATION littps.Ilcctssos.wa.gc��f#IBusinessSearclifBusinessl7frrnati�i 1/2 5/27/2020 Corporations and Charities System Registered Agent Name: JEFF BOYER Street Address: 23048172ND AVE SE, KENT,WA, 98042-4713, UNITED STATES Mailing Address: GOVERNORS Title Governors Type Entity Name First Name Last Name GOVERNOR INDIVIDUAL ANTHONY LIND Back Filing History Name History Print Return to Business Search https://ccfs.sos.wa.gov/#/BusinessSearch/Businessinformation 2/2